Seattle Washington Building Expert Directory

Force Majeure Under the Coronavirus (COVID-19) Pandemic

March 08, 2021 — Lindsay T. Watkins - Ahlers Cressman & Sleight PLLC
As COVID-19 disrupts work and life as we know it, the question many contractors have is what protections are available against the inevitable project impacts and delays? Generally, construction contracts require a contractor to timely perform work until project completion or potentially face damages (liquidated or actual) and possible termination. When events occur, however, that are beyond our control (such as a national pandemic), it is important to review and understand what contract provisions or avenues are available for potential relief. 1. Review Your Contract For A Force Majeure Provision. A “force majeure” contract provision is commonly included in construction contracts, service agreements, purchase orders, etc. It typically covers events or conditions that can be neither anticipated nor controlled. These provisions, however, will vary greatly from contract to contract and may not include the language “force majeure” but rather may be included in general delay or impact clauses. For example, some common provisions include:

Washington State Department of Transportation Clause (2018 Standard Specifications for Road, Bridge and Municipal Construction): The Contractor shall rebuild, repair, restore, and make good all damages to any portion of the permanent or temporary Work occurring before the Physical Completion Date and shall bear all the expense to do so, except damage to the permanent Work caused by: (a) acts of God, such as earthquake, floods, or other cataclysmic phenomenon of nature, or (b) acts of the public enemy or of governmental authorities; or (c) slides in cases where Section 2-03.3(11) is applicable; Provided, however, that these exceptions shall not apply should damages result from the Contractor’s failure to take reasonable precautions or to exercise sound engineering and construction practices in conducting the Work.

Read the court decision
Read the full story...
Reprinted courtesy of Lindsay T. Watkins, Ahlers Cressman & Sleight PLLC
Ms. Watkins may be contacted at Lindsay.Watkins@acslawyers.com

Contractors: Consult Your Insurance Broker Regarding Your CGL Policy

February 15, 2018 — David Adelstein – Florida Construction Legal Updates

Contractors: do yourself a favor and consult your insurance broker regarding your commercial general liability (CGL) policy. Do this now, especially if you subcontract out work.

CGL policies contain a “your work” exclusion. The CGL policy is written such that it excludes “‘property damage’ to ‘your work’ arising out of it or any part of it and included in the ‘products-completed operations hazard.’” This exclusion will be raised in the post-completion latent construction defect scenario. (There are other exclusions that will be raised to a defect discovered during construction.) Certain policies will contain a subcontractor exception to this “your work” exclusion. You WANT this exception- no doubt about it so that this exclusion does not apply to work performed by your subcontractors. Without this subcontractor exception, truth be told, this “your work” exclusion is a total back-breaker to contractors. It will give your insurer an immediate out for many latent defect property scenarios since excluded from coverage is property damage to your work including work performed by your subcontractors.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

Construction is the Fastest Growing Industry in California

May 20, 2015 — Garret Murai – California Construction Law Blog
We wrote earlier about why construction workers are the happiest employees on Earth, and pointed to one possible factor: That construction, which was one of the hardest hit industries during the 2008 real estate collapse, has since bounced back. This past month, the California Employment Development Department (“EDD”) released data putting some numbers to that hypothesis. And the result: According to the EDD, over the past 12 months, construction was the fastest growing industry in California, adding more than 46,000 jobs within the last year, an increase of 6.9% from 667,000 workers in March 2014 to 713,000 workers in March 2015. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Car Crashes Through Restaurant Window. Result: Lesson in the History of Additional Insured Coverage

December 29, 2020 — Randy J. Maniloff - White and Williams LLP
Back in the day, additional insureds were oftentimes afforded coverage for liability “arising out of” the named insured’s work for the additional insured. When confronted with such language, courts often concluded that it dictated “but for” causation. In other words, but for the named insured doing the work for the additional insured, the additional insured would not be in the liability-facing situation that it is in. The result in some cases: additional insureds were entitled to coverage for their sole negligence. Decisions reaching such a conclusion were generally not well-received by insurers. This was especially so when you consider that the premium received by insurers, for the AI coverage, may not have been enough to buy a package of Twizzlers. Insurer frustration with such decisions -- which insurers did not believe expressed the intent of additional insured coverage -- led ISO to make revisions to additional insured forms in 2004 (later revisions followed). At the heart of these revisions was an attempt to require fault on the part of the named insured before coverage could be afforded to the additional insured. (This is a very brief and simple history of this complex issue.) Read the court decision
Read the full story...
Reprinted courtesy of Randy J. Maniloff, White and Williams LLP
Mr. Maniloff may be contacted at maniloffr@whiteandwilliams.com

Chicago Makes First Major Update to City's Building Code in 70 Years

August 06, 2019 — Engineering News-Record
The City Council recently voted to adopt a major update to the Chicago Building Code, its first in 70 years, that will better align it with the International Code Council’s International Building Code. Mayor Rahm Emanuel (D) said the new code will spur and enhance building projects by adding more flexibility and options for construction materials. Engineering News-Record Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Congratulations 2019 DE, NJ and PA Super Lawyers and Rising Stars

May 26, 2019 — White and Williams LLP

Fifteen White and Williams lawyers have been named by Super Lawyers as a Delaware, New Jersey or Pennsylvania "Super Lawyer" while eight received "Rising Star" designations. Each lawyer who received the distinction competed in a rigorous selection process which took into consideration peer recognition and professional achievement. The lawyers named to this year's Super Lawyer list represent a multitude of practices throughout the firm.

Super Lawyers 2019
Attorney	Practice Area
John Balaguer	PI Defense: Med Mal
Kevin Cottone	PI Defense: Med Mal
Thomas Goutman	Class Action
David Haase	Business Litigation
Christopher Leise	Civil Litigation: Defense
Randy Maniloff	Insurance Coverage
David Marion	Business Litigation
Peter Mooney	Business Litigation
Michael Olsan	Insurance Coverage
John Orlando	General Litigation
Wesley Payne	Insurance Coverage
Daryn Rush	Insurance Coverage
Anthony Salvino	Workers’ Comp
Patricia Santelle	Insurance Coverage
Andrew Susko	Civil Litigation: Defense

Read the court decision
Read the full story...
Reprinted courtesy of White and Williams LLP

Viewpoint: A New Approach to Job Site Safety Reaps Benefits

June 30, 2016 — Jimmy Morgan & Eric Pfeiffer – Engineering News-Record
Every organization that participates in the construction and manufacturing industries understands that safety is critical to success and strives to end each day injury-free and incident-free. Read the court decision
Read the full story...
Reprinted courtesy of Jimmy Morgan & Eric Pfeiffer, Engineering News-Record
Comments or questions regarding this story may be submitted to ENR.com@bnpmedia.com

Supply Chain Delay Recommendations

August 07, 2022 — Denise Motta - Gordon & Rees Construction Law Blog
This Bulletin provides guidance to contractors, subcontractors, suppliers, and others to ensure compliance with contractual change order requirements in the event work on a construction project is impacted by supply chain delays. Contract Protection Tips: The construction industry is being impacted substantially by inability to obtain necessary construction products due to supply chain issues. Most construction contracts do not accommodate time extensions due to supply chain impacts. To address this gap in contract terms, we recommend including language such as: “lack of or failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers” as part of the defined force majeure event under the contract. This provision can be included in the Change Order section of the contract as well by including a provision such as: “If the Work is delayed by the failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers, contractor shall be entitled to a change order for its costs and time associated with the delay.” Read the court decision
Read the full story...
Reprinted courtesy of Denise Motta, Gordon Rees Scully Mansukhani, LLP
Ms. Motta may be contacted at dmotta@grsm.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES