CAMBRIDGE MASSACHUSETTS BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season

January 13, 2020 — David Adelstein - Florida Construction Legal Updates
There are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be. For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:

[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season. Meridian Engineering, 2019 WL at *7 (internal citations omitted)

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Accident/Occurrence Requirement Does not Preclude Coverage for Vicarious Liability or Negligent Supervision

June 06, 2018 — Christopher Kendrick & Valerie A. Moore - Haight Brown & Bonesteel, LLP
In Liberty Surplus Ins. Corp. v. Ledesma & Meyer Construction Co., Inc. (No. S236765, filed 6/4/18) (L&M), the California Supreme Court ruled that the liability insurance requirement that injury be caused by an “occurrence,” defined as an “accident,” does not preclude coverage of an employer’s independent tort liability for injury deliberately caused by its employee. In L&M, Liberty insured a construction company that contracted to manage a construction project at a middle school in San Bernardino, California. A 13-year-old student subsequently sued the company in state court, alleging that she had been sexually molested by a company employee, Hecht. Among others, she alleged a cause of action for negligent hiring, retention and supervision of the employee. The construction company tendered to Liberty, which defended the employer under a reservation of rights while seeking declaratory relief in federal court. The district court granted summary judgment for Liberty, ruling that the injury was not caused by an “occurrence.” On appeal, the 9th Circuit Court of Appeals certified the question to the California Supreme Court as a matter of state law. Reprinted courtesy of Christopher Kendrick, Haight Brown & Bonesteel LLP and Valerie A. Moore, Haight Brown & Bonesteel LLP Mr. Kendrick may be contacted at ckendrick@hbblaw.com Ms. Moore may be contacted at vmoore@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Arizona Court Cites California Courts to Determine Construction Defect Coverage is Time Barred

December 30, 2013 — CDJ STAFF
Construction defect claims in an Arizona community are time barred and so the judge had determined that National Fire & Marine Insurance is not liable for coverage. National Fire claimed that while there was no Arizona case law concerning statutes of limitations for equitable contributions by insurance carriers, the court agreed that “its position is directly supported by cases from other jurisdictions.” In the underlying construction defect case, Steadfast Insurance had settled with homeowners over allegations of construction defects. National Fire was a co-insurer and declined coverage. National Fire’s citing of two California cases was not unique for the Arizona courts. Other Arizona cases cited the same two California cases. Read the court decision
Read the full story...
Reprinted courtesy of

---

Quick Note: Can a Party Disclaim Liability in their Contract to Fraud?

April 11, 2022 — David Adelstein - Florida Construction Legal Updates
It is possible for a party to contractually disclaim or otherwise foreclose liability to a fraud claim. However, let’s be honest. It can be done, but rarely is and would require very specific language to EXPLICITLY disclaim or foreclose such liability to a fraud claim. A recent case, discussed here, exemplifies this point where as-is language in a purchase-and-sale agreement was NOT specific to contractually foreclose or disclaim liability to a fraud claim. For a party to contractually waive a fraud claim, there needs to be an express waiver of liability for fraud that might have been made and that any fraudulent misrepresentation, if such fraud was committed, was disclaimed and would not destroy the validity of the parties’ contract. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Some Coastal Cities Are Sinking Even Faster Than Seas Are Rising

June 20, 2022 — Ditas B Lopez - Bloomberg
Rising seas have long been a threat to coastal cities. New research suggests that cities—particularly in Asia—are sinking as well, compounding the risks of frequent and severe flooding. In Karachi, land is sinking five times as fast as the sea level is rising, according to the study published this month in Geophysical Research Letters. Manila and Chittagong, Bangladesh’s second-largest city, are sinking at 10 times the rate of the rising waters. In China’s Tianjin, a coastal city about 150 kilometers southeast of Beijing, the ground is giving way at 20 times that speed. In those four cities alone, the phenomenon could affect roughly 59 million residents. Read the court decision
Read the full story...
Reprinted courtesy of Ditas B Lopez, Bloomberg

---

Reversing Itself, West Virginia Supreme Court Holds Construction Defects Are Covered

July 31, 2013 — Tred Eyerly, Insurance Law Hawaii
The West Virginia Supreme Court previously held that construction defects were not covered under a CGL policy. The Court, however, reversed itself in Cherrington v. Erie Ins. Prop. & Cas. Co., 2013 W.Va. LEXIS 724 (W.V. June 18, 2013). The underlying complaint against the general contractor alleged various defects in the plaintiff’s recently constructed house, including an uneven concrete floor, water infiltration through the roof and chimney joint, a sagging support beam, and numerous cracks in the drywall walls and partitions throughout the house. Erie Insurance denied coverage. The insured general contractor sued, but the trial court found that faulty workmanship was not sufficient to give rise to an “occurrence.” The West Virginia Supreme Court reversed its prior rulings determining there was no coverage for construction defects. The court recognized its prior position was in the minority, as is Hawaii's position on coverage for construction defects. See Group Builders Inc. v. Admiral Ins. Co., 123 Haw. 142, 148, 231 P.3d 67, 73 (Haw. Ct. App. 2010). Now joining the majority position, the West Virginia Supreme Court found that defective workmanship causing property damage was an “occurrence” under a CGL policy. Further, the homeowner had demonstrated that she sustained "property damage" as a result of the allegedly defective construction of her home. The trial court also determined that the business risk exclusions barred coverage. Again, the West Virginia Supreme Court disagreed. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Tred Eyerly can be contacted at te@hawaiilawyer.com

---

Manhattan to Get Tall, Skinny Tower

October 21, 2013 — CDJ STAFF
At its narrowest, it’s going to be only sixty feet wide. And that will run 1,350 feet into the air. A new apartment tower is going up in New York, and one of its amenities will be that residents in the top floors will be able to look down on the Empire State Building. “It may be the skinniest building ever,” said Gregg Pasquarelli, the principal of SHoP Architects, the firm that designed the building. He estimates its ratio of height to width as “something like 25-to-1.” For all its height, the building will be divided into about 100 units. As part of the development deal, the tower will incorporate and preserve the landmark Steinway Hall. The chair of the Landmarks Preservation Commission, Robert Tierney, described it as “the best of both worlds of new construction and design and historic preservation.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Don’t Miss the 2015 West Coast Casualty Construction Defect Seminar

April 01, 2015 — Beverley BevenFlorez-CDJ STAFF
The 22nd West Coast Casualty (WCC) Construction Defect Seminar returning to the Disneyland Hotel in Anaheim, California is just six weeks away. The annual event begins on Thursday, May 14th, with breakfast and registration starting at 7:30am. Panel discussions on various construction defect related topics begin at 8:30am and continue through the morning and afternoon, followed by a cocktail reception in the early evening. The following day includes break-out sessions with the event concluding in the afternoon. Attendees can enhance their seminar experience with the WCC Construction Defect Seminar Mobile App. The event schedule, speaker information, product information, sponsor details, and interactive floorplan can all be accessed through the app. Furthermore, registered attendees will have access to session presentations. The discounted, early registration ends April 15th, 2015. Download an Invitation and Register for the Event... Read the court decision
Read the full story...
Reprinted courtesy of

---