Cambridge Massachusetts Building Expert Directory

Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season

January 13, 2020 — David Adelstein - Florida Construction Legal Updates
There are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be. For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:

[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season. Meridian Engineering, 2019 WL at *7 (internal citations omitted)

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

California’s High Speed Rail Project. Are We Done With the Drama?

October 22, 2014 — Garret Murai – California Construction Law Blog
Proponents of California’s high-speed rail project cleared a major hurdle this past week when the California Supreme Court declined to review a California Court of Appeals ruling which held that the state’s funding plan did not violate Proposition 1A, the voter-approved initiative passed in 2008, which provided initial funding for the project. For those like me who have been following the fits and starts of California’s high-speed rail project, it may be hard to remember how it all got started, and how we got to where we are. California's High-Speed Rail Project California’s high-speed rail project involves the construction of a high-speed passenger rail system running from Northern California to Southern California. The $68 billion system, expected to begin operation in 2029, will initially run from San Francisco to the Los Angeles basin in under 3 hours with train speeds capable of over 200 miles per hour. The system will eventually extend from Sacramento to San Diego covering a distance of approximately 800 miles with up to 24 stations. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Kronick Moskovitz Tiedemann & Girard
Mr. Murai may be contacted at gmurai@kmtg.com

SAFETY Act Part II: Levels of Protection

June 21, 2024 — Lorelie S. Masters, Kevin W. Jones & Charlotte Leszinske - Hunton Insurance Recovery Blog
Part I of this series, SAFETY Act is Powerful Protection Against Emerging Liabilities, addressed the benefits of obtaining SAFETY Act coverage, including:

From a reputational perspective, SAFETY Act protection provides benefits even absent a security incident: it demonstrates that a knowledgeable federal agency has examined the relevant technology and determined that it is both safe and effective.
SAFETY Act protection can benefit companies taking steps to enhance the security of their physical premises and operations, or their cybersecurity defenses, to reduce their potential liability and enhance their reputation.
Other benefits include—depending on the level of protection—powerful liability protections including exclusive federal jurisdiction and choice of law for the venue where the incident occurred, caps on liability, prohibitions on punitive damages, and government contractor immunity.

This post will explain the levels of protection that a company can seek under the SAFETY Act. Reprinted courtesy of Lorelie S. Masters, Hunton Andrews Kurth, Kevin W. Jones, Hunton Andrews Kurth and Charlotte Leszinske, Hunton Andrews Kurth Ms. Masters may be contacted at lmasters@HuntonAK.com Mr. Jones may be contacted at kjones@HuntonAK.com Ms. Leszinske may be contacted at cleszinske@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Scaffolding Purchase Suggests No New Building for Board of Equalization

July 30, 2014 — Beverley BevenFlorez-CDJ STAFF
Employees at California’s Board of Equalization spoke out against the Brown administration after the state purchased new scaffolding for the defect-riddled building, rather than finding a new facility, reported the Sacramento Bee. The existing scaffolding was leased for $10,000 per month, but the lease expired, prompting the purchase of new scaffolding for about $100,000. The board’s Chairman Jerome Horton stated “that while the change may make financial sense in the short term, it sends a signal that the Department of General Services intends to keep Equalization’s 2,200 or so employees in the troubled building,” according to the Sacramento Bee. Building problems include “toxic mold, defective elevators, leaking windows, corroded wastewater pipes, floods, and exterior glass panels that spontaneously break or pop off.” So far, $2.3 million has been paid “in connection with building-related employee injury claims” along with $60 million in repairs. However, an additional $115 million is estimated to completely fix the defects. Read the court decision
Read the full story...
Reprinted courtesy of

Following California Law, Federal Court Adopts Horizontal Allocation For Asbestos Coverage

May 19, 2014 — Tred R. Eyerly – Insurance Law Hawaii
Following California law, the federal district court adopted horizontal allocation to settle a dispute among carriers for an insured sued for selling asbestos products. New England Fire Ins. Corp. v. Ferguson Enterprises, Inc., Civil No. 3:12cv948 (D. Conn. April 8, 2014) [ruling here] The insured was a California-based corporation that sold plumbing supply products that contained asbestos. The insured was named in numerous asbestos-related lawsuits that were filed largely in California. The insured had primary and excess coverage for bodily injury claims. New England Fire Insurance issued an excess policy to the insured. The policy provided the insurer would be liable for the ultimate new loss in excess of the insureds underlying limit, which was defined as the amount equal to the limits of the underlying insurance, plus the applicable limits of any other underlying insurance collectible by the insured. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Which Cities have the Most Affordable Homes?

October 08, 2014 — Beverley BevenFlorez-CDJ STAFF
Builder analyzed U.S. cities with populations of half a million or more and then filtered further with cities that have a “median new home closing price under $250,000, a first mortgage rate below 4 percent for new homes, and a median new home price per square foot below $125.” Topping the list was El Paso, Texas with the lowest median price ($168,600). Fifth on the list was San Antonio-New Braunfels, Texas with a median price of $230,400. Read the court decision
Read the full story...
Reprinted courtesy of

4 Ways to Mitigate Construction Disputes

March 20, 2023 — Bill Shaughnessy - ConsensusDocs
Resolving construction disputes in litigation (court or arbitration) can be expensive and may drag on for years. Most disputes could have been avoided, or at least mitigated, had the parties (both owners and contractors) identified contract risks during negotiations and been more proactive in communicating the risks during execution of the work. This article highlights four practical risk management approaches that help all parties focus on their mutual interest in close coordination and clear communication at the beginning of the project as well as throughout performance:

Identifying and allocating risks;
Accurate scheduling;
Clear project documentation and communication; and
Real-time dispute resolution.

The intent of these techniques is not to shift legal obligations or risks. Rather, the intent is to keep project personnel and project management for all the participants focused on communicating and working together, including responsibly confronting real problems to avoid or mitigate their impact. Allocating risks, scheduling, project documentation and communication, and real-time dispute resolution are independently relevant on a bilateral basis between the owner, designer, and the various contractors. These approaches and their diligent execution by the parties during construction contribute far more to a successful project than anything lawyers and claims consultants can contribute in after-the-fact legal proceedings. Read the court decision
Read the full story...
Reprinted courtesy of Bill Shaughnessy, Jones Walker LLP (ConsensusDocs)
Mr. Shaughnessy may be contacted at bshaughnessy@joneswalker.com

U.S. District Court of Colorado Interprets Insurance Policy’s Faulty Workmanship Exclusion and Exception for Ensuing Damage

August 15, 2022 — Carin Ramirez - Colorado Construction Litigation
Recently, the United States District Court for the District of Colorado interpreted a faulty workmanship exclusion in a property insurance policy in The Lodge at Mountain Village Owner Association v. Eighteen Certain Underwriters of Lloyd’s of London, 22 U.S Dist. Ct LEXIS 48883*, decided on March 18, 2022. The Court held that the faulty workmanship exclusion at issue extended to preclude coverage for later ensuing damage that arose from the faulty workmanship, even though the damage was weather related, because faulty workmanship was the primary cause of the ensuing damage. The claims in The Lodge at Mountain Village arose from maintenance work performed on log siding at three multi-unit condominium buildings in Telluride. The maintenance work to the log siding included staining, finishing, and chinking repairs to joints between the logs. About a year after completion of the work, The Lodge at Mountain Village Owners Association (“The Lodge”) notified the maintenance contractor that logs were extremely weathered and that its work was defective. The Lodge retained an expert who prepared a report stating that the log finish and underlying wood was deteriorating because of the contractor’s work and that some areas were not properly protected from exposure to snow, rain, and brine from ice-melting salt. The Lodge pursued and settled its claims against the contractor. Read the court decision
Read the full story...
Reprinted courtesy of Carin Ramirez, Higgins, Hopkins, McLain & Roswell, LLC
Ms. Ramirez may be contacted at ramirez@hhmrlaw.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES