Seattle Washington Building Expert Directory

Subcontract Should Flow Down Delay Caused by Subcontractors

December 21, 2020 — David Adelstein - Florida Construction Legal Updates
A general contractor’s subcontract with its subcontractor should include a provision that entitles it to flow down liquidated damages assessed by the owner stemming from delays caused by the subcontractor. Such a provision does not mean the general contractor does not have to prove delays caused by the subcontractor or can arbitrarily allocate the amount or days it claims the subcontractor is liable. The general contractor still will need to reasonably establish the delays the subcontractor caused the critical path of the schedule, i.e., delayed the job. In addition to the right to flow down liquidated damages, the subcontract should also entitle the general contractor to recover its actual extended general conditions caused by the subcontractor’s delays (regardless of whether the owner assesses liquidated damages). The objective is that if the subcontractor delays the job, the subcontractor is liable for liquidated damages the general contractor is liable to the owner for in addition to the general contractor’s own delay damages. This is an important subcontractual provision so that the risk of delay caused by subcontractors is clearly flowed down to them in the subcontract. In a 1987 case, Hall Construction Co., Inc. v. Beynon, 507 So.2d 1225 (Fla. 5th DCA 1987), the subcontract at-issue contained language that stated, “The parties hereto agree that a supplier who delays performance beyond the time agreed upon in this Purchase Order shall have caused [general contractor] liquidated damages in the amount required of [general contractor] by their contract per day for each day such delay continues which sum the supplier hereby agrees to pay.” Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Hawaii Federal District Court Grants Preliminary Approval of Settlement on Volcano Damage

September 13, 2021 — Tred R. Eyerly - Insurance Law Hawaii
The federal district court granted preliminary approval of the class action settlement reached on behalf of insureds who suffered property damage due to the 2018 Kilauea eruption on the Big Island. Aquilina v. Certain Underwriters at Lloyd's London, 2021 U.S. Dist. LEXIS 152614 (D. Haw. Aug. 13, 2021). After destruction of their homes due to lava flow, plaintiffs sued various insurers and agents as a putative class action. Plaintiffs claimed they purchased surplus lines policies brokered and underwritten by various defendants. The policies each contained an exclusion for the peril of lava flow, which plaintiffs claimed rendered them worthless or unsuitable given that their properties were located in a high-risk lava zone. Plaintiffs alleged that defendants breached obligations under the Hawaii Surplus Lines Act, which required that surplus lines insurers conduct a diligent search for other available coverage before placing a homeowner with surplus lines coverage. Plaintiffs alleged defendants should have advised them of the availability of lava-damage coverage through the Hawaii Property Insurance Association (HPIA), a statutorily created association of admitted insurers established in part in response to Kilauea's eruption patterns, which made the private insurance market less likely to Insure certain high-risk areas. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Claim for Vandalism Loss Survives Motion to Dismiss

October 02, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The court ruled that the insured's claim for vandalism of his house by a renter and for bad faith survived the insurer's motion to dismiss. Wehrenberg v. Metro. Prop. & Cas. Ins. Co., 2015 U.S. Dist. LEXIS 103758 (W.D. Pa. Aug. 7, 2015). The insured's home was insured by a homeowner's policy issued by Metropolitan. The insured rented his home to Alphonso Hyman in October 2011. In lieu of rent, Hyman was to pay the mortgage company the equivalent of his rent each month. In early 2012, Hyman stopped making the monthly rent/mortgage payments. The insured went to the home and found the locks had been changed. Looking in the windows, he saw the interior had been gutted. When the insured reached Hyman, Hyman said he was a contractor and was fixing the structural problems and would put the house back together. He also promised to make up late payments to the mortgage company. The insured did not report what he found to Metropolitan. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Insurer’s Duty to Indemnify Not Ripe Until Underlying Lawsuit Against Insured Resolved

February 03, 2020 — David Adelstein - Florida Construction Legal Updates
A liability insurer has two duties: 1) the duty to defend its insured; and 2) the duty to indemnify its insured. With respect to the second duty – the duty to indemnify – this duty is typically “not ripe for adjudication unless and until the insured or putative insured has been held liable in the underlying action.” Hartford Fire Ins Co. v. Beazer Homes, LLC, 2019 WL 5596237, *2 (M.D.Fla. 2019) (internal quotation omitted). For instance, Beazer Homes involved an insurance coverage dispute stemming from construction defects. An owner sued its general contractor for construction defects relating to stucco problems. The general contractor paid for the repairs. The general contractor then sued its stucco subcontractor to recover the costs it incurred. The subcontractor tendered the defense of the lawsuit to its commercial general liability insurer which is defending its insured-subcontractor under the commonly issued reservation of rights. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

New ANSI Requirements for Fireplace Screens

March 19, 2015 — Beverley BevenFlorez-CDJ STAFF
The American National Standards Institute (ANSI) now requires “vented gas fireplaces to include a safety barrier screen as standard equipment,” according to Remodeling. "While gas fireplaces, stoves and inserts are a great asset to any home, the glass can become very hot during operation and stay hot long afterwards, creating a potential burn hazard," Jack Goldman, HPBA president and CEO told Remodeling. Read the court decision
Read the full story...
Reprinted courtesy of

Too Costly to Be Fair: Texas Appellate Court Finds the Arbitration Clause in a Residential Construction Contract Unenforceable

November 21, 2022 — Gus Sara - The Subrogation Strategist
In Cont’l Homes of Tex., L.P. v. Perez, No. 04-21-00396-CV, 2022 Tex. App. LEXIS 7691, the Court of Appeals of Texas (Appellate Court) considered whether the lower court erred in refusing to enforce an arbitration clause in a construction contract between the parties. The Appellate Court considered the costs of the arbitration forum required by the contract in the context of the plaintiffs’ monthly household income. The court also compared the arbitration cost to the estimated cost of litigating the dispute. The court held that the arbitration clause was substantively unconscionable on the grounds that the arbitration costs were not affordable for the plaintiffs and not an “adequate and accessible substitute to litigation.” The Appellate Court affirmed the lower court’s decision denying the defendant’s motion to compel arbitration. The plaintiffs, Giancarlo and Krystle Perez (collectively, the Perezes), hired the defendant, Continental Homes of Texas, LP d/b/a Express Home (Express Homes), to build a new home in San Antonio. Express Homes provided its standard contract, which included a binding arbitration clause. The clause stated that every potential dispute between the parties occurring before and after the closing of the purchase of the home was subject to binding arbitration, to be administered and conducted by the American Arbitration Association (AAA). The clause also stated that the costs of the arbitration were to be split by the parties. Read the court decision
Read the full story...
Reprinted courtesy of Gus Sara, White and Williams LLP
Mr. Sara may be contacted at sarag@whiteandwilliams.com

Relying Upon Improper Exclusion to Deny Coverage Allows Bad Faith Claim to Survive Summary Judgment

December 04, 2018 — Tred R. Eyerly - Insurance Law Hawaii
The insurer was successful on summary judgment in establishing it correctly denied coverage for collapse, but its motion was denied regarding the insureds' bad faith claim. Jones v. State Farm Fire & Cas. Co., 2018 U.S. Dist. LEXIS 153102 (W.D. Wash. Sept. 7, 2018). The insureds' retaining wall collapsed. They tendered to State Farm under their homeowners policy. An engineer retained by State Farm determined that the wall buckled due to "excessive lateral earth pressure from retained soils behind the wall." The parties agreed that the soil, saturated by water from frequent rain, grew too heavy for the retaining wall to bear, causing the collapse. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Policy Reformed to Add New Building Owner as Additional Insured

July 10, 2023 — Tred R. Eyerly - Insurance Law Hawaii
The lower court correctly reformed the policy to replace the prior owner with the new owner as an additional insured under the policy. Wesco Ins. Co. v. Fulmont Mut. Ins. Co., 2023 N.Y. App. Div. LEXIS 2650 (N. Y. App. Div. May 11, 2023). Beyond was sued as owner of the building in a personal injury lawsuit. The former owners leased the building to the tenant who included the then-owners as additional insureds under the tenant's policy. When the deed to the building was transferred to Beyond, the additional insured endorsement in the tenant's policy was not updated to reflect the change in ownership. Beyond's insurer, Wesco, tendered the lawsuit to the tenant's insurer, Fulmont. Coverage was denied because Beyond was not an additional insured under the tenant's policy. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES