Seattle Washington Building Expert Directory

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Sochi Construction Unlikely to be Completed by End of Olympic Games

February 11, 2014 — Beverley BevenFlorez-CDJ STAFF
As journalists and visitors descended upon Sochi, Russia for this winter’s Olympic Games, they reported “used linen, improper toilets, poor wiring, unclean water and loose fixtures” using the Twitter hash tag @SochiProblems, according to The International Business Times. Furthermore, it is doubtful that the construction work “in and around Sochi” will be completed by February 23rd—the official end of the games. The International Business Times article features photographs of various unfinished construction sites including an apartment building, hotels, a sports store, and other buildings. The Olympic opening ceremony took place on February 7th. Read the court decision
Read the full story...
Reprinted courtesy of

Newmeyer & Dillion Announces New Partner Bahaar Cadambi

May 06, 2019 — Newmeyer & Dillion
Prominent business and real estate law firm Newmeyer & Dillion LLP is pleased to announce that Newport Beach attorney Bahaar Cadambi has been elected to partnership. "Bahaar has worked hard to become an integral part of the firm's litigation practice, delivering exceptional value to her colleagues and clients at every opportunity," said the firm's Managing Partner, Paul Tetzloff, "We are proud to count her among our partners and look forward to her continued success and contributions." Cadambi concentrates her practice in business, insurance, and real estate litigation. She represents businesses, homebuilders, developers, and general contractors in complex, multi-party real estate, construction defect, and insurance disputes. She also represents individuals and businesses across a variety of business litigation matters. Her approach to litigation ensures that clients are informed of all potential strategies, the consequences of those strategies, and how the implementation of those strategies will affect their business. Passionate about the legal community, Cadambi is an adjunct professor at the University of Southern California Gould School of Law and an active member of CREW (Commercial Real Estate Women Orange County). She is also a Barry's Bootcamp and yoga enthusiast, lover of all things interior design, avid traveler, devoted wife, and favorite aunt to two energetic nieces and one cheerful nephew. Bahaar earned her B.A. from the University of California, Los Angeles and her J.D. from the University of California, Hastings College of Law. Prior to joining Newmeyer & Dillion, she served as a Judicial Extern for the Honorable William Alsup in the U.S. District Court for the Northern District of California. Bahaar Cadambi: bahaar.cadambi@ndlf.com

Practice Areas

Business Litigation
Construction Litigation
Insurance Law

About Newmeyer & Dillion For almost 35 years, Newmeyer & Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of business, employment, real estate, privacy & data security and insurance law, Newmeyer & Dillion delivers legal services tailored to meet each client's needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer & Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949.854.7000 or visit www.ndlf.com. Read the court decision
Read the full story...
Reprinted courtesy of

Surplus Lines Carriers Cannot Compel Arbitration in Louisiana

May 29, 2023 — Tred R. Eyerly - Insurance Law Hawaii
The court denied the surplus lines insurer's motion to compel arbitration based on Lousiana's law prohibiting arbitrations of coverage disputes. Fairway Village Condominiums v. Independent Spec. Ins. Co., 2023 U.S. Dist. LEXIS 62135 (E.D. La. April 20, 2023). The plaintiff's condominium complex was damaged by Hurricane Ida. A claim was filed with the insurer. The insurer made an initial advance payment of $200,000. Three additional payments were made bringing the total to $951,462.49, which was less than half of the proof of loss amounts submitted by plaintiff. Plaintiff sued the insurer for breach of contract and bad faith. The insurer filed a motion to compel arbitration based upon an arbitration provision in the policy. Recognizing that Louisiana law prohibited enforcement of a policy's arbitration clause, the insurer argued it did not apply because it was a surplus lines carrier. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Power & Energy - Emerging Insurance Coverage Cases of Interest

November 30, 2020 — David G. Jordan & Tiffany Casanova - Saxe Doernberger & Vita, P.C.
The Power & Energy sector faces a multitude of risks that impact output and profitability, requiring sound risk management and robust insurance programs. As of recent, like most industries, there have been significant challenges facing the industry in light of COVID-19. These issues, including decreased product demand as well as supply- side issues, have been well documented. However, other issues continue to impact Power & Energy providers, with significant insurance coverage implications that are worthy of note. Below is a summary of three open cases of interest, where declaratory relief has been sought by energy providers’ insurance carriers, seeking an avoidance of coverage. 1. Fracking Dispute and “Intentional Acts” In the Texas case of The James River Insurance Co. v. Clearpoint Chemicals LLC et al., No. 4:20-cv-0076 (N.D.Tex), James River Insurance Company (“James River”) is asking a federal district court to declare that it does not owe defense or indemnity to its insured for acts it defines as both intentional and/or malicious acts. Reprinted courtesy of David G. Jordan, Saxe Doernberger & Vita, P.C. and Tiffany Casanova, Saxe Doernberger & Vita, P.C. Mr. Jordan may be contacted at DJordan@sdvlaw.com Ms. Casanova may be contacted at TCasanova@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

White and Williams Defeats Policyholder’s Attempt to Invalidate Asbestos Exclusions

January 28, 2014 — White and Williams LLP
White and Williams attorneys scored a significant victory for the insurance industry on January 15, 2014, when a federal jury of four men and four women rejected a policyholder’s novel efforts to invalidate asbestos exclusions contained in insurance policies issued between February 1, 1979 and August 1, 1985. In General Refractories Co. v. First State Ins. Co., Civil Action No. 04-CV-3509 (E.D. Pa.), General Refractories Company contended that asbestos exclusions in insurance policies issued by various insurance companies in the late 1970s and 1980s had not been submitted to the Pennsylvania Department of Insurance for approval prior to use and, therefore, were unenforceable. Holding a failure to obtain approval, by itself, would not be sufficient to render the exclusions unenforceable, the Honorable Edmund Ludwig sent the matter to trial to determine whether the Pennsylvania Insurance Commissioner implemented a policy that was uniformly executed by the Insurance Department to disapprove all asbestos exclusions between February 1, 1979 and August 1, 1985, such that the exclusions violated a “dominant public policy.”

Reprinted courtesy of Gregory LoCasale, White and Williams LLP

and Patricia Santelle , White and Williams LLP

Ms. Santelle may be contacted at santellep@whiteandwilliams.com and Mr. LoCasale may be contacted at locasaleg@whiteandwilliams.com. Read the court decision
Read the full story...
Reprinted courtesy of

Congratulations to Nicole Whyte, Keith Bremer, John Toohey, and Tyler Offenhauser for Being Recognized as 2022 Super Lawyers!

February 07, 2022 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
BWB&O is proud to announce that Partners Nicole Whyte, Keith Bremer, John Toohey, and Tyler Offenhauser have been named as 2022 Southern California’s Super Lawyers! We are also honored to share that Nicole Whyte is included in two of the top lists, Top 50 Women Lawyers in Southern California and Top 50 Lawyers in Orange County! Super Lawyers is a rating service of outstanding lawyers from more than 70 practice areas who have attained a high degree of peer recognition and professional achievement. The patented selection process includes independent research, peer nominations, and peer evaluations. Each candidate is evaluated on 12 indicators of peer recognition and professional achievement. During the final selection process, only lawyers in the top 5% of the total lawyers in the state are selected to the Super Lawyers list. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

Georgia Legislature Passes Additional Procurement Rules

May 30, 2018 — David R. Cook Jr. - Autry, Hall & Cook, LLP
On May 3, 2018, Governor Nathan Deal signed HB 899 into law, officially making it Act 389. Act 389 modifies O.C.G.A. § 13-10-4 and § 36-91-23 relating to public works bidding and contracts of state and local governments, respectively. Both sections are modified in the same bill because they contain the same language. The bill prohibits the disqualification of bidders based upon lack of previous experience with the project’s desired construction delivery method. Before the modifications, the code protected a contractor from disqualification only for lack of previous experience on a job of comparable size. After the modification, the law expands to prohibit disqualification based on lack of previous experience with comparable job size and lack of previous experience with the construction delivery method. Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook Jr., Autry, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES