Differences in Types of Damages Matter
June 22, 2016 —
Christopher G. Hill – Construction Law MusingsOver the last 7 and a half years (yes I have been doing this for that long), I have often “mused” on various contractual provisions and their application. Why? Because
the contract matters and will be enforced. Provisions like “no damages for delay” and “
pay if paid” litter construction contracts and will be enforced if properly drafted. These types of clauses affect whether and what types of damages you as a construction company can collect.
Of course, these clauses have their limitations. For instance, and as
pointed out by my pal Matt DeVries at his great Best Practices Construction Law blog, not all damages that a subcontractor or general contractor may attribute to coordination or other scheduling related issues are “delay damages” to which a “no damages for delay” clause may apply.
Read the court decisionRead the full story...Reprinted courtesy of
Christopher G. Hill, Law Office of Christopher G. Hill, PCMr. Hill may be contacted at
chrisghill@constructionlawva.com
Florida’s New Civil Remedies Act – Bulletpoints As to How It Impacts Construction
April 10, 2023 —
David Adelstein - Florida Construction Legal UpdatesThere has been much talk about Florida’s new Civil Remedies Act (
House Bill 837) that Governor DeSantis approved on March 24, 2023. As it pertains to construction, here is how I see it with key bulletpoints on the impact this new Act has on the construction industry:
- New Florida Statute s. 86.121 – This is an attorney’s fees statute for declaratory relief actions to the prevailing insured to determine insurance coverage after TOTAL COVERAGE DENIAL. (Note: A defense offered pursuant to a reservation of rights is not a total coverage denial.) This right only belongs to the insured and cannot be transferred or assigned. And the parties are entitled to the summary procedure set forth in Florida Statute s. 51.011 requiring the court to advance the cause on the calendar. The new statute does say it does NOT apply to any action arising under a residential or commercial property insurance policy. (Thus, since builder’s risk coverage is a form of property insurance, the strong presumption is this new statute would not apply to it.) Rather, the recent changes to Florida Statute s. 626.9373 would apply which provides, “In any suit arising under a residential or commercial property insurance policy, there is no right to attorney fees under this section.”
- Florida Statute s. 95.11 – The statute of limitations for negligence causes of action are two years instead of four years. This applies to “causes of action accruing after the effective date of this act.”
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
What Every Project Participant Needs to Know About Delay Claims
August 05, 2024 —
Andrew G. Vicknair - The Dispute ResolverA “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays.
I. Types of Delays
Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule.
Read the court decisionRead the full story...Reprinted courtesy of
Andrew G. Vicknair, D'Arcy Vicknair, LLCMr. Vicknair may be contacted at
agv@darcyvicknair.com
Checking the Status of your Contractor License During Contract Work is a Necessity: The Expanded “Substantial Compliance” under B&P 7031 is Here
June 05, 2017 —
Ivo G. Daniele – Newmeyer & Dillion LLP News AlertIt is paramount that a contractor diligently maintains its license prior to and during the performance of any contract work. Failure to do so could result in barring a contractor from receiving payment and/or disgorgement of profits received under the construction contract.
California Business and Professions Code section 7031 is part of the Contractors State License Law (Business & Prof. section 700 et seq.), and is both feared and loathed by all contractors performing work in the state of California. This draconian statute is known as the “Shield” and was enacted over 70 years ago for the singular purpose to bar all actions by contractors seeking compensation for unlicensed contract work – even precluding a contractor from enforcing his or her mechanic’s lien rights. However, a contractor could potentially avoid the harshness of B&P 7031 by establishing that he or she had substantially complied with the appropriate licensing requirements.
SUBSTANTIAL COMPLIANCE WITH LICENSE REQUIREMENTS PRIOR TO 2017 AMENDMENT
The substantial compliance exception is found in section B&P 7031(e), which authorizes the court to determine that there has been substantial compliance with licensure requirements, if the contractor has shown at an evidentiary hearing that he or she engaged in the unlicensed work had:
- Been duly licensed as a contractor in this state prior to the performance of the act or contract;
- Acted reasonably and in good faith to maintain the license;
- Did not know or reasonably should not have known that he or she was not licensed when he or she performed the work; and
- Acted promptly and in good faith to reinstate the license once it learned the license had lapsed.
Although not impossible, satisfying all four requirements of the exception was challenging for the contractor, specifically, requirement # (3) – the lack of knowledge that he or she was unlicensed during performance of work.
SUBSTANTIAL COMPLIANCE POST 2017
Fortunately, Governor Brown heard the collective cry for relief and signed Assembly Bill 1793 (“AB 1793”) into law. The new bill revises the criteria for the court to determine if a contractor is in substantial compliance with the licensing requirements by deleting requirement # (3) in its entirety and modestly amending requirement # (4) to require the contractor to act promptly and in good faith to remedy the failure to comply with the licensure requirements upon learning of the failure.
As a result, the substantial compliance exception under B&P 7031(e) reads as follows:
(e) The judicial doctrine of substantial compliance shall not apply under this section where the person who engaged in the business or acted in the capacity of a contractor has never been a duly licensed contractor in this state. However, notwithstanding subdivision (b) of Section 143, the court may determine that there has been substantial compliance with licensure requirements under this section if it is shown at an evidentiary hearing that the person who engaged in the business or acted in the capacity of a contractor
(1) had been duly licensed as a contractor in this state prior to the performance of the act or contract, (2) acted reasonably and in good faith to maintain proper licensure, and (3) acted promptly and in good faith to remedy the failure to comply with the licensure requirements upon learning of the failure.
This new legislation has tempered the burden of proof born by the contractor in establishing substantial compliance, although be it minor in its modification, the fact of the matter remains the same – be diligent in maintaining your license during all phases of contract work.
Ivo Daniele is a seasoned associate in the Walnut Creek office focusing his practice on commercial transactions and business and construction litigation. For questions regarding California Business and Professions Code section 7031, please feel free to contact Ivo Daniele at (925) 988-3222 or ivo.daniele@ndlf.com.
About Newmeyer & Dillion
For more than 30 years, Newmeyer & Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of business, employment, real estate, construction and insurance law, Newmeyer & Dillion delivers legal services tailored to meet each client’s needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer & Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949-854-7000 or visit www.ndlf.com.
Read the court decisionRead the full story...Reprinted courtesy of
Diggin’ Ain’t Easy: Remember to Give Notice Before You Excavate in California
February 15, 2018 —
Matthew Peng – Construction Law Blog If you are reading this blog, my guess is that you know what excavation is and why it is important to the construction process. However, what you may not know is the complicated California law that governs this process. The statute for an excavation contractor to be familiar with is California Government Code section 4216,
et seq. However, like most things worth pursuing, that is easier said than done. Section 4216 contains several layers of prerequisites and requirements. This article will explore the notice requirement.
Section 4216.1 requires “every operator of a subsurface installation” to share costs of a regional notification center. This is necessary because Section 4216.2(b) requires “an excavator planning to conduct an excavation shall notify the appropriate regional notification center of the excavator’s intent to excavate” before beginning that excavation. The statute lists two regional notification centers: the Underground Service Alert—Northern California and the Under Ground Service Alert—Southern California.
Read the court decisionRead the full story...Reprinted courtesy of
Matthew Peng, Gordon & ReesMr. Peng may be contacted at
mpeng@grsm.com
The Job is Substantially Complete, the Subcontract was Never Signed, the Subcontractor Wants to be Paid—Now What?
July 28, 2016 —
John P. Ahlers – Ahlers & Cressman PLLCA recent case in North Carolina illustrates the types of problems created when a general contractor accepts a subcontractor’s bid and then allows the subcontractor to perform the work without obtaining a signed subcontract.[i] In this case, the general contractor (Choate Construction Company – “Choate”) accepted a bid from a foundation subcontractor (Southeast Caissons, LLC – “SEC”). Choate sent the subcontract to SEC. SEC provided its changes in a “Proposed Addendum” to the subcontract stating, “[SEC] hereby accepts the terms of the attached Subcontract, subject to and conditioned upon Choate[’s] acceptance of the terms set forth in this Addendum[.]” After that, Choate called SEC and exchanged emails concerning the subcontract terms, but did not reach an agreement. SEC then performed its subcontract and sought payment, and acknowledged it had not signed the subcontract. Choate agreed it owed SEC something, but refused to pay because SEC did not have a signed subcontract, asserting the subcontract was not binding on Choate.
Read the court decisionRead the full story...Reprinted courtesy of
John P. Ahlers, Ahlers & Cressman PLLCMr. Ahlers may be contacted at
jahlers@ac-lawyers.com
New Jersey Court Adopts Continuous Trigger for Construction Defect Claims
November 15, 2017 —
Tred R. Eyerly - Insurance Law HawaiiThe New Jersey Superior Court, Appellate Division, adopted the continuous trigger for establishing which insurers were on the risk for construction defect claims. Air Master & Cooling, Inc. v. Selective Ins. Co. of Am., 2017 N.J. Super. LEXIS 144 (N.J. Super. Ct., App. Div. Oct. 10, 2017).
The insured, Air Master, worked as a subcontractor on the construction of a condominium building. Air Master performed HVAC work in the building between November 2005 and April 2008. Air Master's work consisted of installing condenser units on rails on the building's roof, and also HVAC devices within each individual unit.
Starting in early 2008, some of the unit owners began to notice water infiltration and damage in their windows, ceilings, and other portions of their units. On April 29, 2010, an expert consultant, Jersey Infrared Consultants, performed a moisture survey of the roof for water damage. A report identified 111 spots on the roof damaged by moisture from water infiltration. The report noted it was impossible to determine when moisture infiltration occurred. The expert recommended that these damaged areas of the roof be removed and replaced.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
BWB&O Attorneys are Selected to 2024 Southern California Super Lawyers Rising Stars
July 22, 2024 —
Bremer Whyte Brown & O'Meara LLPBWB&O is proud to announce Senior Family Law Associate Pamchal Deylami, Newport Beach Partner Kyle Riddles, Newport Beach Partner Courtney Serrato, Newport Beach Associate Kevin Moore, Woodland Hills Associate Brian Taylor have been selected to the 2024 Southern California Super Lawyers list as Rising Stars for their work in Family Law, Civil Litigation, Business Litigation, and Personal Injury.
SELECTED AS RISING STARS
Pamchal Deylami: 2020-2024
Kyle Riddles: 2024
Courtney Serrato: 2023-2024
Kevin Moore: 2021-2024
Brian Taylor: 2023-2024
Read the court decisionRead the full story...Reprinted courtesy of
Bremer Whyte Brown & O'Meara LLP
