Fairfield Connecticut Building Expert Directory

California Expands on Scope of Coverage for Soft Cost Claims

February 14, 2023 — Caitlin N. Rabiyan - Saxe Doernberger & Vita, P.C.
The California federal district court case of KB Home v. Illinois Union Insurance Co., No. 8:20-cv-00278-JLS-JDE, (C.D. Cal. August 23, 2022), provides much needed guidance for cases involving builder's risk insurance claims for soft cost coverage. The case stems from damage to several of KB Home’s residential building sites caused by a severe rainstorm in January 2017. Each home site was a smaller part of a large housing development project. The damage caused significant delay in the completion of some individual home sites, although there was limited evidence of delay to the overall housing development project. As a result, KB Home sought coverage under a builder’s risk policy purchased from Illinois Union for both hard costs and soft costs. “Hard costs” are the costs directly associated with repairing property damage to the sites. Conversely, “soft costs” are indirect expenses associated with project delays caused by such property damage and repair efforts. For example, hard costs would include labor and materials, whereas the soft costs claimed by KB Home included additional real estate taxes, construction loan interest, and advertising and promotional expenses incurred because of the delays. Illinois Union paid the claim for the hard costs, but denied the soft costs claim. KB Home filed suit and Illinois Union eventually filed a motion for summary judgment. Read the court decision
Read the full story...
Reprinted courtesy of Caitlin N. Rabiyan, Saxe Doernberger & Vita, P.C.
Ms. Rabiyan may be contacted at CRabiyan@sdvlaw.com

$48 Million Award and Successful Defense of $135 Million Claim

June 04, 2024 — Peckar & Abramson
Peckar & Abramson is proud to have represented one of the nation’s largest general contractors in the achievement of a $48 million award in its favor and the denial of a $135 million claim against it in Federal Court in the Middle District of Florida on May 3, 2024 arising out of the FDOT’s $2.3 billion reconstruction of I-4, a P3 project and the Department’s largest project ever in the State of Florida. After a 2-week bench trial, P&A secured the favorable decision which found that the general contractor client was entitled to recover $48 million on its affirmative claim against the party who initiated the lawsuit and that it did not breach its fiduciary duties and was not grossly negligent as was claimed which resulted in a denial of the initiating party’s $135 million claim in its entirety. Read the court decision
Read the full story...
Reprinted courtesy of Peckar & Abramson

Client Alert: Restaurant Owed Duty of Care to Driver Killed by Third-Party on Street Adjacent to Restaurant Parking Lot

January 07, 2015 — R. Bryan Martin, Lawrence S. Zucker II, & Kristian B. Moriarty – Haight, Brown, & Bonesteel, LLP
In Annocki v. Peterson Enterprise, LLC, (Filed 11/14/2014, Certified for Publication 12/5/2014, No. B251434) the Court of Appeal, Second District, held a restaurant owed a duty of care to the driver of a motorcycle who died as a result of the negligent driving of a third party exiting the restaurant’s parking lot. Decedent, Joseph M. Annocki, was driving his motorcycle on Pacific Coast Highway in Malibu, when it collided with the vehicle operated by Terry Allen Turner, who was exiting the parking lot of “Geoffrey’s" restaurant, which was owned and operated by the Defendant, Peterson Enterprise, LLC (“Peterson”). The parents of the decedent (“Plaintiffs”) filed suit against Peterson, alleging Peterson failed to adequately staff the restaurant parking lot, which caused Turner to become confused and make an illegal left turn onto Pacific Coast Highway, thereby causing the accident that killed decedent. Plaintiffs further alleged Peterson knew, or should have known, that its parking lot and driveway were designed and in such condition as to create a danger of decreased visibility of the adjacent highway, and failed to adequately provide signage directing patrons that only right turns could be made onto Pacific Coast Highway. Reprinted courtesy of Haight Brown & Bonesteel LLP attorneys R. Bryan Martin, Lawrence S. Zucker II and Kristian B. Moriarty Mr. Martin may be contacted at bmartin@hbblaw.com Mr. Zucker may be contacted at lzucker@hbblaw.com Mr. Moriarty may be contacted at kmoriarty@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Midview Board of Education Lawsuit Over Construction Defect Repairs

February 04, 2014 — Beverley BevenFlorez-CDJ STAFF
Midview Local Schools Board of Education in Grafton, Ohio, “filed a lawsuit asking Lorain County Common Pleas Court to order the Ohio School Facilities Commission to help pay for repairs on three new schools,” according to The Morning Journal. Scott Goggin, Midview’s Superintendent, told The Morning Journal: “Water-stained ceilings and weeping windows in three new elementary schools, built with financial help and cooperation of the OSFC Expedited Local Partnership Program, irritated the district for months.” “The lawsuit,” as reported by The Morning Journal “claimed other school districts received financial help from the state when correcting repairs to their schools built through the same program.” Furthermore, the lawsuit stated that “OSFC failed to assess the total classroom facilities needs of the school district, and to share the costs of repairing defects.” The Morning Journal reported, “The lawsuit asks for restitution of the state’s share of correcting the construction defects, the costs of the lawsuit and reasonable attorney’s fees, and further relief the court decides is just and fair.” Read the court decision
Read the full story...
Reprinted courtesy of

California Court of Appeal Clarifies Intent of Faulty Workmanship Exclusions

October 26, 2017 — Tiffany Casanova – Saxe Doernberger & Vita, P.C.
Last month, in Global Modular, Inc. v. Kadena Pacific, Inc., 1 a California Court of Appeal clarified the meaning of the frequently asserted j.(5) and j.(6) exclusions of the standard commercial general liability policy; an issue the court deemed one of “first impression” for the state. The court took a close look at how courts nationwide handle the exclusions and relied on the policy language to come to a policyholder-friendly decision. Read the court decision
Read the full story...
Reprinted courtesy of Tiffany Casanova, Saxe Doernberger & Vita, P.C.
Ms. Casanova may be contacted at tlc@sdvlaw.com

Cross-Motions for Partial Judgment on the Pleadings for COVID-19 Claim Denied

May 24, 2021 — Tred R. Eyerly - Insurance Law Hawaii
The court denied both parties' motions for partial judgment on the pleadings seeking clarification of the policy's contamination exclusion. Thor Equities, LLC v. Factory Mut. Ins. Co., 2021 U.S. Dist. LEXIS 62967 (S.D. N.Y. March 31, 2021). Thor was a commercial landlord, renting properties across the country to hundreds of tenants, for use in a variety of businesses, including office space, retail stores, restaurants, and bars. When state governments began shutting down businesses and issuing stay-at-home orders in March 2020, many of Thor's tenants had to close shop and sought abatements or other accommodations. Thor alleged it suffered significant business interruption as a result of the pandemic. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Construction Lien Needs to Be Recorded Within 90 Days from Lienor’s Final Furnishing

March 22, 2018 — David Adelstein – Florida Construction Legal Updates

A lienor needs to record its construction lien within 90 days of its final furnishing date. This final furnishing date excludes punchlist, warranty, or the lienor’s own corrective work. A lien recorded outside of the 90-day window will be deemed invalid.

The opinion in In re: Jennerwein, 309 B.R. 385 (M.D. Fla. 2004) provides a good discussion of this 90-day window. This matter dealt with a debtor / owner’s bankruptcy where the owner was contesting the validity of a construction lien by its pool contractor. The owner contended that the lienor’s lien was recorded outside of this 90-day window thus rendering the lien invalid. The bankruptcy court was determining the validity of the lien.

In this matter, the owner hired a swimming pool contractor to construct a pool. On October 25, 2002, the pool contractor installed pavers around the pool. After this was performed, the pool contractor realized the owner was unable to obtain the financing to pay for the pool. As a result, the pool contractor ceased doing any more improvements. But, neither the pool contractor nor the owner terminated the contract. Then, on November 27, 2002, the pool contractor sent a supervisor to the property to inspect the pool (work-in-place), the pool equipment, the installed pavers, made a list of the unfinished work, and remove any debris. On January 27, 2003, the pool contractor recorded its lien.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

Construction Firm Sues City and Engineers over Reservoir Project

October 28, 2011 — CDJ STAFF

The city of Fremont, Ohio and Arcadis have been sued by Trucco Construction. Trucco had been hired by the city to build a reservoir designed by Arcadis, the News-Messenger reports. Peter Welin, attorney for Trucco, said that he found “startling evidence of the company’s negligence” when he deposed Arcadis engineers. “This project could never be built the way they bid it.”

Their suit alleges that Arcadis and the city were aware that the site was not conducive to construction and also that Arcadis failed to be a neutral party in discussions between Trucco and the city regarding compensation.

Sam Wamper, an attorney for Fremont, said he was going to file a motion which would include “quite an interesting story,” but declined to elaborate.

Read the full story...

Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES