Fairfield Connecticut Building Expert Directory

Recovering Unabsorbed Home Office Overhead Due to Delay

May 30, 2022 — David Adelstein - Florida Construction Legal Updates
In the preceding article, I discussed the use of a retrospective as-built delay analysis in a case before the Civilian Board of Contract Appeals (CBCA). This case also discussed a damages component in certain delay claims known as unabsorbed home office overhead—a challenging damages component to recover because this deals with indirect costs as opposed to direct costs. Unabsorbed home office overhead is a damages component when the contractor is on standby, but this is NOT as easy as just claiming standby thereby you are automatically entitled to unabsorbed home office overhead. There are requirements that MUST be met.

To obtain an equitable adjustment for unabsorbed home office overhead as compensation for being on standby, [the contractor] must initially show “[1] a government-caused delay of uncertain duration,” that “[2] the delay extended the original time for performance” or precluded the contractor from finishing earlier than scheduled, and that “[3] the contractor [was] on standby and unable to take on other work during the delay period. CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022) quoting Nicon, Inc. v. U.S., 331 F.3d 878, 883 (Fed. Cir. 2003).

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Alexander Moore Promoted to Managing Partner of Kahana Feld’s Oakland Office

May 08, 2023 — Alexander R. Moore - Kahana Feld
Kahana Feld is pleased to announce that Alexander R. Moore, Esq., has been promoted to Managing Partner of our Oakland office. Mr. Moore has been at Kahana Feld since 2021 and is a member of the construction defect and general liability practice groups. Mr. Moore has over 23 years of experience representing individual and commercial clients in complex disputes arising out of construction contracts, construction defect allegations, premises liability matters, landlord-tenant disputes, and contractual disputes arising out of various business relationships involving financial services companies, technology companies, telecommunications companies, real estate brokerages, non-profits, and a range of small businesses. When not focused on litigation, Mr. Moore enjoys consulting on transactional matters including the development of construction and business contracts. He has extensive experience evaluating rights and obligations under construction contracts and related insurance programs. He also assists clients in the implementation of pre-litigation risk management strategies. Read the court decision
Read the full story...
Reprinted courtesy of Alexander R. Moore, Kahana Feld
Mr. Moore may be contacted at amoore@kahanafeld.com

Insurance Policies Broadly Defining “Suits” May Prompt an Insurer’s Duty to Defend and Indemnify During the Chapter 558 Pre-Suit Notice Process

May 30, 2018 — Daniel Garcia - Gordon & Rees Construction Law Blog
In Altman Contractors, Inc. v. Crum & Forster Specialty Insurance Company, No. SC16-1420, 2017 WL 6379535 (Fla. Dec. 14, 2017), the Florida Supreme Court addressed whether the notice and repair process set forth in chapter 558, Florida Statutes, constitutes a “suit” within the meaning of a commercial liability policy issued by Crum & Forster Specialty Insurance Company (“C&F”) to Altman Contractors, Inc. (“Altman”). The Court found that because the chapter 558 pre-suit process is an “alternative dispute resolution proceeding” as included in the definition of “suit” in the policy by C&F to Altman, C&F had a duty to defend Altman during the chapter 558 process, prior to the filing of a formal lawsuit. Chapter 558, titled “Construction Defects,” sets forth procedural requirements before a claimant may file a construction defect action. It requires a claimant to serve a written notice of claim on the applicable contractor, subcontractor, supplier, and/or design professional prior to filing a construction defect lawsuit. The legislature intended for Chapter 558 to be an alternative dispute resolution mechanism in certain construction defect matters allowing an opportunity to resolve the claim without further legal process. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Garcia, Gordon & Rees Scully Mansukhani
Mr. Garcia may be contacted at daniel.garcia@grsm.com

A Court-Side Seat: SCOTUS Clarifies Alien Tort Statute and WOTUS Is Revisited

July 11, 2021 — Anthony B. Cavender - Gravel2Gavel
What follows is a brief account of some of the notable U.S. environmental and administrative law cases recently decided. THE U.S. SUPREME COURT Nestle USA, Inc. et al. v. Doe, et al. The Supreme Court has decided another important case interpreting the Alien Tort Statute. Released on June 17, 2021, this decision reverses the Ninth Circuit which had ruled that the respondents—six individuals who alleged they were child slaves employed on Ivory Coast cocoa farms, could sue the American-based companies for aiding and abetting child slave labor. Without dissent, the Court rejected this reading of the ATS and affirmed its own recent rulings on the scope of the ATS. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

Small Airport to Grow with Tower

October 25, 2013 — CDJ STAFF
The city Hammond, Louisiana is finding that their airport just keeps getting busier. Mayson Foster, the mayor of Hammond noted that the city now has “various types of aircraft ranging from blimps, regional jets, smaller private planes, helicopters and other aircraft using the airport.” Spartan Construction Company has made a successful $1.6 million bid to build the tower. Funding will come from the sale of 17 acres of land near the airport. Air traffic at the Northshore Regional Airport is expected to increase after the tower becomes operational. Read the court decision
Read the full story...
Reprinted courtesy of

Contractors Should be Aware of Homeowner Duties When Invited to Perform Residential Work

September 26, 2022 — Joshua Lane - Ahlers Cressman & Sleight PLLC
Division 2 of the Court of Appeals[1] recently addressed a property owner’s liability to a contractor who is injured performing work on their property. The action arose from an incident in which Virgil Mihaila, a remodeling contractor, fell from a ladder while installing a new roof on the Troths’ shed and landed on a metal grounding rod that was sticking over a foot out of the ground. Mihaila saw the grounding rod as he was working and recognized the danger, but he claimed that he could not complete the roofing job without encountering it. Although he tried to position his ladder so that he would avoid the grounding rod if he fell, he somehow fell off the ladder and landed on the grounding rod, sustaining multiple rib fractures and a punctured lung. Mihaila filed a complaint against the Troths, alleging that they were negligent in failing to protect him from the danger of the grounding rod sticking out of the ground. The Troths denied that they were negligent and asserted the affirmative defense of contributory negligence. The Troths filed a motion for summary judgment, which the trial court granted, stating that summary judgment was appropriate regarding the Troths’ duty because Mihaila “became aware of the risk, undertook to encounter the risk, and made his own efforts to mitigate the risk.” The trial court denied Mihaila’s motion for reconsideration and Mihaila appealed. Read the court decision
Read the full story...
Reprinted courtesy of Joshua Lane, Ahlers Cressman & Sleight PLLC
Mr. Lane may be contacted at joshua.lane@acslawyers.com

New Mexico Architect Is Tuned Into His State

February 08, 2021 — David M. Brown - Engineering News-Record
For 40-plus years, Van Gilbert has combined his love for the topography, history and culture of New Mexico with an equally passionate dedication to designing not just structures, but buildings that help create communities. Reprinted courtesy of David M. Brown, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

CISA Clarifies – Construction is Part of Critical Infrastructure Activities

April 20, 2020 — Brenda Radmacher & Ernest Isola - Gordon & Rees Construction Law Blog
After ongoing confusion by many over whether construction should be considered part of the “essential business,” during the COVID-19 pandemic, the Cybersecurity and Infrastructure Security Agency (CISA) issued an updated Coronavirus Guidance for America on March 28, 2020 to clarify construction’s critical role in supporting essential infrastructure. CISA’s initial advisory list referenced construction in regard to some areas such as energy and wastewater treatment, but it was unclear as to the whole of the construction industry. CISA’s update clarified that construction activities are included in its list of essential critical infrastructure workers. This new federal guidance should remove the ambiguity that led to varying responses by state and local officials halting some construction. The guidance clarifies that construction and related activities – including the manufacture and supply/delivery of supplies and equipment, permitting, safety, and inspections of projects – are covered as part of the critical infrastructure and economic activities. The ongoing challenge will be for construction activities to proceed in a way that protects workers and the general public from the spread of coronavirus. However, contractors are always resourceful and have been implementing safety measures effectively on projects with an unwavering commitment to safety and are ready to meet this challenge. In addition to following the guidance from the CDC, we recommend that contractors implement a comprehensive safety program for their employees as well as for all parties that come onto the jobsite. It is critical that contractors have clear a clear plan for communications with their teams to ensure compliance with the CDC recommendations. This should include what has recently become standard protocol or social distancing, not hosting large group meetings and conducting meetings online or via conference call, maintaining a six-foot distance between people, discouraging hand-shaking or other contact, not sharing tools, and sanitizing reusable PPE. Contractors also should also be sure to place safety posters about “How to Protect Yourself” where they can be readily seen and encourage staying home when sick, cough and sneeze etiquette, and hand hygiene at the entrance of a jobsite. We also recommend heightened site security including interviewing anyone coming to the jobsite. Reprinted courtesy of Brenda Radmacher, Gordon & Rees and Ernest Isola, Gordon & Rees Ms. Radmacher may be contacted at bradmacher@grsm.com Mr. Isola may be contacted at eisola@grsm.com Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES