Fairfield Connecticut Building Expert Directory

Constructive Suspension (Suspension Outside of an Express Order)

December 13, 2022 — David Adelstein - Florida Construction Legal Updates
In the federal procurement arena, there is a concept known as “constructive suspension.” Constructive suspension, while known in the federal arena, should reasonably apply to all projects when work is stopped outside of an express order to stop the work based on the law below. An unreasonable suspension is an unreasonable suspension and an express order to stop the work does not negate the effects of what really amounts to a suspension. “Constructive suspension occurs when work is stopped absent an express order by the contracting officer and the government is found to be responsible for the work stoppage.” P.R. Burke Corp. v. U.S., 277 F.3d 1346, 1359 (Fed. Cir. 2002). The government delay must be unreasonable to support a constructive acceleration claim. Id. “To demonstrate such a constructive suspension of work, the contractor must show that the delay (1) was for an ‘unreasonable length of time,’ (2) was proximately caused by the government’s actions, and (3) resulted in some injury to the contractor.” Fireman’s Fund Ins. Co. v. U.S., 2001 WL 36415627, *6 (Fed.Cl. 2001) (citation omitted). “Relative to proving that the delay was directly caused by the government, the contractor must concomitantly show that it was not delayed by any concurrent cause that would have independently generated the delay during the same time period even if it does not predominate over the government’s action as the cause of the delay.” Beauchamp Const. Co. v. U.S., 14 Cl.Ct. 430, 437 (Cl.Ct. 1988). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Champagne Wishes and Caviar Dreams. Unlicensed Contractor Takes the Cake

August 31, 2020 — Garret Murai - California Construction Law Blog
Before the Kardashians, before Empire, before Crazy Rich Asians there was Lifestyles of the Rich and Famous with Robin Leach. The next case, Moore v. Teed, Case No. A153523 (April 24, 2020), 1st District Court of Appeals, is about the unfulfilled wishes and dashed dreams of the $13 million dollar “fixer upper.” Moore v. Teed The $13 Million Dollar “Fixer Upper” Justin Moore just wanted to buy a house in San Francisco. But he couldn’t afford one in the neighborhoods he preferred. But in 2011, luck struck, when Moore met Richard Teed, a real estate agent with “over 25 years of experience as a building contractor,” “an extensive background in historic restorations” and a “deep understanding of quality construction.” Teed told Moore that he could locate a “lower-priced fixer-upper in a choice neighborhood and then renovate it.” Moore was sold. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

FAA Seeks Largest Fine Yet on Drones in Near-Miss Crackdown

October 21, 2015 — Alan Levin – Bloomberg
The U.S. Federal Aviation Administration is proposing the largest fine to date against a drone operator as the agency cracks down on the booming use of unmanned aircraft in congested skies over populated areas. The FAA said Tuesday it was recommending a $1.9 million penalty against SkyPan International Inc., which made 65 drone flights from 2012 to 2014 in airspace above cities including New York. The company uses drones to photograph the prospective views from Manhattan high rises under construction, according to its website. The action comes as the FAA has struggled to enforce existing rules on drones and attempts to finalize the first regulations allowing small unmanned vehicles to operate commercially. Drone sightings by pilots, including close-calls with airliners, have surged from only a handful a month last year to over 100 per month. Read the court decision
Read the full story...
Reprinted courtesy of Alan Levin, Bloomberg

Insurer's Appeal of Jury Verdict Rejected by Tenth Circuit

March 06, 2023 — Tred R. Eyerly - Insurance Law Hawaii
After a jury awarded damages related to the insurer's delayed payment under the claim and the insurer's post trial motions to set aside the verdict were denied, the Tenth Circuit affirmed. US General, LLC v. GuideOne Mut. Ins. Co., 2022 U.S. App. LEXIS 34066 (10th Cir. Dec. 12, 2022). Crossroads American Baptist Church submitted a claim to GuideOne for hailstorm damage. Crossroads hired US General as the general contractor to perform the repairs and later assigned its interest in the insurance policy to US General. Numerous disputes arose between Crossroads and GuideOne regarding the cost of the repairs. There were delayed payments and portions of the repairs were never paid for. The delayed payments meant GuideOne's ability to begin making the repairs was hindered because it was more expensive to start and stop a project. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Autovol’s Affordable Housing Project with Robotic Automation

February 15, 2021 — Aarni Heiskanen - AEC Business
Just over two years since breaking ground, Autovol is now using automation in new ways as it nears completion of its first major affordable housing project. The project, Virginia Street Studios, will make high-quality apartment homes more affordable to seniors in San Jose, one of America’s 10 most expensive cities. The 400,000 square foot Autovol factory has now successfully deployed its unique combination of construction trades and robotic automation. Autovol has hired more than 100 employees, which the company calls Solutioneers. Led by CEO Rick Murdock and co-developed by The Pacific Companies, Autovol is pioneering a new kind of modular construction. Robotics lead into the future of housing “Automation and robotics will lead the world into the future of housing,” Murdock said. “What we’re doing hasn’t been attempted before. Our investors and Solutioneers leaned in with lots of confidence, and now we’re seeing great results that prove they were right.” Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Ensuing Loss Provision Salvages Coverage for Water Damage Claim

September 16, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The Court of Appeals for the D.C. Circuit reversed the district court's finding of no coverage and found that the ensuing loss provision provided coverage for water damage. 3524 East Cap Venture, LLC, et al. v. Weschester Fire Ins. Co., et al., 104 F. 4th 193 (D.C. Cir. 2024). Plaintiff 3534 East Cap Venture, LLC, a real-estate developer, hired plaintiff McCullough Construction, LLC, to build a residential and retail complex. Defendants Westchester Fire Insurance Company and Endurance American Insurance Company issued identical builders' risk policies, which covered the building while it was under construction. Each insurer was responsible for half of any qualifying losses. The policies covered loss caused by or resulting from water damage. The policies, however, excluded loss caused by "dampness of atmosphere" or by "[e]xtremes or changes in temperature." But the exclusions contained an exception if "loss by an insured peril ensues." Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Can a Contractor be Liable to Second Buyers of Homes for Construction Defects?

November 05, 2014 — Craig Martin - Construction Contractor Advisor
Whether a contractor will be liable to a second purchaser, even though the contractor never contracted with the second purchaser, varies state to state. The Pennsylvania Supreme Court, in Conway v. The Cutler Group, is the latest court to rule that a subsequent purchaser lacks privity and cannot pursue an action against the builder. In that case, the Conways purchased a home from the original owner. After living in the home for about two years, the Conways discovered water leaking around the windows. The Conways sued the builder, alleging breach of the implied warranty of habitability. The builder defended the claim, asserting that it had not contracted with the Conways and thus had not provided any warranties to the Conways. The trial court agreed and dismissed the claim. The first level of appellate court reversed the trial court, holding that the warranty of habitability was intended to level the playing field between the builder and purchaser of a home and it should be extended to subsequent purchasers. The Pennsylvania Supreme Court disagreed and refused to extend any warranties to subsequent purchasers. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

The COVID-19 Impact: Navigating the Legal Landscape’s New Normal

July 27, 2020 — Amanda Mathieu - Lewis Brisbois
While most of the country has been at a standstill since March, you might be wondering, what about my lawsuit or my administrative charge? For the past couple of months, most litigation cases have largely been put on pause in the courts and at administrative agencies. However, as we adjust to what is clearly a new normal in both our lives and the legal landscape as we know it, cases will begin to pick up speed again, albeit with new strategies and challenges to keep in mind. As courts begin to reopen, judges are emphasizing in many jurisdictions that criminal cases will take priority in an effort to attend to constitutionally required timelines. Nevertheless, it will remain just as important as before the pause button was hit to keep cases moving forward. This ramp up period presents a unique opportunity for clients and attorneys to invest meaningful time into investigating and developing defenses to claims while the court system and related case pace remains slowed. Read the court decision
Read the full story...
Reprinted courtesy of Amanda Mathieu, Lewis Brisbois
Ms. Mathieu may be contacted at Amanda.Mathieu@lewisbrisbois.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES