Fairfield Connecticut Building Expert Directory

California Expands on Scope of Coverage for Soft Cost Claims

February 14, 2023 — Caitlin N. Rabiyan - Saxe Doernberger & Vita, P.C.
The California federal district court case of KB Home v. Illinois Union Insurance Co., No. 8:20-cv-00278-JLS-JDE, (C.D. Cal. August 23, 2022), provides much needed guidance for cases involving builder's risk insurance claims for soft cost coverage. The case stems from damage to several of KB Home’s residential building sites caused by a severe rainstorm in January 2017. Each home site was a smaller part of a large housing development project. The damage caused significant delay in the completion of some individual home sites, although there was limited evidence of delay to the overall housing development project. As a result, KB Home sought coverage under a builder’s risk policy purchased from Illinois Union for both hard costs and soft costs. “Hard costs” are the costs directly associated with repairing property damage to the sites. Conversely, “soft costs” are indirect expenses associated with project delays caused by such property damage and repair efforts. For example, hard costs would include labor and materials, whereas the soft costs claimed by KB Home included additional real estate taxes, construction loan interest, and advertising and promotional expenses incurred because of the delays. Illinois Union paid the claim for the hard costs, but denied the soft costs claim. KB Home filed suit and Illinois Union eventually filed a motion for summary judgment. Read the court decision
Read the full story...
Reprinted courtesy of Caitlin N. Rabiyan, Saxe Doernberger & Vita, P.C.
Ms. Rabiyan may be contacted at CRabiyan@sdvlaw.com

Angela Cooner Receives Prestigious ASA State Advocate Award

April 12, 2021 — Angela Cooner - Lewis Brisbois
Phoenix Partner Angela L. Cooner recently received the American Subcontractors Association, Inc. (ASA) 2020 State Advocate award during ASA’s Virtual Awards Presentation, which took place on February 25. ASA selected Ms. Cooner as the recipient of this honor based upon the significant time that she spent and value she added to subcontractor advocacy in Arizona over the last year. In nominating Ms. Cooner for this award, ASA of Arizona stated, “Angie’s dedication and track record are second to none. However, it is her leadership in managing the recent merger between the Arizona State Contractors’ Coalition (AZSCC) and Arizonans for Fair Contracting (AFC) where she has distinguished herself most notably.” Moreover, ASA explained that Ms. Cooner’s dedication “has allowed ASA of Arizona to renegotiate a new contract with a government affairs firm that helped secure victory on a critical proportional liability bill and begin the upcoming legislative session on the right foot.” According to ASA, Ms. Cooner has donated the equivalent of $120,000 in billable hours to the organization through her work for AFC and as legal counsel for ASA of Arizona’s Board of Directors. Read the court decision
Read the full story...
Reprinted courtesy of Angela Cooner, Lewis Brisbois
Ms. Cooner may be contacted at Angela.Cooner@lewisbrisbois.com

DIR Reminds Public Works Contractors to Renew Registrations Before January 1, 2016 to Avoid Hefty Penalty

December 17, 2015 — Garret Murai – California Construction Law Blog
I know. You’re busy. Perhaps even a bit overwhelmed. You’ve got trees to trim, halls to deck with boughs of holly, and when you throw in (the office, your kids’ school, and the bowling league’s) holiday parties, you’re at the point where you’ve got visions of sugar plums (although it may vary) dancing through your head. Well, the DIR has come to give you its own yuletide greeting. Think of it as a Christmas card of sorts. Merry Christmas. The Department of Industrial Relations (DIR) announced today that a mandatory renewal deadline is approaching for contractors who bid or work on public works projects in California. Contractors whose public works contractor registration expired June 30, 2015, and have ongoing public works projects or plan to bid on new ones, must pay the $300 renewal fee before January 1, 2016 or face an additional $2,000 late penalty after that date. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Apartment Building Damaged by Cable Installer’s Cherry Picker

November 20, 2013 — CDJ STAFF
The owners of Oceana Apartments are suing Shentel Cable Co. and their subcontractors, CCI Systems, Inc. and Big Dog Communications, over the damage caused when a cherry picker rolled downhill and smacked into the building. Kenneth Benn, an employee of Big Dog Communications, was installing utility wire when the cherry picker started moving. The suit alleges that Mr. Benn either failed to properly apply the brakes or immobilize the vehicle before staring work. Mr. Benn is also named as a defendant in the suit. Read the court decision
Read the full story...
Reprinted courtesy of

Traub Lieberman Partners Lisa Rolle, Erin O’Dea, and Nicole Verzillo Win Motion for Summary Judgment in Favor of Property Owner

September 30, 2024 — Lisa M. Rolle, Erin O’Dea, Nicole Verzillo - Traub Lieberman
Traub Lieberman Partners Lisa Rolle, Erin O’Dea, and Nicole Verzillo won motion for summary judgment in a premises liability matter brought before the Supreme Court of the State of New York, Westchester County. The Plaintiff allegedly tripped and fell in a pothole on the common driveway of five abutting properties and sustained an injury. The firm represented one of the multiple property owners. Traub Lieberman moved for summary judgment, asserting that the claims against the firm’s client should be dismissed as they did not own, operate, control or make special use of the driveway where the incident occurred. The firm also asserted that the alleged condition of the driveway that allegedly caused Plaintiff’s accident was a non-actionable, trivial defect. The firm also moved to dismiss the cross-claims asserted against them, contending that there was no evidence of negligence on behalf of the firm’s client. As such, the court found that the defect was a non-actionable, trivial defect. The firm secured dismissal of Plaintiff’s claims against the firm’s clients and against all moving and non-moving Defendants. Reprinted courtesy of Lisa M. Rolle, Traub Lieberman, Erin O’Dea, Traub Lieberman and Nicole Verzillo, Traub Lieberman Ms. Rolle may be contacted at lrolle@tlsslaw.com Ms. O'Dea may be contacted at eodea@tlsslaw.com Ms. Verzillo may be contacted at nverzillo@tlsslaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Planned Everglades Reservoir at Center of Spat Between Fla.'s Gov.-Elect, Water Management District

January 02, 2019 — Miami Herald - Engineering News-Record
Dec. 11 -- Florida's incoming governor stopped short of demanding South Florida water managers step down over a contentious land deal with sugar farmers, saying he would instead await a recommendation from his transition team. That doesn't mean their days may not be numbered. Read the court decision
Read the full story...
Reprinted courtesy of Engineering News-Record
ENR may be contacted at ENR.com@bnpmedia.com

Arizona Supreme Court Holds a Credit Bid at a Trustee’s Sale Should Not be Credited to a Title Insurer Under a Standard Lender’s Title Policy To the Extent the Bid Exceeds the Collateral’s Fair Market Value

March 01, 2017 — Richard H. Herold - Snell & Wilmer Real Estate Litigation Blog
The Arizona Supreme Court recently addressed what impact, if any, a lender’s credit bid at an Arizona trustee’s sale has on an insurer’s liability under Sections 2, 7 and 9 of the standard’s lender’s title policy (“Policy”), holding in Equity Income Partners, LP v. Chicago Title Insurance Company, 241 Ariz. 334, 387 P.3d 1263 (February 7, 2017) as follows: 1. Section 2 of the Policy, entitled “Continuation of Insurance,” not Section 9, entitled “Reduction of Insurance; Reduction or Termination of Liability,” applies when a lender acquires property at a trustee sale by “either a full- or partial-credit bid” since Section 2 directly addresses the existence and amount of coverage in such circumstances. Id. at 1267. Read the court decision
Read the full story...
Reprinted courtesy of Richard H. Herold, Snell & Wilmer
Mr. Herold may be contacted at rherold@swlaw.com

Policing Those Subcontractors: It Might Take Extra Effort To Be An Additional Insured

June 14, 2011 — Douglas Reiser, Builders Council Blog

I just came across a case that I think truly paints the insurance dilemma for contractors. Thanks to this recent Illinois case, I don’t have to make up any factual scenarios—so kudos to Attorney Robert Boylan for posting it.

In reading over my RSS feeds this weekend, I noticed a great writeup on long-time blogger Josh Glazov’s Construction Law Today. Attorney Robert Boylan’s post describes a recent Illinois case where a general contractor was denied its additional insured status on a second-tier subcontractor’s insurance. The reason for the denial: the general contractor failed to procure an agreement in writing with the second-tier subcontractor, requiring it to be listed as an additional insured.

Read the full story…

Reprinted courtesy of Douglas Reiser of Reiser Legal LLC. Mr. Reiser can be contacted at info@reiserlegal.com

Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES