Fairfield Connecticut Building Expert Directory

A Retrospective As-Built Schedule Analysis Can Be Used to Support Delay

May 23, 2022 — David Adelstein - Florida Construction Legal Updates
Delay claims are part of construction. There should be no surprise why. Time is money. A delay claim should be accompanied by expert opinions that bolster evidence that gets introduced. The party against whom the delay claim is made will also have an expert – a rebuttal expert. Not surprisingly, each of the experts will rely on a different critical path as to relates to the same project. The party claiming delay will rely on a critical path that shows the actions of the other party impacted their critical path and proximately caused the delay. This will be refuted by the opposing expert that will challenge the critical path and the actions claimed had no impact on the critical path (i.e., did not proximately cause the delay). Quintessential finger pointing! This was the situation in CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022), where the government terminated the contractor for convenience and the contractor claimed equitable adjustments for, among other things, delay. The contractor’s expert relied on an as-built critical path analysis by “retrospectively creating updates to insert between the contemporaneous updates.” Id., supra, n.3. The government’s expert did not do a retrospective as-built analysis and relied on only contemporaneous schedule updates. Id. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

I’m Sorry Ms. Jackson, I [Sovereign Immunity] am For Real

June 08, 2020 — Greggory Jacobs - Florida Construction Law News Blog
The Supreme Court of Florida issued its opinion in Florida Highway Patrol v. Jackson, 2020 Fla. LEXIS 108 (Fla. Jan 23, 2020), which answered the following certified question of great public importance: Does rule 9.130 [(A)(3)(C)(XI)] permit an appeal of a non-final order denying immunity if the record shows that the defendant is entitled to immunity as a matter of law but the trial court did not explicitly preclude it as a defense? The Court’s answer to this question was “no.” But this opinion stands for much more than just a negative answer to a certified question. Indeed, this opinion has significant implications upon procedural and substantive areas of construction law, which may affect agents of the state of Florida, including Construction Engineering and Inspection professionals and consultants (“CEI”). Procedurally, the Court recognizes that Fla. R. App. P. 9.130 insufficiently protects the public and governmental interests as “it leaves too great a risk that erroneous denials of operational sovereign immunity will go unreviewed until it is too late.” Id. at * 19. By extension of this risk, the Jackson Court announced that “courts should determine entitlement to sovereign immunity as early as the record permits.” Id. at * 18. In fact, on that basis, courts can address a motion for summary judgment asserting entitlement to sovereign immunity even if there are outstanding disputes as to, say, the existence of a duty of care. Id. at 17-18. Accordingly, and in an effort to remedy the risk of erroneous denials going unreviewed until it is too late, the Court amended Fla. R. App. P. 9.130 to expand appellate review of nonfinal orders denying sovereign immunity. Jackson, 2020 Fla. LEXIS 108 at * 19; In re Amendments to Fla. Rule of Appellate Procedure 9.130, No. SC19-1734 (Fla. Jan. 23, 2020). The new form of Fla. R. App. P. 9.130 cements the policy mentioned above because it allows an appeal of a nonfinal order denying a motion for summary judgment due to entitlement to sovereign immunity. Meanwhile, under the old rule, the order was only appealable if the trial court order determined – as a matter of law – that a party was not entitled to sovereign immunity. As such, the new rule focuses on what was argued in the motion as opposed to what was written in the order. Read the court decision
Read the full story...
Reprinted courtesy of Greggory Jacobs, Cole, Scott & Kissane, P.A.
Mr. Jacobs may be contacted at greggory.jacobs@csklegal.com

More Broad-Based Expansion for Construction Industry Expected in 2015

January 07, 2015 — Garret Murai - California Construction Law Blog
It’s a short week for most of us this week. Christmas is over and New Year’s is approaching. So, what will 2015 bring us? According Dodge Data & Analytics’s 2015 Dodge Construction Outlook: Continuing expansion of the construction sector, but one that is more broad-based than in recent years. “The economic environment going forward carries several positives that will help to further lift total construction starts,” said Robert Murray, Chief Economist and Vice President at Dodge Data & Analytics. “Financing for construction projects is becoming more available, reflecting some easing of bank lending standards, a greater focus on real estate development by the investment community, and more construction bond measures getting passed. While federal funding for construction programs is still constrained, states are now picking up some of the slack. Interest rates for the near term should stay low, and market fundamentals (occupancies and rents) for commercial building and multifamily housing continue to strengthen.” Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Wildfire Is Efficient Proximate Cause of Moisture Reaching Expansive Soils Under Residence

November 05, 2014 — Tred R. Eyerly - Insurance Law Hawaii
The court considered whether a wildfire (covered risk) or moisture in the soils (excluded risk) was the cause of damage to the insureds' home. Encompass Ins. Co. v. Berger, 2014 U.S. Dist. LEXIS 142870 (C.D. Cal. Oct. 7, 2014). In May 2009, the Jesusita Fire caused damage to the insureds' home and surrounding area. The west wall of the house was burned, causing damage to a bedroom. A shed, hot tub, wooden decks and some vegetation, including eucalyptus trees, were damaged. The insureds submitted a claim to Encompass. Eventually, Encompass spent $400,000 repairing the property. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Ambitious Building Plans in Boston

November 18, 2011 — CDJ STAFF

Although most are unlikely to change the Boston skyline, there are several large projects on the drawing boards. The site BostInnovation covered ten of them in a recent post. Downtown Boston will be the site of several of these large projects, including three towers to be added to the Christian Science Plaza, a 404-unit residential tower in the Theater District, and perhaps the largest of these projects, a 47-story tower to be built over Copley Plaza, which will tower over the adjacent buildings. None of the planned buildings will challenge the Hancock Tower’s 60 stories.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

Construction Termination Issues Part 6: This is the End (Tips for The Design Professional)

September 25, 2023 — Melissa Dewey Brumback - Construction Law in North Carolina
Whether your role is in helping analyze the contractor’s work on the project to certify a contractor’s termination for cause, or you are being shown the door yourself, and everything in between, termination is a subject that is ripe with potential problems. Consider these summary tips as part of your practice, every time the termination idea arises:

Remember that you are the neutral and must be impartial between Owner and Contractor
After you have made a fair decision, document your decision to the Owner and Contractor
Provide options less nuclear for Owners– stop work; removing scopes of work; etc.

Read the court decision
Read the full story...
Reprinted courtesy of Melissa Dewey Brumback, Ragsdale Liggett
Ms. Brumback may be contacted at mbrumback@rl-law.com

Court Orders City to Pay for Sewer Backups

March 31, 2014 — Beverley BevenFlorez-CDJ STAFF
According to The Courier-Journal, in August of 2009 “raw sewage” backed “up into several houses during a torrential downpour” in Jeffersonville, Indiana. Now, a “Clark County judge has ordered the city of Jeffersonville to pay nearly $100,000 plus 8 percent annual interest for the city's negligence that led to” the incident. The problems allegedly began after a new lift station and force main, which “previously flowed southward to the Ohio River,” was “re-routed it to Springdale.” The city was eventually “cited by the Indiana Department of Environmental Management for failing to obtain a required local permit for the Springdale upgrade.” The Courier-Journal reported that Jeffersonville “agreed to take several steps to remedy the problem for residents and satisfy the state, which ultimately considered the issue resolved in October 2012.” Since the upgrade was completed, there have not been any further sewer backups, according to the city’s utility director, Len Ashack, as quoted by The Courier-Journal. Read the court decision
Read the full story...
Reprinted courtesy of

Even Where Fraud and Contract Mix, Be Careful With Timing

April 12, 2021 — Christopher G. Hill - Construction Law Musings
I have often discussed the limited circumstances under which a construction contract claim and a fraud claim can coexist. A recent case from the Western District of Virginia federal court demonstrates that care is necessary even in those limited circumstances. In Fluor Fed. Sols., LLC v. Bae Sys. Ordinance Sys., the Court examined the question of a fraud statute of limitations under Virginia law. The basic facts found in the Complaint are these: In 2011, the United States Army awarded BAE Systems Ordinance Systems Inc. a basic ordering agreement under which BAE was responsible for modernization projects at the Radford Army Ammunition Plant. This action stems from a subcontract between Fluor Federal Solutions LLC and BAE, under which Fluor agreed to design and construct a new natural gas boiler at the plant. Fluor has completed work on the project, and BAE has accepted that work. Nonetheless, Fluor claims that BAE has refused or failed to pay for the balance of the project costs. Fluor alleges that BAE received several changes to its prime contract from the Army but did not pass those changes along to Fluor until after BAE solicited a bid from Fluor and entered a contract with Fluor to build a temporary facility. Instead, BAE continued to misrepresent the scope of the project. Fluor alleges that the change in plans increased costs substantially, but that BAE withheld information about those changes so that it could solicit lower bids. Fluor alleges that it requested a copy of BAE’s prime contract on numerous occasions, but BAE failed to provide a copy of it. Instead, Fluor submitted a request under the Freedom of Information Act. It received a copy of BAE’s prime contract on Oct. 3, 2018. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES