Columbus Ohio Building Expert Directory

Fifth Circuit Certifies Eight-Corners Duty to Defend Issue to Texas Supreme Court

June 21, 2021 — Jeremy S. Macklin - Traub Lieberman Insurance Law Blog
In the recent case of Bitco Gen. Ins. Corp. v. Monroe Guar. Ins. Co., No. 19-51012, 2021 WL 955155 (5th Cir. Mar. 12, 2021), certified question accepted (Mar. 19, 2021), the Fifth Circuit Court of Appeals certified to the Texas Supreme Court the question of whether a court can consider extrinsic evidence when determining an insurer’s duty to defend. The underlying lawsuit stems from a construction contract in which J&B Farms of Texas hired 5D, a construction company, to drill a commercial irrigation well through the Edwards Aquifer. Two years after beginning the project, J&B Farms sued 5D and its President for breach of contract and negligence. J&B Farms alleged that while drilling, 5D “stuck the drilling bit in the bore hole, rendering the well practically useless for its intended/contracted for purpose.” 5D then “failed and refused to plug the well, retrieve the drill bit, and drill a new well.” J&B Farms asserted that 5D drilled the well “with unacceptable deviation” and then “abandon[ed] the well.” 5D notified its insurers, BITCO and Monroe, of the lawsuit and demanded a defense from both. BITCO agreed to provide a defense to 5D, but Monroe refused arguing that the alleged property damage fell outside the relevant policy period, and therefore, it had no duty to defend 5D. BITCO then filed a declaratory judgment action seeking a finding that Monroe owed 5D a duty to defend. Read the court decision
Read the full story...
Reprinted courtesy of Jeremy S. Macklin, Traub Lieberman
Mr. Macklin may be contacted at jmacklin@tlsslaw.com

Hilti Partners with Canvas, a Construction Robotics Company

April 03, 2023 — Aarni Heiskanen - AEC Business
Hilti announced a strategic partnership with Canvas, a construction robotics company that has developed a robotic drywalling solution. The partnership allows Canvas to scale globally. Hilti launched its Jaibot, the world’s first semi-autonomous ceiling-drilling robot, in 2020. As part of the partnership, Hilti will assume the manufacturing responsibilities for future Canvas systems. They will be based on the Jaibot platform, giving Canvas a reliable and scalable global supply to meet the huge demand for its finishing robots. The partnering companies share a common vision: that robotic tools will unlock vastly untapped potential and drive a new era of productivity and safety for skilled trade workers. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Court Denies Insured's Motion to Dismiss Complaint Seeking to Compel Appraisal

March 13, 2023 — Tred R. Eyerly - Insurance Law Hawaii
The court denied the insured's motion to dismiss after the insurer filed suit to compel an appraisal. Allied Trust Ins. Co. v. Tsang, 2023 U.S. Dist. LEXIS 352 (E.D. La. Jan. 3, 2023). The insureds reported damage to their property arising from Hurricane Ida. The insurer, Allied Trust, investigated and determined that the covered damage was $1,978.18, which was less that the policy's deductible. The insureds estimated that the covered damage was $135,270.78. Allied Trust invoked the appraisal provision. Allied Trust later filed suit alleging the insureds failed to comply and participate in the appraisal. The insureds moved to dismiss the complaint as moot. In their motion, the insureds argued that because they were now complying with the appraisal clause, all relief sought by Allied Trust had either already occurred or was currently underway. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Wilke Fleury Secures Bid Protest Denial

March 16, 2020 — Wilke Fleury LLP
After the City of Vacaville, following a sealed bid process, awarded a significant well drilling contract to Roadrunner Drilling & Pump Company, second-place bidder Nor-Cal Pump and Well Drilling filed a protest with the City on January 30, claiming that Roadrunner’s bid failed to meet certain requirements of the proposed contract. Roadrunner hired Wilke Fleury to defend the bid protest. After Wilke Fleury partner Dan Baxter transmitted a letter to the City explaining why the disgruntled bidder’s protest was factually and legally unsupported, the City—a mere nine days after receiving Dan’s letter—rejected the bid protest, and maintained its award of the project to Roadrunner as the lowest responsive and responsible bidder. Wilke Fleury LLP Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor

September 09, 2024 — David Adelstein - Florida Construction Legal Updates
A recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project. In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

The “Unavailability Exception” is Unavailable to Policyholders, According to New York Court of Appeals

September 10, 2018 — William S. Bennett & Warsame Y. Hassan - Saxe Doernberger & Vita, P.C.
The New York Court of Appeals recently upheld a prior appellate division decision finding that policyholders facing environmental claims, spanning multiple years, cannot force their insurers partially on the risk to provide coverage for years where the insurers did not issue policies, even though pollution insurance was unavailable in the marketplace. In Keyspan Gas E. Corp. v. Munich Reins. Am., Keyspan Gas East Corporation (“Keyspan”) argued other insurers should cover the period when pollution property insurance was unavailable in the marketplace, according to their pro-rata share of coverage. 31 N.Y.3d 51 (2018). In a unanimous decision, the Court emphasized the Appellate Division’s prior ruling that stated, “spreading risk should not by itself serve as a legal basis for providing free insurance to an insured.” Read the court decision
Read the full story...
Reprinted courtesy of William S. Bennett, Saxe Doernberger & Vita, P.C.
Mr. Bennett may be contacted at wsb@sdvlaw.com

Home Buyers will Pay More for Solar

February 05, 2015 — Beverley BevenFlorez-CDJ STAFF
The National Association of Home Builders’ (NAHB) Eye on Housing reported that a study’s results “found that homebuyers are willing to pay more for homes that have installed solar photovoltaic (PV) energy systems.” The team of researchers led by the U.S. Department of Energy’s Berkeley Laboratory “estimates a price premium of approximately $4 per watt of PV installed. For a typical PV system, the research team found that this translates into a price premium of $15,000.” Furthermore, according to the NAHB, the study “suggests that the presence of energy-efficient home features is among the most important concerns for prospective home buyers.” Read the court decision
Read the full story...
Reprinted courtesy of

Colorado’s Federal District Court Finds Carriers Have Joint and Several Defense Duties

October 10, 2013 — Bret Cogdill — Higgins, Hopkins, McLain & Roswell, LLC.
An issue that has plagued builders in Colorado construction defect litigation is the difficulty of getting additional insured carriers to fully participate in the builder’s defense, oftentimes leaving the builder to fund its own defense during the course of the litigation. Many additional insurers offer a variety of positions regarding why they will not pay for fees and costs during the course of a lawsuit. Some insurers argue that, until after trial, it is impossible to determine its proper share of the defense, and therefore cannot make any payments until the liability is determined as to all of the potentially contributing policies. (This is often referred to as the “defense follows indemnity” approach.) Others may make an opening contribution to defense fees and costs, but fall silent as fees and costs accumulate. In such an event, the builder may be forced to fund all or part of its own defense, while the uncooperative additional insured carrier waits for the end of the lawsuit or is faced with other legal action before it makes other contributions. Recent orders in two, currently ongoing, U.S. District Court cases provide clarity on the duty to defend in Colorado, holding that multiple insurers’ duty to defend is joint and several. The insured does not have to go without a defense while the various insurers argue amongst themselves as to which insurer pays what share. Read the court decision
Read the full story...
Reprinted courtesy of Bret Cogdill
Bret Cogdill can be contacted at cogdill@hhmrlaw.com

COLUMBUS OHIO BUILDING EXPERT DIRECTORY AND CAPABILITIES