Fairfield Connecticut Building Expert Directory

Force Majeure Under the Coronavirus (COVID-19) Pandemic

March 08, 2021 — Lindsay T. Watkins - Ahlers Cressman & Sleight PLLC
As COVID-19 disrupts work and life as we know it, the question many contractors have is what protections are available against the inevitable project impacts and delays? Generally, construction contracts require a contractor to timely perform work until project completion or potentially face damages (liquidated or actual) and possible termination. When events occur, however, that are beyond our control (such as a national pandemic), it is important to review and understand what contract provisions or avenues are available for potential relief. 1. Review Your Contract For A Force Majeure Provision. A “force majeure” contract provision is commonly included in construction contracts, service agreements, purchase orders, etc. It typically covers events or conditions that can be neither anticipated nor controlled. These provisions, however, will vary greatly from contract to contract and may not include the language “force majeure” but rather may be included in general delay or impact clauses. For example, some common provisions include:

Washington State Department of Transportation Clause (2018 Standard Specifications for Road, Bridge and Municipal Construction): The Contractor shall rebuild, repair, restore, and make good all damages to any portion of the permanent or temporary Work occurring before the Physical Completion Date and shall bear all the expense to do so, except damage to the permanent Work caused by: (a) acts of God, such as earthquake, floods, or other cataclysmic phenomenon of nature, or (b) acts of the public enemy or of governmental authorities; or (c) slides in cases where Section 2-03.3(11) is applicable; Provided, however, that these exceptions shall not apply should damages result from the Contractor’s failure to take reasonable precautions or to exercise sound engineering and construction practices in conducting the Work.

Read the court decision
Read the full story...
Reprinted courtesy of Lindsay T. Watkins, Ahlers Cressman & Sleight PLLC
Ms. Watkins may be contacted at Lindsay.Watkins@acslawyers.com

Don’t Believe Everything You Hear: Liability of Asbestos Pipe Manufacturer Upheld Despite Exculpatory Testimony of Plaintiff

May 24, 2021 — Garret Murai - California Construction Law Blog
In the next case, Morgan v. J-M Manufacturing Company, Inc. 60 Cal.App.5th 1078 (2021), the 2nd District Court of Appeal upheld a $7 million personal injury verdict against an asbestos-cement pipe manufacturer despite exculpatory testimony from the plaintiff, holding that the testimony was an issue of witness credibility rather than sufficiency of the evidence, and holding that the trial court’s denial of a jury instruction requested by the pipe manufacturer was appropriate because, while the requested jury instruction was a recitation of undisputed facts, the purpose of jury instructions is to recite the law rather than facts, even undisputed ones. The Morgan Case Norris Morgan was exposed to asbestos at construction sites where he worked in the 1970s and 80s. After he was diagnosed with mesothelioma in December 2017, Morgan and his wife sued a number of defendants, including J-M Manufacturing for personal injuries and loss of consortium. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

CGL Coverage for Liquidated Damages and the Contractual Liability Exclusion

October 09, 2023 — Stu Richeson - The Dispute Resolver
Liquidated delay damages are common in construction contracts and are generally imposed when a contractor fails to achieve substantial completion within the time required by the contract. While contracts like the AIA A201-2017 have provisions for extending the time to achieve substantial completion when delays are caused by circumstances beyond the contractor’s control, delays can result from factors other than improper management or planning and the like, for which the owner is not required to give the contractor additional time. Courts are split on whether there is ever coverage under a CGL policy for contractually agreed upon liquidated delay damages. Liquidated delay damages are often excluded under the contractual liability exclusion of most CGL policies. The contractual liability exclusion excludes coverage for “liability for which the Insured is obligated to pay damages by reason of the assumption of liability in a contract or agreement.” Courts often find the contractual liability exclusion in a CGL policy precludes coverage for liquidated delay damages, because such damages are contractual in nature and are triggered by the failure to bring the contract to substantial completion by a fixed deadline, regardless of the cause of the delay. However, some courts will look to the cause of the delay and find that there is coverage under a CGL policy for liquidated delay damages that are the result of property damage caused by an accident or occurrence. In Clark Const. Grp., Inc. v. Eagle Amalgamated Serv., Inc., 01-2478-DV, 2005 WL 2092998, at *1 (W.D. Tenn. Aug. 24, 2005) a general contractor entered a contract for the renovation of the convention center in Memphis. Part of the project included the demolition of a structure attached to the convention center. The demolition work was improperly performed by a subcontractor and resulted in damage to the convention center. Read the court decision
Read the full story...
Reprinted courtesy of Stu Richeson, Phelps
Mr. Richeson may be contacted at stuart.richeson@phelps.com

A Murder in Honduras Reveals the Dark Side of Clean Energy

October 12, 2020 — Monte Reel - Bloomberg
Berta Cáceres campaigned to stop a renewable energy project, and the long fight turned her into one of Central America’s most prominent environmentalists. She won a prestigious international prize known as the “Green Nobel” for protecting a river, using some of the award money to purchase a modest bungalow in La Esperanza, her hometown in central Honduras. Her activism is also what brought three gunmen to her back door. The men broke into her kitchen around 11:30 p.m. on March 2, 2016. Cáceres heard a noise and called out from her bedroom: “Who’s out there?” Within seconds, a gunman entered her room and shot her dead. Read the court decision
Read the full story...
Reprinted courtesy of Monte Reel, Bloomberg

California Posts Nation’s Largest Gain in Construction Jobs

March 28, 2012 — CDJ STAFF

California added about 8,900 construction jobs in January, 2012, as compared to December, 2011, leading the nation in the number of added construction jobs. Thirty-four other states also saw added construction jobs. A year prior, only twenty-eight states added construction jobs. The Associated General Contractors of America analyzed the monthly report from the Labor Department. Ken Simonson, the chief economist for the Associated General Contractors of America noted that “the gains this January partly reflect very mild weather this winter and exceptionally cold and snowy conditions a year before.”

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

Identifying and Accessing Coverage in Complex Construction Claims

September 29, 2021 — Jeffrey J. Vita & Michael V. Pepe - Saxe Doernberger & Vita, P.C.
I. Introduction First-party, third-party, builder’s risk, professional liability, commercial general liability, wrap-ups, and additional insured status are all potential sources of insurance coverage for a large construction loss. Therefore, it is critical for construction industry participants, from owners and developers to general contractors and their subcontractors, to have a functional knowledge of the different types of insurance coverage available to them and how those coverages intersect to respond to a loss. This paper presents a brief overview of the various types of coverage available to contractors, construction managers, and owners in a large construction loss and the risks each coverage is designed to insure. In general, there are two forms of coverage: (1) First-party liability coverage, which protects an insured’s own losses on a project during construction; and (2) Third-party liability coverage, which insures the project participants for losses that become the subject of claims or suits brought against the project participants by third parties. When a loss occurs, such as property damage, both types of coverage can be implicated. For example, if a fire burns down a building under construction, the contractor likely would incur first-party losses such as cleanup costs. The contractor may also have third-party exposure if the owner alleges that the contractor was responsible for the fire. On the other hand, when a bodily injury occurs, all losses to the contractor will be third-party losses. A broad overview of each of these policies is provided below. Reprinted courtesy of Jeffrey J. Vita, Saxe Doernberger & Vita and Michael V. Pepe, Saxe Doernberger & Vita Mr. Vita may be contacted at JVita@sdvlaw.com Mr. Pepe may be contacted at MPepe@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Texas Supreme Court to Rehear Menchaca Bad Faith Case

January 10, 2018 — Sean P. Mahoney – Complex Insurance Coverage Reporter
On December 15th, the Texas Supreme Court agreed to revisit its April 7, 2017 decision in USAA Texas Lloyds Co. v. Menchaca, No. 14-0721, a “bad faith” case arising out of Hurricane Ike damage, in which the court held that a policyholder could potentially recover policy benefits for statutory bad faith under Texas law, even though a jury concluded that the insurer did not breach the terms of the policy, if the policyholder could show that she was nevertheless entitled to the benefit. The decision to rehear this matter comes at the urging of insurers and interested groups, including the Insurance Council of Texas and the U.S. Chamber of Commerce, who argued that the April 7, 2017 ruling substantially unsettled Texas insurance law. Menchaca is a first-party property insurance coverage case. After Hurricane Ike struck in 2008, plaintiff Menchaca submitted a claim under her homeowners policy to USAA. A USAA adjuster later concluded that Menchaca’s property suffered only “minimal damage” that fell below the deductible. Menchaca sued claiming breach of contract and unfair claims settlement practices in violation of the Texas Insurance Code. As damages, she sought only the policy benefit, court costs, and attorneys’ fees. Read the court decision
Read the full story...
Reprinted courtesy of Sean P. Mahoney, White and Williams LLP
Mr. Mahoney may be contacted at mahoneys@whiteandwilliams.com

CSLB Begins Processing Applications for New B-2 License

June 21, 2021 — Garret Murai - California Construction Law Blog
As we wrote about in our 2021 Construction Law Update, one of the new laws to take effect on January 1, 2021 was the enactment of SB 1189 which created a new B-2 Residential Remodeling Contractor’s license. The new license is available to contractors working on existing homes with residential wood frame structures requiring at least three (3) unrelated trades or crafts under a single contract. Beginning June 1, 2021, the Contractors State License Board began accepting applications for the B-2 Residential Remodeling Contractor’s license. According to a press release from the CSLB:

The B-2 classification provides a pathway to licensure for many unlicensed people who are currently working on remodeling and small home improvement projects that don’t qualify for a B-General Building License because the contracted work does not include framing or rough carpentry. Consumers employing a licensed contractor have reduced liability and greater consumer protection. Licensees benefit from licensure as they have opportunities to lawfully advertise, and compete on a level playing field for jobs.

Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES