Constructive Suspension (Suspension Outside of an Express Order)
December 13, 2022 —
David Adelstein - Florida Construction Legal UpdatesIn the federal procurement arena, there is a concept known as “constructive suspension.” Constructive suspension, while known in the federal arena, should reasonably apply to all projects when work is stopped outside of an express order to stop the work based on the law below. An unreasonable suspension is an unreasonable suspension and an express order to stop the work does not negate the effects of what really amounts to a suspension.
“Constructive suspension occurs when work is stopped absent an express order by the contracting officer and the government is found to be responsible for the work stoppage.” P.R. Burke Corp. v. U.S., 277 F.3d 1346, 1359 (Fed. Cir. 2002). The government delay must be unreasonable to support a constructive acceleration claim. Id.
“To demonstrate such a constructive suspension of work, the contractor must show that the delay (1) was for an ‘unreasonable length of time,’ (2) was proximately caused by the government’s actions, and (3) resulted in some injury to the contractor.” Fireman’s Fund Ins. Co. v. U.S., 2001 WL 36415627, *6 (Fed.Cl. 2001) (citation omitted). “Relative to proving that the delay was directly caused by the government, the contractor must concomitantly show that it was not delayed by any concurrent cause that would have independently generated the delay during the same time period even if it does not predominate over the government’s action as the cause of the delay.” Beauchamp Const. Co. v. U.S., 14 Cl.Ct. 430, 437 (Cl.Ct. 1988).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
No Signature? Potentially No Problem for Sureties Enforcing a Bond’s Forum Selection Clause
March 21, 2022 —
Brian C. Padove - ConsensusDocsOne of the foundational tenets of contract law is that a party may only be bound by terms they agree to, or in other words, if the party did not sign a contract, that party cannot be bound by the terms thereof. While this principle is generally unwavering, there are certain situations in which a non-signatory to a contract may still be bound by the terms of a contract.
In particular, this non-signatory issue may arise when a payment bond claimant makes a bond claim, subsequently files a lawsuit, but the bond contains a forum selection clause different than the venue of the lawsuit and the surety seeks to enforce the bond’s forum selection clause. For example, the claimant may have filed its lawsuit against the surety in federal court, even though the bond provides language specifically mandating that no lawsuit shall be commenced by any claimant other than in a state court where the project is located. Thus, the question then becomes, can the surety enforce the forum selection clause against the claimant when the claimant did not sign the bond and/or never agreed to the terms thereof? The short answer, it depends (yes, that is a very lawyer-like answer). Given recent case law over the past decade, however, the surety has a strong argument in favor of enforcement of the forum selection clause.
Read the court decisionRead the full story...Reprinted courtesy of
Brian C. Padove, Watt, Tieder, Hoffar & Fitzgerald, LLP (ConsensusDocs)Mr. Padove may be contacted at
bpadove@watttieder.com
Newark Trial Team Obtains Affirmance of Summary Judgment for General Contractor Client
January 21, 2025 —
Lewis Brisbois NewsroomNewark, N.J. (December 31, 2024) - Days after
obtaining an Appellate Division victory affirming a “no cause” jury verdict, Newark Partner Afsha Noran and Managing Partner Colin Hackett obtained a
second appellate court victory affirming a trial court's dismissal of a complaint against another firm client, a general contractor.
The team had previously obtained summary judgment at the trial level on the grounds plaintiff could not establish a prima facie case against the client. The plaintiff appealed the grant of summary judgment and dismissal of her claim to the Appellate Division.
Read the court decisionRead the full story...Reprinted courtesy of
Lewis Brisbois
Managing Once-in-a-Generation Construction Problems – Part II
April 03, 2023 —
Jeffrey S. Wertman - Construction ExecutivePart I of this series discussed the benefits of construction participants using alternative project delivery methods and properly addressing change order issues, rising costs and payment structure issues to manage construction during these uncertain times. Part II below explores the possibility that higher prices and steady consumer demand could lead to an increase in unscrupulous contractor practices—and how owners can mitigate that risk, managing the challenges posed by the unforeseen labor shortage and turnover in the industry and evolving your construction team for short-term and long-term success.
Higher Prices and Steady Demand
With the demand for construction projects relatively stable, contractors remaining in high demand and a surge in prices for construction materials and components, owners are under great pressure to accept less favorable construction terms. This has presented unscrupulous contractors with perceived leverage over owners and new opportunities to engage in questionable business practices and fraud. Although some contractors may seek to stretch the boundaries of a construction contract, other contractors are more deliberate. Falsifying payment applications and invoices to inflate labor or materials costs, billing for work not yet performed or materials not yet delivered to the project site and manipulating change orders are examples of illicit and fraudulent practices by contractors.
Reprinted courtesy of
Jeffrey S. Wertman, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
On the Ten Year Anniversary of the JOBS Act A Look-Back at the Development of Crowdfunding
May 02, 2022 —
J. Kyle Janecek & Jeffrey M. Dennis - Newmeyer DillionLast month marked the ten-year anniversary of the Jumpstart Our Business Startups (JOBS) Act, which was signed into law by President Obama on April 5, 2012. On May 16, 2016, Title III of the JOBS Act was enacted, as the final piece of the JOBS Act, which gave businesses better access to crowdfunding tactics due to the ability to raise funds based on equity. Today, the JOBS Act and the impact of equity crowdfunding more generally has grown among multiple industries, from entertainment and technology to real estate and construction, and has come a long way from the non-equity crowdfunding of Kickstarter and Indiegogo. So what have been the powers that businesses gained from Title III of the JOBS Act? What has been the impact of the last ten years? Where do businesses go from here to better utilize this source of funding?
WHAT ARE THE CROWDFUNDING POWERS GIVEN BY THE JOBS ACT?
The main difference and change that the JOBS Act had on the field of "crowdfunding" was that for the first time, unaccredited investors could obtain equity stakes in businesses through online solicitations. However, a business was still required to go through the proper approved channels, like accredited crowdfunding portals to solicit and receive funding. Prior to this, crowdfunding had gotten more of an impact and reputation from platforms like Kickstarter and Indiegogo, platforms that benefitted creative works or could act as a "pre-order" system with no guaranty of performance or quality of goods by the party seeking funds.
Reprinted courtesy of
J. Kyle Janecek, Newmeyer Dillion and
Jeffrey M. Dennis, Newmeyer Dillion
Mr. Janecek may be contacted at kyle.janecek@ndlf.com
Mr. Dennis may be contacted at jeff.dennis@ndlf.com
Read the court decisionRead the full story...Reprinted courtesy of
First Railroad Bridge Between Russia and China Set to Open
August 06, 2019 —
Saibal Dasgupta - Engineering News-RecordWork was completed on the first-ever railroad bridge connecting Russia to China in early April, as Russian engineers installed the final steel beam in its section of the structure over the river called the Amur in Russian and the Heilongjiang. China finished its part of the work last October, as the structure successfully spanned the world's 10th longest river, which markets the boundary between the two countries. Officials say the bridge will open for public use after the necessary inspections in July this year.
Read the court decisionRead the full story...Reprinted courtesy of
Saibal Dasgupta, ENRENR may be contacted at
ENR.com@bnpmedia.com
Limiting Liability: Three Clauses to Consider in your Next Construction Contract
June 25, 2019 —
Tara Lynch - Gordon & Rees Construction Law BlogIn your next contract, consider including some (or all!) of the following clauses to limit your liability and maximize your profits.
Waiver of Consequential Damages
While a proven breach of contract will leave a design professional or contractor exposed to direct or compensatory damages, a waiver of consequential damages will help “stop the bleeding” and protect the design professional or contractor from paying every damage that might flow from the breach. Consequential damages include those damages which indirectly flow from the breach of contract, for example, lost rents, lost profits, lost use, lost opportunity, loss of employee productivity, and damages to reputation.
The American Institute of Architects (AIA) has included a mutual waiver of consequential damages in its sample A201 for over 20 years. The AIA provision includes a definition of consequential damages which are waived, including many of the examples cited above. However, the AIA waiver of consequential damages clause carves out an exception for liquidated damages to the owner. Prudent design professionals and contractors will strike this exception so as not to render the clause meaningless. A well-drafted waiver clause will be mutual, will define which damages are consequential versus direct, and will not contain exceptions.
Read the court decisionRead the full story...Reprinted courtesy of
Tara Lynch - Gordon & Rees Scully MansukhaniMs. Lynch may be contacted at
tlynch@grsm.com
Competitive Bidding Statute: When it Applies and When it Does Not
April 15, 2024 —
Mason Fletcher - Ahlers Cressman & Sleight PLLCThe University of Washington (UW), a public university, aimed to secure a real estate developer for a new building on its campus. The proposal involved an 80-year ground lease (the “Lease”), and developers submitted bids. The selected developer would demolish an existing building, construct a new one, own it during the Lease at its own cost, and UW would lease back a portion, with ownership reverting to UW at the Lease’s end. Alexandria Real Equities, Inc. (ARE) was a finalist but ultimately was not selected, and the Lease was awarded to Wexford Science and Technology, LLC (Wexford). As a result, ARE filed suit against UW asserting three claims: 1) UW lacked authority to execute the Lease, 2) UW didn’t follow required competitive bidding procedures, and 3) UW’s developer selection process was arbitrary and capricious. None of these claims were successful and ARE appealed.
Division II of the Washington Court of Appeals affirmed in Alexandria Real Estate Equities Inc. v. Univ. of Wash., __ Wn. App. __, 539 P.3d 54 (2023), a published decision. The Court concluded, based on the facts in that case, that because construction was not publicly funded, UW did not have to follow competitive bidding requirements that were laid out in a statute relevant to state universities. Still, the Court applied the “bright-line cutoff point” that prohibits disappointed bidders from challenging an award once a contract has been executed. See Dick Enterprises, Inc. v. Metro. King County, 83 Wn. App. 566, 572, 922 P.2d 184 (1996).
Read the court decisionRead the full story...Reprinted courtesy of
Mason Fletcher, Ahlers Cressman & Sleight PLLCMr. Fletcher may be contacted at
mason.fletcher@acslawyers.com
