Understanding Entitlement to Delays and Proper Support
December 10, 2024 —
Andrew G. Vicknair - The Dispute ResolverIn a previous
post, we discussed delays on construction projects including (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. We also reviewed the common methods of delay analysis include (1) the Total Cost Method, (2) the Modified Total Cost Approach, and (3) the Measured Mile Method.
Once you have determined the type of delay and the method to be used to analyze and quantify the delay, it is important to understand the type of documents/evidence needed to support your claim for delay.
If a party determines that they are entitled to some type of recovery for the delay, the party making a claim for delay, such as a contractor, must have the proper documentation/evidence to assist in proving entitlement for damages from the delay. Without the proper back-up, contractors are generally unable to recover all of the additional costs and expenses associated with the delays or, at best, recover only an “equitable” amount. Generally, damages must be proved with reasonable certainty and may not be based on speculation or conjecture. Thus, it is crucial for a party asserting a delay to have the proper documentation to support a delay claim, if the goal is to recover the damages associated with the delay.
Read the court decisionRead the full story...Reprinted courtesy of
Andrew G. Vicknair, D'Arcy Vicknair, LLCMr. Vicknair may be contacted at
agv@darcyvicknair.com
Homeowner Has No Grounds to Avoid Mechanics Lien
September 01, 2011 —
CDJ STAFFThe California Court of Appeals has rejected a motion by a homeowner in a dispute with the contractor who built an extension to his home. In McCracken v. Pirvulete, Mr. McCracken filed a mechanics lien after Mr. Pirvulete failed to complete payment. The matter went to trial with a series of exhibits that showed “the contractual relationship was strained and the parties disagreed over performance and payment.” As a result of the trial, the court awarded Mr. McCracken, the contractor, $1,922.22.
Mr. Pirvulete appealed, contending that the court had not allowed his daughter to act as a translator, that the court had failed to give him sufficient time to present his case, that the mechanics lien should have been dismissed, and several other claims, all before a formal judgment was issued. After the court formalized its judgment and rejected the appeal, Mr. Pirvulete appealed again.
The appeals court found that Mr. Pirvulete did not provide an adequate record for review. The court dismissed Mr. Pirvulete’s claims. The court notes that Mr. Pirvulete claimed that a request for a discovery period was denied, however, he has provided neither the request nor the denial. The trial court has no record of either.
Nor was there a record of a request that Mr. Pirvulete’s daughter provide translation. The court notes, “so far as we can glean from the record provided, the Register of Actions states, ‘Trial to proceed without Romanian Interpreter for Defendant; Daughter present to interpret if needed.’” Additionally, the court found that “there has been no showing that his facility with the English language is or was impaired in any way or that there was any portion of any proceeding, which he did not understand.”
Further, the appeals court found there were no grounds for a new trial, despite Mr. Pirvulete’s filings. The court concluded, “The owner has failed to provide a record adequate for review of most, if not all, of the claims of error. Some issues are not cognizable because they relate to entirely separate proceedings, and not the trial below. To the limited extent that the claims are examinable, the owner has made no showing of error.” The court affirmed the judgment of the lower court against Mr. Pirvulete.
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of
What’s in a Name? Trademarks and Construction
April 25, 2022 —
Carol Wilhelm and J.P. Vogel - Construction ExecutiveEvery company, no matter the industry, relies on its name and reputation to develop customers and generate revenue. Think about the brands that dominate American culture such as Nike, Wal-Mart, Amazon or McDonald’s, then imagine those businesses without the ability to adequately protect their names, slogans and logos. No doubt the vultures would circle and brand power would most likely become short lived or otherwise diluted to the point of non-existence. The construction industry is not exempt, and the industry leaders benefit from identifiable names and logos, built over years of reputation and brand building. While the tools necessary to protect your company’s brand exist at the state and federal level, many business owners or leaders are unfamiliar with the trademark process and unaware of the consequences of not utilizing those tools.
Trademark Registration
Trademarks are “concise and unequivocal identifiers” that provide potential customers with essential information about your business. With a single word, tagline, logo, color—essentially anything that can carry meaning—potential customers learn to associate particular product or service characteristics and expected quality level with a particular source. That is, your mark is the way that consumers connect your expertise and reputation to your business and nobody else’s. It serves a critical role in reducing consumer search costs and capturing your hard-earned business opportunities.
Reprinted courtesy of
Carol Wilhelm and J.P. Vogel, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Mr. Vogel may be contacted at jpvogel@grayreed.com
Ms. Wilhelm may be contacted at cwilhelm@grayreed.com
Read the court decisionRead the full story...Reprinted courtesy of
General Contractor Gets Fired [Upon] for Subcontractor’s Failure to Hire Apprentices
September 23, 2024 —
Garret Murai - California Construction Law BlogAs most public works contractors know, Labor Code section 1777.5 requires the hiring of apprentices on public works projects and, under Labor Code section 1777.7, violations are subject to civil penalties of up $100/day and up to $300/day days for repeated violations within a three-year period.
In
Lusardi Construction Co. v. Dept. of Industrial Relations, 102 Cal.App.5th (2024), a prime contractor learned the hard way that not only could it be penalized for its failure to hire apprentices but that it could also be liable for its subcontractor’s failure to hire apprentices. Forewarned is to be forearmed.
The Lusardi Construction Case
In 2014, general contractor Lusardi Construction Company hired subcontractor Pro Works Contracting to perform iron reinforcing work on a public works project owned by the San Marcos Unified School District.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Expired Contract Not Revived Due to Sovereign Immunity and the Ex Contractu Clause
October 27, 2016 —
Chadd Reynolds and David Cook – Autry, Hanrahan, Hall & Cook, LLPA few months ago, a decision by the Supreme Court of Georgia in Georgia Department of Labor v. RTT Associates, Inc. provided a strict rule for contractors that work with state agencies to determine whether a state agency has waived its sovereign immunity. The issue as framed by the Court was “whether an agency’s waiver of immunity from a breach of contract claim as a result of entering into a written contract remains intact in the event the contract is extended without a written document signed by both parties expressly amending the contract, as required by its terms.”
Reprinted courtesy of
David Cook, Autry, Hanrahan, Hall & Cook, LLP and
Chadd Reynolds, Autry, Hanrahan, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com
Mr. Reynolds may be contacted at reynolds@ahclaw.com
Read the court decisionRead the full story...Reprinted courtesy of
New Jersey Appellate Decision Reminds Bid Protestors to Take Caution When Determining Where to File an Action
March 13, 2023 —
Brian Glicos & Nicholas J. Zaita - Peckar & Abramson, P.C.On February 21, 2023, the New Jersey Appellate Division held that University Hospital is not a “state administrative agency” and, therefore, the Appellate Division does not have original jurisdiction to determine the merits of an action commenced by an unsuccessful bidder to challenge the award of a contract. In re Protest of Contract for Retail Pharmacy Design, Constr., Start-up & Operation, Request for Proposal No. UH-P20-006, A-1667-20, 2023 WL 2125002 (N.J. Super. Ct. App. Div. Feb. 21, 2023).
Pursuant to Rule 2:2-3(a)(2) of New Jersey’s Rules of Court, final decisions or actions of any state administrative agency or officer may be appealed directly to the Appellate Division as of right. Accordingly, where an unsuccessful bidder chooses to challenge the award of a contract issued by, for example, the New Jersey Department of Transportation, the unsuccessful bidder must file its action directly with the Appellate Division. On the other hand, where an unsuccessful bidder wishes to challenge a contract award made by a local municipality (among a slew of other public entities), the Superior Court Law Division maintains original jurisdiction over the dispute.
Reprinted courtesy of
Brian Glicos, Peckar & Abramson, P.C. and
Nicholas J. Zaita, Peckar & Abramson, P.C.
Mr. Glicos may be contacted at bglicos@pecklaw.com
Mr. Zaita may be contacted at nzaita@pecklaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Pennsylvania Modular Home Builder Buys Maine Firm
December 11, 2013 —
CDJ STAFFExcel Homes, a modular home builder based in Liverpool, Pennsylvania, has bought Keiser Homes, a modular home builder based in Oxford Hills, Maine. Excel sought to increase their capacity, which acquisition of the Oxford Hills facility allows. Excel had previously shown an interest in the property of an Oxford Hills modular home builder that had closed, Oxford Homes, but a decrease in sales of modular homes lead Excel to reconsider the purchase.
Excel Homes plans on doubling the current output of the Oxford Hills facility and will be hiring additional employees. The purchase included all of Keiser’s machinery, trucks, trailers, equipment, and the customer list.
Read the court decisionRead the full story...Reprinted courtesy of
Trump Abandons Plan for Council on Infrastructure
August 17, 2017 —
Mark Niquette - BloombergPresident Donald Trump will not move forward with a planned Advisory Council on Infrastructure, a person familiar with the matter said Thursday.
The infrastructure council, which was still being formed, would have advised Trump on his plan to spend as much as $1 trillion upgrading roads, bridges and other public works. Its cancellation follows Trump’s announcement Wednesday that he was disbanding two other business advisory panels.
Read the court decisionRead the full story...Reprinted courtesy of
Mark Niquette, Bloomberg