FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Delays and Suspension of the Work Under Fixed Price Government Contract

July 22, 2024 — David Adelstein - Florida Construction Legal Updates
Here is an interesting fact pattern and case decided by the Civilian Board of Contract Appeals dealing with (1) force majeure type events and epidemics (Covid-19); (2) suspension of the work; and (3) delays. These are three topics important to all contractors including federal contractors. In Lusk Mechanical Contractors, Inc. v General Services Administration, 2024 WL 1953697, CBCA 7759 (CBCA 2024), a contractor entered into a fixed price contract with the government to repair, replace, and modernize site and building systems at a federal building. The contractor commenced work right before Covid-19. When Covid-19 hit, the government issued the contractor a two-week suspension of work notice on March 27, 2020. The suspension of work allowed off-site administrative work to continue but suspended on-site physical work. The government extended the suspension of work three more times. The contractor could resume work on the exterior on June 1, 2020, but was not permitted to resume work on the interior until July 20, 2020. On the same date that the contractor was able to commence interior work, it submitted a modification for delay caused by the suspension – 64 days for the time period the entire site shutdown, and 51 days for the interior work shutdown. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Wait, You Want An HOA?! Restricting Implied Common-Interest Communities

September 17, 2018 — Neil McConomy - Snell & Wilmer Real Estate Litigation Blog
While the butt of many jokes and a thorn in the side of some property owners, homeowners associations (“HOAs”) serve the vital function of collecting and disbursing funds to care for and maintain common areas of residential developments. Without HOAs, neighborhood open spaces, parks, and other amenities risk falling into disrepair through a type of tragedy of the commons, wherein residents use such amenities but refuse to subsidize care and maintenance for these common areas believing someone else will pony-up the funds. HOAs, when properly organized and managed, avoid this problem by ensuring everyone pays their fair shares for the common areas. Colorado’s Common Interest Ownership Act (“CCIOA”), C.R.S. § 38-33.3-101 et seq., sets forth the manner in which such common-interest communities, and their related associations, must be established. Earlier this summer, the Colorado Supreme Court issued an opinion limiting the application of previous case law that allowed for the establishment of common-interest communities (and their related HOAs) by implication. See McMullin v. Hauer, 420 P.3d 271 (Colo. 2018). Prior to McMullin, Colorado courts had been increasing the number of factual scenarios implying the creation of common-interest communities under CCIOA. See e.g., Evergreen Highlands Assoc. v. West, 73 P.3d 1 (Colo. 2003) (finding an implied obligation of landowners to fund a pre-existing HOA’s obligations); DeJean v. Grosz, 412 P.3d 733 (Colo. App. 2015) (finding an implied right of a homeowner to found an HOA after the developer filed a declaration expressing an intent to form one but ultimately failed to do so); and Hiwan Homeowners Assoc. v. Knotts, 215 P.3d 1271 (Colo. App. 2009) (finding the existence of an HOA despite no common property existing within the development). The McMullin opinion highlights the importance of strict compliance with CCIOA to preserve common areas in a development, ensure the ability to fund maintenance of such areas, and avoid future litigation. Read the court decision
Read the full story...
Reprinted courtesy of Neil McConomy, Snell & Wilmer
Mr. McConomy may be contacted at nmcconomy@swlaw.com

---

Reasonableness of Liquidated Damages Determined at Time of Contract (or, You Can’t Look Back Again)

October 05, 2020 — Christopher G. Hill - Construction Law Musings
I’ve discussed the continuing litigation between White Oak Power Constructors v. Mitsubishi Hitachi Power Systems Americas, Inc. previously here at Construction Law Musings because the case was another reminder that your construction contract terms matter and will be interpreted strictly here in the Commonwealth of Virginia. The prior opinion in this case from the Eastern District of Virginia court the Court considered the applicability of a liquidated damages provision. In the latest opinion from the Court (PDF) the Court looked at when and how any liquidated damages would be calculated. In its June 22, 2020 opinion, the Court put the issue as follows:

White Oak’s motion for partial summary judgment presents a narrow issue: whether courts may consider the damages actually sustained by a party as a result of a contract breach when deciding if liquidated damages required by a contract “grossly exceed” a party’s actual damages.

Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

Condominium Association Responsibility to Resolve Construction Defect Claims

July 23, 2014 — Nicholas D. Cowie – Maryland Condo Construction Defect Law Blog
The Maryland Court of Special Appeals recently issued an opinion in Greenstein v. Council of Unit Owners of Avalon Court Six Condominium Inc. finding that an association can be sued by its unit owner members if it fails to take timely legal action against a developer. In that case, the association was aware of construction defects, but failed to take action to preserve its claim and then filed a lawsuit against the developer too late, after the statute of limitations expired. As a result, the suit against the developer was dismissed and the association was forced to assess its unit owner members for the $1 million in repair costs. Some of the unit owners then sued their association, seeking to recover the cost of their assessments on the ground that the association was negligent in failing to pursue a timely legal action against the developer. On appeal, the court was asked to decide whether state law permits owners to sue their condominium association for negligently failing to sue a developer for common element construction defects. The court, in an unpublished opinion, found that an association could be held liable to its members. The court said: “The duty to maintain, repair and replace the common elements together with the exclusive right to initiate litigation regarding the common elements [which was stated in a provision of the association’s bylaws] creates a concomitant obligation on the part of the [association] to pursue recovery from [the developer] on behalf of [the unit owners] for damage to the common elements caused by [the developer’s] negligence, breach of contract or violation of any applicable law.” Read the court decision
Read the full story...
Reprinted courtesy of Nicholas D. Cowie, Maryland Condo Construction Defect Law Blog
Mr. Cowie may be contacted at ndc@cowiemott.com

---

St Louis County Approves Settlement in Wrongful Death Suit

August 13, 2014 — Beverley BevenFlorez-CDJ STAFF
According to the StarTribune, the St Louis County Board agreed to pay $100,000 to settle with the family of a teenager who had been killed in a car crash. The family purported that “an improperly placed road construction sign contributed to the accident that caused her death.” Defendants in the suit included the county, Benchmark Engineering, and Jola & Sopp Excavating. The county board settled, but denied liability. Read the court decision
Read the full story...
Reprinted courtesy of

---

Apartment Investors Turn to Suburbs After Crowding Cities

March 12, 2015 — Nadja Brandt and Oshrat Carmiel – Bloomberg
(Bloomberg) -- Real estate investor Robert Hart pulled into the lot of a 400-unit apartment community in a San Diego suburb last month, prepared to pay up for the recently completed project on a quiet residential street. A competitor from a publicly traded landlord was already there, he said. “It was on the one hand reassuring to know that we were both chasing the same opportunity,” said Hart, president and chief executive officer of closely held TruAmerica Multifamily. “On the other hand, it reinforced my opinion that large institutional real estate investors will be chasing yield far beyond the urban core.” Reprinted courtesy of Nadja Brandt, Bloomberg and Oshrat Carmiel, Bloomberg Ms. Brandt may be contacted at nbrandt@bloomberg.net Ms. Carmiel may be contacted at ocarmiel1@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of

---

Application of Set-Off When a Defendant Settles in Multiparty Construction Dispute

January 05, 2017 — David Adelstein – Florida Construction Legal Updates
The defense of set-off is an important defense in construction disputes, particularly multiparty disputes. For more information on this defense, please check out this article as it explains the application of set-off in civil disputes in detail. The issue of set-off will come up in a multiparty dispute when a plaintiff settles with one or more of the defendants. The remaining defendant(s) wants the benefit of that settlement to set-off and reduce any judgment against it. An example of this scenario can be found in Escadote I Corp. v. Ocean Three Limited Partnership, 42 Fla. L. Weekly D23a (Fla. 3d DCA 2016). In this case, an owner of a condominium unit sued the condominium association, the developer, and the general contractor for water intrusion and mold infestation. The claim against the condominium association was the only claim that entitled the owner to attorney’s fees pursuant to its lawsuit (thus, attorney’s fees were isolated to only that claim against the association). During trial, the owner settled with the association. In entering a settlement, the owner smartly allocated the settlement amount such that $500 was allocated to its principal damages and $374,500 was allocated to its attorney’s fees. The owner then obtained a jury verdict against the contractor and developer for approximately $2M, jointly and severally, and the contractor and developer wanted the entire $375,000 settlement amount with the association to be set-off from the $2M verdict. The trial court set-off the entire $375,000 from the jury verdict when entering judgment. The appellate court reversed. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dma@katzbarron.com

---

Commonwealth Court Strikes Blow to Philly Window and Door Ordinance

January 05, 2017 — Wally Zimolong – Supplemental Conditions
On December 22, 2016, the Pennsylvania Commonwealth Court issued an important opinion that has flown under the radar somewhat. The case Rufo v. Board of Licenses and Inspection Review, invalidates a major portion of Philadelphia’s so called windows and doors ordinance, which requires owners of vacant properties to install glass windows and doors with frames on vacant properties. A copy of the opinion can be found here. (I only learned about the case because of a tweet by a litigator with the pro-freedom group the Institute for Justice.) The Windows and Doors Ordinance The case concerns Section 306.2 of the Property Maintenance Code which requires “the owner of a vacant building that is a blighting influence, as defined in this subcode, [to] secure all spaces designed as windows with windows that have frames and glazing and all entryways with doors.” Property owners found in violation of the ordinance can face stiff fines. Property owners are subject to a daily fine for each door and window in violation of the Ordinance. The fine is $300 per window or door. However, because most vacant properties have multiple windows and doors the fines can add up exponentially. Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

---