Fairfield Connecticut Building Expert Directory

Is The Enforceability Of A No-Damage-For-Delay Provision Inappropriate For Summary Judgment

February 24, 2020 — David Adelstein - Florida Construction Legal Updates
Is the enforceability of a no-damage-for-delay provision inappropriate for resolution on a summary judgment? The recent decision in U.S. f/u/b/o Kingston Environmental Services, Inc. v. David Boland, Inc., 2019 WL 6178676 (D. Hawaii 2019), dealing with Florida law, suggests that it is inappropriate for a summary judgment resolution, particularly when there is a right to a jury trial. In this case, a prime contractor was hired on a federal construction project in Hawaii. The prime contractor hired a subcontractor and the subcontractor sued the prime contractor and its surety under the Miller Act. Of interest, the subcontractor was seeking to recover for the costs it incurred due to construction delays. The prime contractor moved for summary judgment as to the no-damage-for-delay provision in the subcontract. The no-damages-for-delay provision read as follows (and it is a well-written no-damage-for-delay provision): The Subcontractor expressly agrees that the Contractor shall not be liable to the Subcontractor for any damages or additional costs, whether foreseeable or unforeseeable, resulting in whole or in part from a delay, hindrance, suspension, or acceleration of the commencement or execution of the Work, caused in whole or in part by the acts or omissions, whether negligent or not, of the Contractor including other subcontractors or material suppliers to the Project, its agents, employees, or third parties acting on behalf of the Contractor. The Subcontractor’s sole remedy for any such delay, hindrance, suspension, or acceleration shall be a noncompensable time extension. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Over 70 Lewis Brisbois Attorneys Recognized in 4th Edition of Best Lawyers: Ones to Watch in America

September 25, 2023 — Lewis Brisbois
(August 17, 2023) – 75 Lewis Brisbois attorneys across 25 offices have been named to the 4th edition of "Best Lawyers: Ones to Watch in America." Congratulations to the following attorneys on this recognition! You can see the full list of Lewis Brisbois attorneys named to Best Lawyers' 30th edition of The Best Lawyers in America here. Akron, OH

Associate Meleah M. Skillern – Commercial Litigation

Atlanta, GA

Partner Candis R. Jones - Insurance Law, Medical Malpractice Law – Defendants, and Personal Injury Litigation – Defendants

Boston, MA

Partner Amanda Mathieu - Labor and Employment Law – Management

Charleston, WV

Partner Sophie L. Johns - Product Liability Litigation - Defendants

Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

ACEC Research Institute Releases New Engineering Industry Forecast

December 13, 2021 — American Council of Engineering Companies
Washington, DC, Dec. 09, 2021 (GLOBE NEWSWIRE) -- Today, the ACEC Research Institute released two new reports on the Engineering and Design Services industry: the 2021 Economic Assessment of the Engineering and Design Services Industry and a new Engineering Business Sentiment report for Q4 2021. The data shows the industry has rebounded from project postponements due to COVID, though firms identify a tight labor market and lack of qualified workers as continued barriers to growth across public and private markets. This is the second annual release of the Engineering and Design Services industry assessment, which tracks the industry's economic contributions, analyzes key economic drivers, and forecasts industry growth. Snapshot of the Engineering and Design Services Industry: 1.5 million direct full- and part-time jobs $97,300 average yearly wages $338 billion in industry sales $198 billion direct economic contribution $105 billion collected in total federal, state & local tax Both reports, the 2021 Economic Assessment of the Engineering and Design Services Industry and the Engineering Business Sentiment report for Q4 2021, are available for download by clicking here. ### The ACEC Research Institute is the research arm of the American Council of Engineering Companies – the business association of the nation's engineering industry. The ACEC Research Institute's mission is to deliver knowledge and business strategies that guide and elevate the engineering industry and to be the leading source of knowledge and thought leadership for creating a more sustainable, safe, secure and technically advanced built environment. For more information, go to www.acecresearchinstitute.org. Read the court decision
Read the full story...
Reprinted courtesy of

New York’s Lawsky Proposes Changes to Reduce Home Foreclosures

May 20, 2015 — Jesse Westbrook – Bloomberg
New York’s banking regulator proposed changes to the foreclosure process to try to help borrowers in the state keep their homes. One reason New York has a high rate of foreclosures is that mandatory settlement meetings between borrowers and mortgage servicers typically don’t take place for months after a bank initiates a foreclosure, Benjamin Lawsky, superintendent of New York’s Department of Financial Services said in prepared remarks Tuesday. Read the court decision
Read the full story...
Reprinted courtesy of Jesse Westbrook, Bloomberg

U.S. Homeownership Rate Rises for First Time in Two Years

October 28, 2015 — Prashant Gopal – Bloomberg
The homeownership rate in the U.S. rose for the first time in two years as sustained job growth and low borrowing costs fueled demand for housing. The share of Americans who own their homes was 63.7 percent in the third quarter, up from 63.4 percent in the previous three months, the Census Bureau reported Tuesday. It was the first quarterly increase since the third quarter of 2013. The pool of eligible buyers is expanding as U.S. employment improves and families who lost properties during the recession repair their credit and seek another chance at owning. Sales of existing homes rebounded in September to the second-highest level since February 2007. Read the court decision
Read the full story...
Reprinted courtesy of Prashant Gopal, Bloomberg

Construction Litigation Roundup: “Ursinus is Cleared!”

March 11, 2024 — Daniel Lund III - Lexology
Ursinus University in Pennsylvania – a “private, nonprofit liberal arts college” – funded a construction project for a new building utilizing monies loaned by the Montgomery County Health and Higher Education Authority, a public economic development authority “formed by the Board of County Commissioners… authorized to issue bonds relative to projects for eligible educational institution such as Ursinus.” Loans up to the amount of $23,000,000 became available to the University, and construction proceeded using the loans as construction funds. At issue: whether a project was to be considered publicly funded project such that prevailing wage rates were required to be paid. IBEW filed a related grievance with the Pennsylvania Department of Labor and Industry’s Bureau of Labor Law Compliance, which was refused by the Bureau, on the basis that because work was “financed completely by loans from the Authority, which Ursinus was required to repay in their entirety, the Project was ultimately funded through private sources and exempt from coverage under the [Pennsylvania Prevailing Wage Act].” A grievance to the Prevailing Wage Appeals Board ensued, and the Board took a different position. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

U.S. Supreme Court Limits the Powers of the Nation’s Bankruptcy Courts

June 11, 2014 — Earl Forte – White and Williams LLP
On June 9, 2014, the Supreme Court of the United States issued its much-awaited decision in Executive Benefits Insurance Agency v. Arkison, Chapter 7 Trustee of Estate of Bellingham Insurance Agency, Inc., Case No. 12-1200, in which the court confirmed that the power of the nation’s bankruptcy courts to hear and decide cases involving state-created private rights in which the bankruptcy proof of claim process has not been directly invoked, is severely limited by Article III of the Constitution of the United States. The decision in Executive Benefits, while providing some clarity to practitioners and the public following the Court’s June 2011 decision in Stern v. Marshall, 131 S. Ct. 2594 (2011), nevertheless will make a substantial portion of bankruptcy litigation matters more cumbersome and potentially more expensive to guide through the bankruptcy system. Clients and practitioners are best advised to hire knowledgeable counsel to help navigate the more complex procedural waters created by this decision. Although the Court in Executive Benefits did resolve a pending procedural question that had dogged practitioners since Stern was decided in 2011, the Court’s decision in Executive Benefits now makes it abundantly clear that many disputes that were previously heard and decided in the nation’s bankruptcy courts can no longer be decided there and must be submitted to the district courts for full de novo review and entry of a final judgment or order. It is difficult to see how this decision will not make bankruptcy litigation more cumbersome and expensive by adding an additional layer of judicial involvement to many matters, notably to fraudulent transfer and other avoidance “claw back” actions that historically have been decided in the bankruptcy courts and used famously in Madoff and other cases as an efficient device for creating value for creditors. Read the court decision
Read the full story...
Reprinted courtesy of Earl Forte, White and Williams LLP
Mr. Forte may be contacted at fortee@whiteandwilliams.com

The A, B and C’s of Contracting and Self-Performing Work Under California’s Contractor’s License Law

July 19, 2017 — Garret Murai - California Construction Law Blog

Class A – General Engineering Contractors;
Class B – General Building Contractors; and
Class C – Specialty Contractors of which there are currently 42 different Class C specialty contractors license types.

Each of these license classifications has separate contracting rules, and rules regarding when work can be self-performed, which for many can be confusing. Minor Work Exception One important (albeit “minor”) exception is that no contractor’s license is required no matter what type of work is being performed if the project has a value of less than $500. Known as the “minor work exception,” the exception is a project-based, not work-based, exception. Thus, for example, if a project owner is remodeling their kitchen at a cost of $6,000 and the cost of doing the flooring is only $300, the person doing the flooring would need to have a contractor’s license in the appropriate classification since the aggregate cost of the work is $500 or more. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES