Cambridge Massachusetts Building Expert Directory

Specification Challenge; Excusable Delay; Type I Differing Site Condition; Superior Knowledge

January 02, 2024 — David Adelstein - Florida Construction Legal Updates
An Armed Services Board of Contract Appeals dispute, Appeal of L.S. Black-Loeffel Civil Constructors JV, ASBCA No. 62402, 2023 WL 5827241 (ASBCA 2023), involved which party bore liability for delay—the federal government or the prime contractor–based on various legal theories. Without detailing the factual details, a number of interesting legal issues were raised in this dispute including (1) a defective specification challenge, (2) excusable delay, (3) Type I differing site condition, and (4) superior knowledge. These legal issues are discussed below. 1. Specification Challenge (Defective Specifications) The contractor claimed that the government’s specifications were defective in regard to a thermal control plan. The government countered that the specifications were not design specifications but performance specifications. The specifications were performance based because they did not tell the contractor how to achieve the performance-based criteria. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Is it the End of the Story for Redevelopment in California?

October 02, 2015 — Garret Murai – California Construction Law Blog
Long, long ago (in 2012 to be exact) in a land not so far away (also known as California), legislation which allowed local governments to establish redevelopment agencies tasked with eliminating blight through the development, reconstruction and rehabilitation of residential, commercial, industrial and retail districts were abolished. Note: For a relatively concise history of redevelopment in California see the U.S. Department of Housing and Urban Development’s working paper Redevelopment Agencies in California: History, Benefits, Excesses, and Closure (January 2014). A quite war has been waged ever since. Cities, community development commissions, successor agencies to redevelopment agencies, nonprofit housing corporations and individual taxpayers have fought the legislation (AB 1X 26 (Blumenfield 2011)) which eliminated California’s 425 redevelopment agencies, principally, on constitutional grounds. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Back to Basics – Differing Site Conditions

December 19, 2018 — Tracey W. Pruiett - Smith Currie
Encountering an unexpected site condition is one of the more common risks on a construction project. A “differing site condition”, or it is sometimes called a “changed condition”, is generally understood to be a physical condition that is discovered while performing work and that was not visible or otherwise expected at the time of bidding. Often, the condition could not have been discovered by a reasonable site investigation. Examples of common differing site conditions include: soil with inadequate bearing capacity to support the building being constructed, soil that cannot be reused as structural fill, unanticipated groundwater, quicksand, mud, rock formations, or other artificial subsurface obstructions. Differing site conditions may also occur within the walls or ceilings of a renovation project such as the renovation of a hospital or historic building. Read the court decision
Read the full story...
Reprinted courtesy of Tracey W. Pruiett, Smith Currie
Ms. Pruiett may be contacted at twpruiett@smithcurrie.com

Wheaton to Require Sprinklers in New Homes

November 06, 2013 — CDJ STAFF
The town of Wheaton, Illinois is considering a change to its building codes, based on the recommendations made in the 2012 building code, released by the International Code Council. Eighty-two towns in Illinois already require new homes to have fire sprinklers. Wheaton did not adopt any changes from the 2006 or 2009 building code; they are currently using the standards of the 2003 edition. Read the court decision
Read the full story...
Reprinted courtesy of

Court Finds that Subcontractor Lacks Standing to Appeal Summary Judgment Order Simply Because Subcontractor “Might” Lose at Trial Due to Order

May 03, 2021 — Garret Murai - California Construction Law Blog
Cases sometimes take unanticipated twists and turns. Atlas Construction Supply, Inc. v. Swinerton Builders, Case No. D076426 (January 26,2021), involving a tragic construction accident, a motion for summary judgment, a motion for good faith settlement, and a stipulated dismissal, is one of those cases. The Accident Swinerton Builders was the general contractor on a residential construction project in San Diego, California. Swinerton contracted with J.R. Construction, Inc. to perform concrete work and with Brewer Crane & Rigging, Inc. to perform crane work on the project. J.R. Construction in turn rented a concrete column formwork approximately 10 feet tall and weighing 300 to 400 pounds from Atlas Construction Supply, Inc. One day on the construction project, Marcus Develasco, Sr. and another co-worker, employees of J.R. Construction, climbed to the top of the formwork to adjust its size. The formwork, which had been positioned on the site by Brewer, was upright but unsupported by braces. When the co-worker stepped off the formwork, Develasco’s weight caused the unsecured formwork to topple over, killing Develasco in the process. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

North Carolina Appeals Court Threatens Long-Term Express Warranties

April 09, 2014 — Beverley BevenFlorez-CDJ STAFF
Jonathan Massell of the firm Nexsen Pruet explained how a “recent holding by the North Carolina Court of Appeals is threatening to render many long-term express warranties ineffective,” in the online publication Lexology. In Christie v. Hartley Construction, Inc., “the court held that the six-year North Carolina statute of repose for improvements to real property trumps the bargained-for duration terms of an express warranty.” In the Christie case, this meant that even though the homeowners had a twenty year warranty, because of the statute of repose, the warranty effectively expired after six years. Massell stated to “be mindful of jurisdiction.” If the express warranty is in a state other than North Carolina, it’s possible that the claim could be filed in that state instead of North Carolina. For instance, according to Massell, South Carolina’s “statue of repose does not expire until eight years after the date of substantial completion for an improvement to real property.” Furthermore, “long-term warranties are not trumped by the South Carolina statute of repose.” Read the court decision
Read the full story...
Reprinted courtesy of

As Trump Visits Border, Texas Landowners Prepare to Fight the Wall

February 11, 2019 — Associated Press - Engineering News-Record
HIDALGO, Texas (AP) — As President Donald Trump traveled to the border in Texas to make the case for his $5.7 billion wall , landowner Eloisa Cavazos says she knows firsthand how the project will play out if the White House gets its way. The federal government has started surveying land along the border in Texas and announced plans to start construction next month. Rather than surrender their land, some property owners are digging in, vowing to reject buyout offers and preparing to fight the administration in court. Read the court decision
Read the full story...
Reprinted courtesy of Engineering News-Record
ENR may be contacted at ENR.com@bnpmedia.com

Ohio Court of Appeals: Absolution Pollution Exclusion Bars Coverage for Workplace Coal-Tar Pitch Exposure Claims

January 10, 2018 — Complex Insurance Coverage Reporter

On December 28, 2017, the Ohio Court of Appeals (Eighth District) held in GrafTech International, Ltd., et al. v. Pacific Employers Ins. Co., et al., No. 105258 that coverage for alleged injurious exposures to coal tar pitch was barred by a liability insurance policy’s absolute pollution exclusion. Applying Ohio law, the court concluded that Pacific Employers had no duty to defend GrafTech or pay defense costs in connection with claims by dozens of workers at Alcoa smelting plants that they were exposed to hazardous substances in GrafTech products supplied to Alcoa as early as 1942.

Read the court decision
Read the full story...
Reprinted courtesy of White and Williams LLP

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES