Fairfield Connecticut Building Expert Directory

Reasonableness of Liquidated Damages Determined at Time of Contract (or, You Can’t Look Back Again)

October 05, 2020 — Christopher G. Hill - Construction Law Musings
I’ve discussed the continuing litigation between White Oak Power Constructors v. Mitsubishi Hitachi Power Systems Americas, Inc. previously here at Construction Law Musings because the case was another reminder that your construction contract terms matter and will be interpreted strictly here in the Commonwealth of Virginia. The prior opinion in this case from the Eastern District of Virginia court the Court considered the applicability of a liquidated damages provision. In the latest opinion from the Court (PDF) the Court looked at when and how any liquidated damages would be calculated. In its June 22, 2020 opinion, the Court put the issue as follows:

White Oak’s motion for partial summary judgment presents a narrow issue: whether courts may consider the damages actually sustained by a party as a result of a contract breach when deciding if liquidated damages required by a contract “grossly exceed” a party’s actual damages.

Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Trump Soho May Abandon Condos to Operate Mainly as Hotel

January 28, 2015 — Nadja Brandt – Bloomberg
Lower Manhattan’s Trump Soho, the five-year-old tower that was seized in a foreclosure amid slow sales of its condominiums, may drop its focus on part-time residences and operate most of the property solely as a hotel. The building’s new owner, Los Angeles-based CIM Group, is “stepping away” from marketing the roughly two-thirds of condos that remain unsold, said Gary Schweikert, the building’s managing director. The company is considering converting the unsold units at the tower permanently into hotel rooms, he said. Read the court decision
Read the full story...
Reprinted courtesy of Nadja Brandt, Bloomberg
Ms. Brandt may be contacted at nbrandt@bloomberg.net

The Black Woman Architect Who Hopes to Change the Face of Design in America

January 16, 2024 — Kriston Capps - Bloomberg
In the US, only 2% of licensed architects are Black. Less than a single percent are Black women. Architects tend to be older, White and men, as reflected by the leadership of both firms and professional groups. So when the American Institute of Architects inaugurated its 100th president, Kimberly Dowdell — the first Black woman to lead the association, and at 40 the youngest architect to ever hold the post — it suggested an optimistic change of course. A principal and director of strategic relationships for the global design firm HOK, Dowdell comes to her new position from a leadership background. She has served as the president of the National Organization of Minority Architects and sits on the board of the Chicago Central Area Committee and Chicago Architecture Biennial, among other groups. She is the winner of both the AIA’s Young Architects Award and the Women in Architecture award from Architectural Record. Dowdell spoke to Bloomberg CityLab about her goals as AIA president, the challenges facing the field and why every city should hire its own chief architect. Read the court decision
Read the full story...
Reprinted courtesy of Kriston Capps, Bloomberg

Congratulations to Partner Nicole Whyte on Being Chosen to Receive The 2024 ADL’s Marcus Kaufman Jurisprudence Award

May 28, 2024 — Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara, LLP is proud to announce Founder/CEO Nicole Whyte has been chosen by the Orange County/Long Beach region of the Anti-Defamation League (“ADL”) to receive the 2024 ADL’s Marcus Kaufman Jurisprudence Award. The ADL annual Jurisprudence Dinner, at which Nicole will be honored along with the Hon. Kirk Nakamura (retired) and Michael Ermer, will be held on Thursday, September 19, 2024, at the Turnip Rose Promenade in Costa Mesa. Congratulations to Nicole for her lifetime of service not only to Bremer Whyte Brown & O’Meara, LLP but also to the larger community. Immediate past recipients include Brian Farrell, the Hon. Glenda Sanders (retired), and Eric Trout. Read the court decision
Read the full story...
Reprinted courtesy of Bremer Whyte Brown & O'Meara LLP

First Lumber, Now Drywall as Canada-U.S. Trade Tensions Escalate

November 30, 2016 — Katia Dmitrieva – Bloomberg
A new trade dispute has broken out between Canada and the U.S. that threatens to raise prices in Canada’s already overheated housing markets. The Canada Border Services Agency imposed a provisional tariff as high as 277 percent on U.S. drywall imports in September after ruling that manufacturers were dumping the product, or selling it below the price in their home market, undercutting local suppliers. The tariff has raised the price of drywall, or gypsum board as it’s also called, by as much as 30 percent and is causing “chaos” and delays as contractors scramble for alternative sources. Some builders say the tariff could add as much as C$13,000 ($9,671) to the cost of a new home, which would amount to a C$2.6 billion increase to the roughly 200,000 homes built in Canada each year. Read the court decision
Read the full story...
Reprinted courtesy of Katie Dmitrieva, Bloomberg
Ms. Dmitrieva may be followed on Twitter @katiadmi

Seeking the Urban Lifestyle in the Suburbs

March 05, 2015 — Beverley BevenFlorez-CDJ STAFF
As the ‘burbs become more urbanized, the definition of city is changing. Builder Magazine reported that while builders have responded to buyers who wanted an urban lifestyle, “what nearly all of them have learned in the process is that ‘city’ doesn’t mean what it used to. Neither does ‘suburb.’ In fact, nearly every builder that added a post-recession ‘urban’ division has found that home buyers in search of an urban lifestyle aren’t married to living downtown. For many, it seems it’s not ‘the city’ they want at all—it’s the lifestyle.” Leigh Gallagher, assistant managing editor of Fortune and author of The End of the Suburbs: Where the American Dream is Moving, told Builder, “People don’t necessarily want to live in Manhattan. They want a little bit of Manhattan sprinkled right near them.” Read the court decision
Read the full story...
Reprinted courtesy of

Melissa Dewey Brumback Invited Into Claims & Litigation Management Alliance Membership

October 14, 2013 — CDJ STAFF
Melissa Dewey Brumback has been invited to join the Claims & Litigation Management Alliance, an “invitation only” organization of insurance companies, litigation and risk managers, claims professionals, and attorneys. Ms. Brumback, an attorney at Ragsdale Ligget PPLC, has a practice that focuses on construction law and business disputes. Her clients include architects and engineers in construction-related claims. Ms. Brumbuck is respected as an author and lecturer on construction law. The Claims & Litigation Management Alliance comprises the leaders of claims and litigation management. Members are risk and litigation managers, insurance and claims professionals, and corporate and outside counsel. Read the court decision
Read the full story...
Reprinted courtesy of

Partner Yvette Davis Elected to ALFA International’s Board of Directors

November 15, 2021 — Yvette Davis - Haight Brown & Bonesteel LLP
Congratulations to Haight Partner Yvette Davis who was elected by her peers to serve a three-year term on ALFA International’s 15 Member Board of Directors. The announcement was made during ALFA International’s Annual Business Meeting which took place in San Diego, California on October 20-22, 2021. About ALFA International ALFA International is the premier network of independent law firms. Founded in 1980, ALFA International was the first and continues to be one of the largest and strongest legal networks. We have 150 member firms throughout the world. Our 80 U.S. firms maintain offices in 95 of the 100 largest metropolitan areas. Our 70 international firms are located throughout Europe, Asia, Australia/New Zealand, Africa, Canada, Mexico and South America. Read the court decision
Read the full story...
Reprinted courtesy of Yvette Davis, Haight Brown & Bonesteel LLP
Ms. Davis may be contacted at ydavis@hbblaw.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES