Seattle Washington Building Expert Directory

Is The Enforceability Of A No-Damage-For-Delay Provision Inappropriate For Summary Judgment

February 24, 2020 — David Adelstein - Florida Construction Legal Updates
Is the enforceability of a no-damage-for-delay provision inappropriate for resolution on a summary judgment? The recent decision in U.S. f/u/b/o Kingston Environmental Services, Inc. v. David Boland, Inc., 2019 WL 6178676 (D. Hawaii 2019), dealing with Florida law, suggests that it is inappropriate for a summary judgment resolution, particularly when there is a right to a jury trial. In this case, a prime contractor was hired on a federal construction project in Hawaii. The prime contractor hired a subcontractor and the subcontractor sued the prime contractor and its surety under the Miller Act. Of interest, the subcontractor was seeking to recover for the costs it incurred due to construction delays. The prime contractor moved for summary judgment as to the no-damage-for-delay provision in the subcontract. The no-damages-for-delay provision read as follows (and it is a well-written no-damage-for-delay provision): The Subcontractor expressly agrees that the Contractor shall not be liable to the Subcontractor for any damages or additional costs, whether foreseeable or unforeseeable, resulting in whole or in part from a delay, hindrance, suspension, or acceleration of the commencement or execution of the Work, caused in whole or in part by the acts or omissions, whether negligent or not, of the Contractor including other subcontractors or material suppliers to the Project, its agents, employees, or third parties acting on behalf of the Contractor. The Subcontractor’s sole remedy for any such delay, hindrance, suspension, or acceleration shall be a noncompensable time extension. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Hudson River PCB Cleanup Lands Back in Court

September 03, 2019 — Mary B. Powers - Engineering News-Record
As it previously had warned, New York state on Aug. 21 filed a federal lawsuit against the U.S. Environmental Protection Agency seeking to reverse its certification that General Electric Co.'s removal of PCBs from the Hudson River was complete, despite the agency’s five-year review finding that the cleanup was not adequate to protect human health and the environment. Read the court decision
Read the full story...
Reprinted courtesy of Mary B. Powers, ENR
ENR may be contacted at ENR.com@bnpmedia.com

Locals Concerns over Taylor Swift’s Seawall Misdirected

January 13, 2014 — CDJ STAFF
Homeowners in Westerly, Rhode Island have been concerned about alterations made to a seawall below Taylor Swift’s seaside home in Rhode Island, particularly in that some large boulders have been moved to the shore. But officials with Rhode Island’s Coastal Resource Management Council have assured residents that the work is being done at their request, according to the Westerly Sun. In addition to moving boulders, the project repairs an existing seawall which was damaged by Hurricane Sandy. The cost is estimated to be $2 million. Read the court decision
Read the full story...
Reprinted courtesy of

Florida Supreme Court: Notice of Right to Repair is a CGL “Suit,” SDV Amicus Brief Supports Decision

January 10, 2018 — Gregory Podolak & Brian Clifford - SD&V Case Alert
Construction policyholders in Florida have been given substantial ammunition to compel general liability insurers to provide a defense against pre-suit accusations of defective work. Florida is one of approximately thirty (30) states that require property owners to serve contractors with notice and an opportunity to repair construction defects before filing suit. Only a few states have addressed whether a CGL policy should provide a defense for similar processes. Altman Contractors, Inc. v. Crum & Forster Specialty Ins. Co., decided late in December by the Florida Supreme Court, acknowledged that the 558 process is a “suit,” thus impeding insurers from refusing a defense during this notice period. Section 558.004(1), Florida Statutes (2012) requires a property owner alleging construction defects to serve a written notice to repair on the contractor before filing an action in court. Altman Contractors built a condominium in Broward County, Florida. In 2012, the condominium owners alleged defects in accordance with Section 558. Altman demanded that its general liability carrier, Crum & Forster, defend and indemnify it against the 558 notices. Crum & Forster denied coverage, claiming that 558 notices are not a “suit” as defined by the policy. Reprinted courtesy of Gregory Podolak, Saxe Doernberger & Vita, P.C. and Brian Clifford, Saxe Doernberger & Vita, P.C. Mr. Podolak may be contacted at gdp@sdvlaw.com Mr. Clifford may be contacted at bjc@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

New Jersey Traffic Circle to be Eliminated after 12 Years of Discussion

February 04, 2014 — Beverley BevenFlorez-CDJ STAFF
The online publication New Jersey.com reported that on February 6th a “Pre-Construction Public Information hearing” will be held in Little Ferry, New Jersey, to discuss “the upcoming Route 46 Circle Elimination construction project.” The project includes “installation of a storm water pump station” as well as reconfiguring the circle into “a conventional four-way signalized intersection with a brand new traffic signal.” Conti Enterprises of Edison was awarded the bid “at a cost of $33,837,739,” according to New Jersey.com. The project, which has been discussed for over a decade, stalled over combining the elimination of the traffic school with rehabilitation of a bridge. Improvements include “replacing of the entire bridge deck, structural steel member replacement and strengthening, sidewalk replacement on both sides of the structure and substructure patching, crack sealing and reconstruction where needed.” The informational meeting will introduce the public to the engineer and contractor for the project. "This information session will help residents learn more about the project and what to expect as the state undertakes this work," Little Ferry Mayor Mauro Raguseo told New Jersey.com. "I wish we could fast forward to the completion of the project so we can realize the benefits without the headaches, but that's not reality. We all need to be prepared." Read the court decision
Read the full story...
Reprinted courtesy of

Defining Construction Defects

February 04, 2013 — CDJ STAFF
Joseph M. Junfola has started a series at PropertyCasualty360.com on construction defect, and as is appropriate with an in-depth look, he starts by defining the central terms. What is a construction defect? What is a construction defect claim? Junfola notes that "there is no one uniform definition in all jurisdictions," and so he looks at the commonalities to "fashion at least a working definition." Nevada says that a construction defect "includes a defect in the design, construction, manufacture, repair or landscaping of a new residence, of an alteration of or an addition to an existing residence, or of an appurtenance." According to Florida it is "a deficiency in, or a deficiency arising of, the design, specifications, surveying, planning, supervision, observation of construction, or construction, repair, alteration, or remodeling of real property." He continues that a construction defect claim is "a claim for damages, i.e. money, arising out of a defect in construction, including defective design, faulty workmanship, and defective materials," but he notes that this is typically pursuant to the discovery of the problem within a given time. Read the court decision
Read the full story...
Reprinted courtesy of

Force Majeure, Construction Delays, Labor Shortages and COVID-19

April 06, 2020 — Elizabeth J. Dye - Gravel2Gavel Construction & Real Estate Law Blog
The global effect of the Coronavirus disease (COVID-19) is still unknown, and the progress of many large-scale construction projects has been affected by “Shelter in Place” orders, although some states and localities have classified construction projects as “essential.” Just last Friday, New York shut down all construction, with few exceptions. Several states have enacted gathering bans of all sizes (including Michigan, Oregon, New Mexico, Washington, New York, New Jersey, Wisconsin, Illinois, Indiana, Ohio, West Virginia, California) and more people are likely to be quarantined as widespread testing becomes available. These decisions will undoubtedly affect the supply of materials and labor necessary for construction projects. Officials have turned to increasingly disruptive and measures to control the spread of the virus in addition to event prohibitions and school closures, including restricting people to their homes, and closing businesses that are not “essential.” While many companies have adopted mandatory telecommuting, this is an impossibility on the construction sites. Eventually, supply and labor shortages due to governmental restrictions or quarantines will affect the critical path of construction projects. Read the court decision
Read the full story...
Reprinted courtesy of Elizabeth J. Dye, Pillsbury
Ms. Dye may be contacted at elizabeth.dye@pillsburylaw.com

Floors Collapse at Russian University in St. Petersburg

February 27, 2019 — The Associated Press - Bloomberg
St. Petersburg, Russia (AP) -- Part of the roof and several floors of university building in Russia's second-largest city collapsed Saturday, but officials say there were no casualties. The Emergencies Ministry said the collapse at the Saint Petersburg National Research University of Information Technologies, Mechanics and Optics took place as construction work was underway. An investigation into criminal violation of construction safety has been opened. Read the court decision
Read the full story...
Reprinted courtesy of The Associated Press, Bloomberg

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES