Seattle Washington Building Expert Directory

Standard For Evaluating Delay – Directly from An Armed Services Board Of Contract Appeal’s Opinion

October 04, 2021 — David Adelstein - Florida Construction Legal Updates
Sometimes, it is much better to hear it from the horse’s mouth. That is the case here. The Armed Services Board of Contract Appeal’s (ASBCA) opinion in Appeals of -GSC Construction, Inc., ASBCA No. 59402, 2020 WL 8148687 (ASBCA November 4, 2020) includes an informative discussion of a contractor’s burden when it encounters excusable delay and, of importance, the standard for evaluating delay. It’s a long discussion but one that parties in construction need to know, appreciate, and understand. EVERY WORD IN THIS DISCUSSION MATTERS. Construction projects get delayed and with a delay comes money because time is money. Many claims are predicated on delay. These can be an owner assessing liquidated damages due to a delayed job or a contractor seeking its costs for delay. Either way, the standard for evaluating delay and the burdens imposed on a party cannot be understated and, certainly, cannot be overlooked. For this reason, here is the discussion on evaluating delay directly from the horse’s mouth in the Appeal of-GSC Construction, Inc.:

The critical path is the longest path in the schedule on which any delay or disruption would cause a day-for-day delay to the project itself; those activities must be performed as they are scheduled and timely in order for the project to finish on time. Wilner v. United States, 23 Cl. Ct. 241, 245 (1991). In Yates-Desbuild Joint Venture, CBCA No. 3350 et al., 17-1 BCA ¶ 36,870, our sister board compiled an excellent and very helpful synopsis of the standards for evaluating delay claims, which I adopt nearly verbatim among the discussion that follows.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Housing Starts in U.S. Beat 1 Million Pace for Second Month

June 18, 2014 — Shobhana Chandra – Bloomberg
Builders broke ground on 1 million U.S. homes in May, indicating the industry is picking up this quarter after a weather-induced slump to start the year. The number of housing starts last month was in line with the median forecast of economists surveyed by Bloomberg and followed April’s 1.07 million annualized rate that was the most since November, a Commerce Department report showed today in Washington. Permits, a proxy for future construction, decreased, reflecting a decline in the volatile multi family category. A strengthening job market and a retreat in mortgage costs in recent weeks is helping support residential real-estate following a lull in building in early 2014. Faster sales will prompt developers to step up construction, given supplies of homes on the market remain lean and property values are rising. Read the court decision
Read the full story...
Reprinted courtesy of Shobhana Chandra, Bloomberg
Ms. Chandra may be contacted at schandra1@bloomberg.net

The (Jurisdictional) Rebranding of The CDA’s Sum Certain Requirement

April 15, 2024 — Jordan A. Hutcheson and Stephanie Rolfsness - Watt Tieder
The Contract Disputes Act (the “CDA”), 41 U.S.C.A. §§ 7101 et seq., which has provided the statutory framework for resolution of most contract disputes between the federal government and its contractors since 1978, has recently been the subject of changes in judicial interpretation, despite no corresponding statutory changes. The CDA’s implementing provisions in the Federal Acquisition Regulations (FAR), require that contractors submit a claim to the government in the form of written demand to a contracting officer requesting a final decision and seeking the payment of money in a sum certain prior to pursuing resolution via board or court. However, with respect to the sum certain requirement, the United States Court of Appeals for the Federal Circuit issued an opinion in late 2023 determining that this requirement “should not be given the jurisdictional brand” as it has categorically received in the past. Rather, the court concluded that the sum certain requirement is merely an element of a claim for relief under the CDA that a contractor must satisfy to recover. This rebranding does not debase the sum certain requirement, but it does indicate a renewed focus on what constitutes “jurisdictional” in government contracts litigation. Reprinted courtesy of Jordan A. Hutcheson, Watt Tieder and Stephanie Rolfsness, Watt Tieder Ms. Hutcheson may be contacted at jhutcheson@watttieder.com Ms. Rolfsness may be contacted at srolfsness@watttieder.com Read the court decision
Read the full story...
Reprinted courtesy of

UCP Buys Citizen Homes

March 31, 2014 — Beverley BevenFlorez-CDJ STAFF
UCP, a home builder and land developer based in San Jose, California, has purchased “Charlotte-based Southeast regional home building venture Citizens Homes, whose chairman is well-known home building industry veteran Tony Mon, and whose president and chief operating officer is third-generation home builder Scott Thorson,” according to Big Builder. According to a UCP press statement, as quoted by Big Builder, “[t]he purchase price, estimated to be approximately $15 million, is based on the total assets of Citizens at the closing of the acquisition, less cash and cash equivalents, and less certain assumed trade payables. In addition, Citizens is eligible to receive earnout payments from UCP of up to $6 million in the aggregate based on performance over the next five years.” The acquisition is expected to close during the second quarter of 2014. Read the court decision
Read the full story...
Reprinted courtesy of

Leftover Equipment and Materials When a Contractor Is Abruptly Terminated

November 06, 2023 — Brian Perlberg - ConsensusDocs
Termination for cause is costly and adversarial and has been covered in this article. But can a terminating party use equipment and tools left behind on the worksite (i.e., a crane)? The answer depends on what is in your contract. Under ConsensusDocs, a constructor must give its permission to use any equipment or supplies left at the worksite, such as a crane.[i] Moreover, the owner must indemnify the constructor for using their equipment. This makes sense because even if a constructor were appropriately terminated for cause, using their equipment and materials they no longer possess or control unfairly creates additional liability exposure. At a minimum, the owner should take on the risk of using the equipment and materials since they benefit from such use. Read the court decision
Read the full story...
Reprinted courtesy of Brian Perlberg, ConsensusDocs Coalition
Mr. Perlberg may be contacted at bperlberg@ConsensusDocs.org

District of Oregon Predicts Oregon’s Place in “Plain Meaning” Pollution Camp

March 29, 2017 — William S. Bennett – Saxe Doernberger & Vita, P.C.
The Federal District Court for the District of Oregon recently decided that Carbon Monoxide constitutes a pollutant within the meaning of a pollution exclusion in a Commercial General Liability (“CGL”) policy. In Colony Ins. V. Victory Constr. LLC, No. 3: 16-cv-00457-HZ (Mar. 14, 2017), the District Court considered whether there was coverage for a pool company that allegedly failed to warn of the “risks of carbon monoxide poisoning associated with operating the heater in an insufficiently ventilated area,” leading to carbon monoxide sickness. Read the court decision
Read the full story...
Reprinted courtesy of William S. Bennett, Saxe Doernberger & Vita, P.C.
Mr. Bennett may be contacted at wsb@sdvlaw.com

Teaching An Old Dog New Tricks: The Spearin Doctrine and Design-Build Projects

October 30, 2018 — John Castro - Gordon & Rees Construction Law Blog
The United States District Court for the Southern District of California has now held that the Spearin doctrine applies to design-build subcontractors where the subcontractor is expected to design a portion of their work. The case is United States for the use and benefit of Bonita Pipeline, Inc., et al. v. Balfour Beatty Construction, LLC, et al. (“Bonita Pipeline”) (Case No. 3:16-cv-00983-H-AGS). In Bonita Pipeline, a subcontractor sued the general contractor and its sureties alleging breach of contract, breach of implied warranty, declaratory relief, and recovery under the Miller Act. The subcontractor then filed a motion for partial summary judgment against the general contractor on its declaratory relief cause of action, seeking a finding that the general contractor could not shift legal responsibility for its defective plans and specifications to the subcontractor. Read the court decision
Read the full story...
Reprinted courtesy of John Castro, Gordon & Rees Scully Mansukhani
Mr. Castro may be contacted at jcastro@grsm.com

The Need for Situational Awareness in Construction

January 27, 2020 — Aarni Heiskanen - AEC Business
Recent research backs up what we already know from practice: construction work is suboptimal. What happens on a construction site has not kept up with the demands of an increasingly complex work environment. Situational awareness could give on-site employees the necessary means to finally reap the productivity benefits of digitalization. Under the guidance of Professor Olli Seppänen, research teams at the Finnish Aalto University have delved into everyday conditions at a construction site. With the workers’ permission, they used video cameras, sensors, and surveys to locate the bottlenecks in productivity. The researchers also monitored the movement of products and materials on a construction site. The results are eye-opening. According to Aalto’s data, digitalization has not improved the productivity of construction foremen and workers. A typical worker still spends up to 70% of their time on activities that add no value: searching for information, unnecessary movement, and waiting. Construction materials are moved from place to place six times on the site before being consumed. In addition, especially on large construction sites, machinery often goes missing or is displaced. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES