Fairfield Connecticut Building Expert Directory

Construction Delays: Which Method Should Be Used to Calculate Delay?

July 25, 2021 — David Adelstein - Florida Construction Legal Updates
If you need to prove and allocate construction project delays, you should engage a scheduling consultant qualified with CPM (critical path method) analysis. You should also engage counsel to assist in preserving your rights, as well as presenting and maximing your arguments for delay. There are numerous methodologies used to quantify and allocate delay. You want to discuss the most effective analysis for your case and facts including whether you want/should use a forward-looking prospective analysis or a backward-looking retrospective analysis that factors in as-built data. In doing so, you want to make sure you understand the pros and cons of each methodology including the bases to attack the methodology that will be subject to cross-examination. The five primary CPM methodologies are as follows:

As-Planned Versus As-Built. This methodology compares the as-planned baseline schedule to an as-built schedule reflecting progress to assign delay. An as-built schedule that reflects progress includes actual start dates, finish dates, and durations. The actual dates and durations are compared with the as-planned dates and durations on the baseline schedule to determine delay. Under this methodology, the delay impact is determined retrospectively.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

North Dakota Universities Crumble as Oil Cash Pours In

August 27, 2014 — Jennifer Oldham – Bloomberg
North Dakota is struggling to finance deteriorating public universities even as it experiences the biggest energy boom in its history, raising concern that less prosperous states will face more serious funding challenges. Students returning this week will attend classes in buildings without adequate ventilation or fire detection systems and in historic landmarks with buckling foundations. A space crunch is making it difficult for researchers to obtain grants and putting the accreditation of several programs at risk, administrators say. “It’s embarrassing,” said North Dakota state Representative Kathy Hawken, a Republican from Fargo who sits on the higher education funding and budget committees. “We have a divided legislature on higher ed: Some think we put too much money into it and some think we don’t put enough. Buildings aren’t people, so we don’t put dollars there.” Read the court decision
Read the full story...
Reprinted courtesy of Jennifer Oldham, Bloomberg
Ms. Oldham may be contacted at joldham1@bloomberg.net

“Since You Asked. . .”

October 15, 2024 — Daniel Lund III - Lexology
… you must now pay. So said a California appellate court, affirming the trial court’s decision against a subcontractor suing for unpaid subcontract sums. Instead of being awarded those unpaid amounts, the subcontractor lost the case and was tagged with a $1.55 million attorney’s fees award and $270,000 costs award in favor of the defendants. What went wrong? California law requires a licensed contractor to maintain at all times proper workers’ compensation insurance coverage. The failure to maintain the coverage and have the certificate of coverage on file with the California Contractors State License Board results in “automatic and immediate suspension” of the contractor license. Retroactive reinstatement of the license may occur only if the contractor provides proof of the insurance within 90 days of the effective date of the insurance certificate – unless the contractor can show that failure to have the certificate on file was “due to circumstances beyond the control of the licensee.” Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

Are Construction Defect Laws a Factor in Millennials Home Buying Decisions?

March 12, 2015 — Beverley BevenFlorez-CDJ STAFF
Kimberly A. O’Hagan of Otten Johnson Robinson Neff + Ragonnetti PC discussed Millennials in Denver, Colorado, and how their desire to buy may cause them to leave the area due to a lack of affordable housing. O’Hagan describes various possible reasons for the lack of affordable housing: “Some cite the inability to qualify for financing and low demand as the reasons for the decreased number of condominium projects. Others, including Denver’s Mayor Hancock, credit the chill on condominium construction to Colorado’s construction defect laws, which they say have resulted in increased insurance costs that make condominium development economically infeasible.” Read the court decision
Read the full story...
Reprinted courtesy of

Mercury News Editorial Calls for Investigation of Bay Bridge Construction

July 01, 2014 — Beverley BevenFlorez-CDJ STAFF
Editors at the San Jose Mercury News called for investigations of the construction of the new eastern span of the Bay Bridge: “It's time for public officials, especially members of the Metropolitan Transportation Commission, state legislators and Gov. Jerry Brown, to demand thorough independent analyses.” Problems with the $6.5 billion structure were found about nine months ago, which led to questions regarding the “integrity and maintenance costs” that were allegedly covered up by Caltrans officials. Issues raised included questions “about the strength of thousands of bolts, including at the base of the tower and the connections of the main cable; cracked welds in the suspension span; and rusting of the single cable holding up the bridge.” The Mercury editors, however, do not show much optimism about the situation: “It's likely that, absent a political outcry, Caltrans will sign off. From the start, agency officials have failed to adequately oversee the construction and thrown public money at problems while trying to cover-up their own failures. Brown, ultimately responsible for Caltrans, has dismissed concerns about the bridge's integrity.” Read the court decision
Read the full story...
Reprinted courtesy of

Unpaid Subcontractor Walks Off the Job and Wins

September 01, 2016 — John P. Ahlers – Ahlers & Cressman PLLC
Make the following inquiry of your constructional lawyer, watch him/her sit up in his/her chair and give your question immediate attention: “I haven’t been paid, can I walk off the job?” The answer to this question is a strong “maybe, but it’s risky.” Walking off the project has a significant downside. The risk is that the judge who reviews your decision, sometimes years after the event, may not agree that the non-payment was a material breach and, thus, suspension of performance (walking off) is not justified. A breach of contract occurs where, without legal justification, a party fails to perform any promise that forms a whole or part of the contract. Not all breaches are equal. Some failures to perform a promise are “nominal,” “trifling” or “technical.” These breaches do not excuse performance under the contract by the non-breaching party. If the breach is “material,” that is, goes to the essential purpose of the agreement, is a question that only a judge decides, and only after the decision was made as to whether to walk off the job or not. Therefore, before deciding whether to walk off the job, you have to second guess what a judge may decide under the circumstances. Since not all judges see things the same way, the decision is fraught with uncertainty and risk. Read the court decision
Read the full story...
Reprinted courtesy of John P. Ahlers, Ahlers & Cressman PLLC
Mr. Ahlers may be contacted at jahlers@ac-lawyers.com

Balestreri Potocki & Holmes Attorneys Named 2020 Super Lawyers and Rising Star

July 06, 2020 — Balestreri Potocki & Holmes
The law firm of Balestreri Potocki & Holmes is pleased to announce that Shareholders Thomas A. Balestreri, Jr. and Joseph P. Potocki have been selected as 2020 Super Lawyers and Associate Robin H. Smith has been named a 2020 Rising Star. Each year no more than 5 percent of the lawyers in the state are selected to receive the honor of being included in the Super Lawyers list and no more than 2.5 percent of the lawyers are selected to the Rising Stars list. Balestreri has been selected to the Super Lawyers list in the areas of Construction Litigation. Balestreri has dedicated most of his 30 plus years in practice to the representation of developers, property owners, and general contractors in litigation, negotiations, and risk management. A seasoned trial lawyer, he has tried a number of high exposure cases with great success. Selected as a Super Lawyer in the area of Construction Litigation, Potocki’s practice concentrates on litigation, transactional matters and construction contract drafting and negotiation. His extensive litigation experience involves high-value disputes relating to a wide variety of issues in the real estate, business and construction arenas. Smith has been named a Rising Star by Super Lawyers in the area of Civil Litigation. In her varied litigation practice, Smith represents individuals and business entities in complex catastrophic personal injury matters. She also represents employers in labor and employment matters and a variety of businesses, including automobile dealers, in breach of contract, unfair competition, unfair business practices, defamation, and consumer claims. Super Lawyers, a Thompson Reuters business, is a rating service of outstanding lawyers from more than 70 practice areas who have attained a high degree of peer recognition and professional achievement. The annual selections are made using a patented multiphase process that includes a statewide survey of lawyers, an independent research evaluation of candidates and peer reviews by practice area. The result is a credible, comprehensive and diverse listing of exceptional attorneys. Balestreri Potocki & Holmes is headquartered in San Diego, California. The firm provides comprehensive counsel to large and small companies across a wide range of established and emerging industries. Balestreri Potocki & Holmes is located in downtown San Diego at 401 B Street, Suite 1470. More information about the firm can be found at: www.bph-law.com. Read the court decision
Read the full story...
Reprinted courtesy of Balestreri Potocki & Holmes

What is the True Value of Rooftop Solar Panels?

April 15, 2014 — Beverley BevenFlorez-CDJ STAFF
In Colorado, regulators are questioning the true value of rooftop solar panels, reported the Denver Business Journal: “Minneapolis-based Xcel Energy Inc. (NYSE: XEL), the biggest utility in Colorado, has said it believes Colorado’s current ‘net metering’ policy means the utility is overpaying customers who have rooftop solar power systems.” Currently, “Xcel...credits customers at a rate of 10.5 cents per kilowatt hour of excess power produced.” However, the utility company believes that “the ‘true value’ of the rooftop solar electricity is about half what it’s paying—just 4.6 cents per kilowatt hour.” According to the Denver Business Journal, supporters argue that “Xcel has undervalued the electricity and hasn’t accounted for the systems’ environmental and economic attributes.” Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES