Uniwest Rides Again (or, Are Architects Subject to Va. Code Section 11-4.1?)
October 16, 2018 —
Christopher G. Hill - Construction Law MusingsIn 2010, the Virginia Supreme Court held in Uniwest Const., Inc. v. Amtech Elevator Servs., Inc., that Va. Code Sec. 11-4.1 renders completely void and unenforceable any indemnification provision in a construction contract between a contractor and subcontractor that seeks to indemnify the indemnified party from its own negligent acts. In short, the Virginia Supreme Court stated that such overly broad provisions violate Section 11-4.1.
A recent case out of the Eastern District of Virginia Federal District Court examined a provision in a contract between a designer/architect and a contractor or owner on a project. In Travelers Indem. Co. of Conn. v. Lessard Design Inc. the Court examined the application of Section 11-4.1 to the following provision of a design contract where Lessard, the indemnitor, agreed to:
[i]ndemnify, defend and hold the Owner, Owner’s Developer, and Owner’s and Owner’s Developer’s wholly owned affiliates and the agents, employees and officers of any of them harmless from and against any and all losses, liabilities, expenses, claims, fines and penalties, costs and expenses, including, but not limited to reasonable attorneys’ fees and court costs relating to the services performed by the Architect hereunder . . .
Read the court decisionRead the full story...Reprinted courtesy of
Christopher G. Hill, The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
Documenting Contract Changes in Construction
December 07, 2020 —
J.D. Holzheauser - Construction ExecutiveConstruction projects are almost inevitably subject to changes in the contract. A fundamental understanding of construction changes, how those changes are governed and what is necessary to ensure a complete change are of paramount importance to all parties involved in a construction project. This article is not a treatise on construction contract changes; rather, it provides advice on actions a contractor can take during construction that will help the contractor recover time or money when a contract’s schedule or scope of work needs to be changed.
Changes Defined
Changes to a construction project affect two broad spheres—timing and scope of work. Changes usually present themselves as either a change order or a change directive. Each may go by a different name depending on the contractual scheme in the project’s prime contract, but they essentially have the same characteristics.
The difference between a change order and a change directive is one of agreement. A change order (in the owner-prime contractor context) occurs when the contractor and the owner agree to a change in the timing or scope of work in the contract. Normally, the change order is a written agreement to change the contract and is executed by the contractor and owner.
Reprinted courtesy of
J.D. Holzheauser, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Mr. Holzheauser may be contacted at jdholzheauser@pecklaw.com
Read the court decisionRead the full story...Reprinted courtesy of
It Has Started: Supply-Chain, Warehouse and Retail Workers of Essential Businesses Are Filing Suit
June 22, 2020 —
Robert G. Devine, James Burger & Douglas Weck - White and Williams LLPSupply-chain businesses that are appropriately characterized as “essential” have remained open for the delivery of critical supplies while everyone else has been told to close up shop and stay home. Now essential-business employees are contracting COVID-19 and filing suit. Following up on our earlier piece — “Is a Violation of a COVID-19 Order the Basis For Civil Liability?” — it is important to recognize that government directives, oftentimes couched as “recommendations,” can come to define what it means to provide a reasonably safe workplace that protects employees from COVID-19. While common law negligence defenses consider the reasonableness of conduct, these directives will likely become the standard.
The cases that have been filed are overwhelmingly premised upon the timeless negligence construct. The negligence construct, simply put, imposes a duty to act as a reasonable person would under the circumstances. Nonetheless, while the negligence construct lives in the ordinary world of “reasonableness,” infection-control guidance lives in the rapidly developing world of the science of COVID-19. Guidance on seemingly basic questions, such as the methods of transmission (e.g., personal contact, mucus membrane only, airborne transmission) or even the virus’s shelf life on different surfaces, of particular interest packaging and material handling equipment, can change by the day. All of this provides challenges for the supply-side business looking to protect its workforce.
Reprinted courtesy of White and Williams LLP attorneys
James Burger,
Robert Devine and
Douglas Weck
Mr. Burger may be contacted at burgerj@whiteandwilliams.com
Mr. Devine may be contacted at deviner@whiteandwilliams.com
Mr. Weck may be contacted at weckd@whiteandwilliams.com
Read the court decisionRead the full story...Reprinted courtesy of
Giving Insurance Carrier Prompt Notice of Claim to Avoid “Untimely Notice” Defense
June 12, 2023 —
David Adelstein - Florida Construction Legal UpdatesWhen it comes to giving your insurance carrier notice of claim, I am an advocate of providing that notice as soon as possible, i.e., prompt notice. The reason is to take away the carrier’s argument to deny coverage because you, as the insured, failed to provide it with prompt notice—the “untimely notice” defense. It doesn’t matter whether it is a first party property insurance claim or third-party liability policy claim, provide notice as soon as reasonably possible to take away that “untimely notice” defense.
The “untimely notice” defense was the issue in Benson v. Privilege Underwriters Reciprocal Exchange, 48 Fla.L.Weekly D1085a (Fla. 6th DCA 2023) dealing with a first party property insurance policy. In this case, eighteen months after Hurricane Irma, the plaintiff noticed a smell and observed brown stains on walls and ceiling in his home. The plaintiff called roofing companies to inspect the damage and perform certain repairs. However, the plaintiff still noticed the smell so he called a company to test and remediate mold. The plaintiff, then, contacted his property insurer with numerous claims relative to the leaks and damage. Although there was an initial property insurance payment made, the carrier ultimately denied coverage for subsequent claims stating that “the late notice of the claim and the prior repairs to the roof substantially prejudiced its ability to complete an inspection of [plaintiff’s] property to evaluate the claim.” Benson, supra.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Not So Fast, My Friend: Pacing and Concurrent Delay
April 25, 2022 —
William E. Underwood - ConsensusDocsWhen critical path activities are delayed by the owner (or another party), contractors will sometimes “pace,” or slow down, other activities to match the owner-caused delay. After all, why should the contractor hurry up and wait? But paced activities can often appear as concurrent delays on a project’s overall schedule. And all too often, contractors fail to contemporaneously document their efforts to pace work. Not only can this create avoidable disputes with owners and other contractors, but it can also create future roadblocks to the recovery of delay damages. This article examines the interplay between pacing and concurrent delay[1] and what contractors should do to minimize risk and preserve their rights to obtain more than a simple time extension for project delays.
Pacing versus Concurrent Delay
As a basic matter, most contracts allocate responsibility/liability for a schedule delay to the party that caused the delay. For example, if an owner is contractually required to provide equipment for a contractor to install, then the owner likely bears responsibility for any delays caused if the equipment is delivered late. If, however, the contractor was also behind schedule on other activities during this time and the project would have been delayed regardless of the owner’s late deliveries, then the delay is probably concurrent. And the contractor will generally be entitled to only an extension of time, and no other monetary relief.
Read the court decisionRead the full story...Reprinted courtesy of
William E. Underwood, Jones Walker LLP (ConsensusDocs)Mr. Underwood may be contacted at
wunderwood@joneswalker.com
Insured's Claim for Water Damage Dismissed with Leave to Amend
August 12, 2024 —
Tred R. Eyerly - Insurance Law HawaiiThe court granted the insurer's motion to dismiss the insured's claim for water damage under a homeowners' policy, but granted leave to amend. Thompson v. State Farm Gen. Ins. Co., 2024 U.S. Dist. LEXIS 98486 (C.D. Cal. June 3, 2024).
The insureds' first amended complaint alleged they "suffered a sudden and accidental water loss below their slab in their home." A plumber hired by the insureds discovered "a copper pipe burst inside a structural concrete footing between a manifold in the living room and the water heater." The insureds notified their insurer, State Farm.
Claim adjuster Andrea Acevedo conducted a visual inspection. The complaint alleged she did not "inspect or view the pipe, or have a testing conducted on the pipe." Acevedo sent a letter denying the insureds' claim based upon her finding that "because the loss was caused by a slab leak, there is no coverage available for the loss." The letter explained that the hot water supply line under the home failed due to wear, tear, deterioration and/or electrolysis. The predominant cause of loss to the failed pipe was due to one or a combination of rust, electrolysis, corrosion, wear, tear and/or deterioration. The policy did not cover water damage caused by water from below the surface of the ground. Further coverage for wear, tear, deterioration, rot, mold, maintenance, water from below the surface of the ground and a continuous or repeated seepage or leakage of water was excluded.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Newmeyer Dillion Attorneys Named to 2022 Southern California Rising Stars List
June 13, 2022 —
Newmeyer DillionNEWPORT BEACH, Calif. – June 8, 2022 – Prominent business and real estate law firm Newmeyer Dillion is pleased to announce that partner
Jason Moberly Caruso and associate
Jessica Garland Daley have been selected to the 2022 Southern California Rising Stars list by Super Lawyers. Each year, no more than 2.5 percent of the lawyers in the state are selected to receive this honor. The attorneys will be recognized in the June 2022 issues of Super Lawyers Magazine, Los Angeles Magazine and Orange Coast Magazine.
Jason Moberly Caruso is a partner in the Newport Beach office. Jason's practice focuses on land use, "contaminated sites" environmental legal work, complex litigation, and appellate matters. This is the fifth consecutive year Jason has been honored.
Jessica Garland Daley is an associate in the Newport Beach office. Jessica's practice focuses on litigation in the areas of employment law and construction law. This is the first year Jessica has been selected.
About Newmeyer Dillion
For over 35 years, Newmeyer Dillion has delivered creative and outstanding legal solutions and trial results that achieve client objectives in diverse industries. With over 60 attorneys working as a cohesive team to represent clients in all aspects of business, employment, real estate, environmental/land use, privacy & data security and insurance law, Newmeyer Dillion delivers holistic and integrated legal services tailored to propel each client's operations, growth, and profits. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California and Nevada, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949.854.7000 or visit www.newmeyerdillion.com.
Read the court decisionRead the full story...Reprinted courtesy of
Unlicensed Contractors Nabbed in Sting Operation
September 09, 2011 —
CDJ STAFFThe California State License Board charged sixteen people in the Fresno area with accepting contracting jobs without licenses. The Statewide Investigative Fraud Team of the CSLB set up a sting operation at a home in Clovis, California seeking bids on tree service, painting, and general contracting services. Those who bid for jobs at more than $500 are required under California law to be licensed. Unlicensed contractors can only work on jobs with a cost to the homeowner of less than $500 and must inform the homeowner that they are not licensed.
In addition to citing contractors for not possessing appropriate licenses, the CSLB also cited contractors for failure to carry workers compensation insurance and illegal advertising. Further, California law limits down payments to the lesser of ten percent or $1,000. Two contractors were cited for requesting excessive down payments.
One contractor, an unlicensed tree service contractor, had been cited previously in a sting operation. He failed to show up for his court date.
Read the full story…
Read the court decisionRead the full story...Reprinted courtesy of
