Risk Transfer: The Souffle of Construction Litigation
December 13, 2022 —
Alexa Stephenson & Ivette Kincaid - Kahana FeldWho does not love a good souffle?! Enthusiasts will know that a great souffle is not something you can obtain quickly. Rather, it is common in restaurants to order the souffle as dessert at the beginning of the meal because it takes an hour to bake. Risk transfer – like a good souffle – also requires planning, preparation, and the right ingredients.
In construction litigation, attorneys are often not retained until after the project has been completed for several years as the dispute between the homeowner and the general contractor or developer took time to escalate to formal litigation. A significant part of defense counsel’s legal analysis involves assessing and evaluating risk transfer opportunities. For example, in the case of a general contractor or developer who did not self-perform the construction work but instead retained subcontractors to do so, counsel will assess if risk can be transferred from the general contractor or developer to the subcontractors who performed the work which the homeowners allege is defective. In other words, a developer or general contractor can reduce their risk (i.e. liability and money owed) by transferring said risk (i.e. pointing the finger at) to a third party.
Sounds easy, right? Unfortunately, just like the souffle making process, it is easier said than done. This task can be exceedingly difficult in the absence of contracts that contain strong indemnity and insurance provisions – the essential ingredients to effect risk transfer. Worry not! We have provided “baking” instructions for you below to help you get a great risk transfer souffle time and again.
Reprinted courtesy of
Alexa Stephenson, Kahana Feld and
Ivette Kincaid, Kahana Feld
Ms. Stephenson may be contacted at astephenson@kahanafeld.com
Ms. Kincaid may be contacted at ikincaid@kahanafeld.com
Read the court decisionRead the full story...Reprinted courtesy of
Formal Request for Time Extension Not Always Required to Support Constructive Acceleration
April 25, 2022 —
David Adelstein - Florida Construction Legal UpdatesDoes a constructive acceleration claim require the contractor to always request an extension of time which is then denied by the owner? While this is certainly the preference and the contractor should be requesting an extension of time as a matter of course for an excusable delay, the answer is NO! in certain circumstances. This is conveyed in the factually detailed case discussed below where a formal request for an extension of time was not required for the contractor to support its constructive acceleration claim.
But first, what is constructive acceleration:
Constructive acceleration “occurs when the government demands compliance with an original contract deadline, despite excusable delay by the contractor.” The Federal Circuit in Fraser defined the elements of constructive acceleration as follows:
(1) that the contractor encountered a delay that is excusable under the contract; (2) that the contractor made a timely and sufficient request for an extension of the contract schedule; (3) that the government denied the contractor’s request for an extension or failed to act on it within a reasonable time; (4) that the government insisted on completion of the contract within a period shorter than the period to which the contractor would be entitled by taking into account the period of excusable delay, after which the contractor notified the government that it regarded the alleged order to accelerate as a constructive change in the contract; and (5) that the contractor was required to expend extra resources to compensate for the lost time and remain on schedule.
Nova Group/Tutor-Saliba v. U.S., 2022 WL 815826, *42 (Fed.Cl. 2022) quoting Fraser Constr. Co. v. U.S., 384 F.3d 1354, 1361 (Fed. Cir. 2004) (internal citations omitted).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
State-Fed Fight Heats Up Over Building Private Nuclear Disposal Sites
August 03, 2022 —
Mary B. Powers & Debra K. Rubin - Engineering News-RecordThe U.S. Nuclear Regulatory Commission and Interim Storage Partners, a joint venture that gained a federal license last year to build an interim storage facility for spent commercial nuclear fuel at a Texas site, have until Aug. 3 to answer a federal lawsuit claim by state officials that a new U.S. Supreme Court decision eliminates the federal agency’s licensing authority.
Reprinted courtesy of
Mary B. Powers, Engineering News-Record and
Debra K. Rubin, Engineering News-Record
Ms. Rubin may be contacted at rubind@enr.com
Read the full story...
Read the court decisionRead the full story...Reprinted courtesy of
Green Construction Claims: More of the Same
May 10, 2021 —
Christopher G. Hill - Construction Law MusingsFor this week’s Guest Post Friday, Musings welcomes back Timothy R. Hughes, Esq., LEED AP. Tim (@timrhughes on Twitter) is a Shareholder in the Arlington, Virginia firm of Bean, Kinney & Korman, P.C. In his practice as a business, corporate, and construction law attorney, Tim was the Chair of the Construction Law and Public Contracts Section of the Virginia State Bar. He was recognized by Virginia Lawyer’s Weekly as a 2010 “Leader in the Law” and a member of the Legal Elite for Construction Law for 2010 by Virginia Business Magazine. A regular speaker and writer, Tim is the lead editor of his firm blog, Virginia Real Estate, Land Use and Construction Law.
Green construction liability risk has received a lot of discussion over time. My take is that sustainable design and construction projects present the same type of risk profile as other construction projects, with the caveat that there may be “a little more”. A little more risk. A little more lack of predictability. A little more process overlay. Thus, green construction claims really are just “more of the same”.
I have watched and participated in the discussion. With regards to the Chesapeake Bay Foundation building, the reality is that any project can face challenges of product specification and performance, green or not. We can see plenty of examples where products have created tremendous risk and liability to the construction industry, the avalanche of EIFS litigation and Chinese drywall standing as just two of the most recent examples. A product failed, but that is nothing truly new.
Read the court decisionRead the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
Complying With Data Breach Regulations in the Construction Industry
November 24, 2019 —
Ryan Bilbrey - Construction ExecutiveRecent data breach incidents—like the massive Capital One cyberattack, where a former employee accessed more than 100 million customer accounts and credit card applications—have left many users questioning how safe their information really is in the hands of companies.
There is reason to be concerned. More than 4.1 billion records were exposed in nearly 4,000 data breaches reported in the first half of 2019 alone, according to the 2019 MidYear QuickView Data Breach Report. Construction companies are not immune.
As the industry becomes more reliant on technology—using augmented reality, Building Information Modeling and drones on construction sites, for example—construction companies are becoming greater targets for hackers looking to gain a financial or strategic advantage.
Instead of assuming a company will never experience a breach (or rather, denying that it will ever happen), it’s important to be aware of possible threats and establish data breach response policies to minimize potentially catastrophic fallout.
Reprinted courtesy of
Ryan Bilbrey, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Mr. Bilbrey may be contacted at
rbilbrey@biaprotect.com
Bremer Whyte Brown & O’Meara LLP Attorneys to Speak at the 2016 National Construction Claims Conference
September 01, 2016 —
Beverley BevenFlorez-CDJ STAFFBremer Whyte Brown & O’Meara, LLP (BWBO), announced that Keith G. Bremer, Founding Partner and John H. Toohey, Partner, will be speaking at the CLM National Construction Claims Conference being held September 28-30th this year. More than 500 professionals will gather at the conference location, the Manchester Grand Hyatt in San Diego, California.
According to BWBO’s release, “the CLM will hold the most comprehensive construction claims conference ever. In addition to addressing construction defect claims, conference sessions will also address facets of construction-related claims including construction site accidents/injuries, coverage issues, subcontractor issues, and new technologies. Sessions will also address issues on the national, regional, and state levels.”
Read the court decisionRead the full story...Reprinted courtesy of
The Impact of Sopris Lodging v. Schofield Excavation on Timeliness of Colorado Construction Defect Claims
January 26, 2017 —
Jean Meyer - Colorado Construction LitigationOn October 20, 2016, the Colorado Court of Appeals announced the Sopris Lodging, LLC v. Schofield Excavation, Inc.[1] decision. The Sopris decision significantly altered the potential pitfalls awaiting a general contractor in pursuit of third-party claims as well as potential defenses available for a subcontractor defending against third-party claims.
By way of background, the Sopris construction defect case arose out of the following facts: TDC was the general contractor for the construction of a hotel owned by Sopris Lodging. On March 11, 2011, Sopris Lodging sent TDC a notice of claim regarding alleged construction defects. On May 24, 2013, Sopris Lodging filed a complaint in district court asserting construction defect claims against one of the subcontractors of the hotel, and against the general contractor’s principals, but not the general contractor. Contemporaneous with the filing of the suit, Sopris Lodging and TDC entered into an agreement to toll the statute of limitations on Sopris Lodging’s potential claims against TDC. In August 2013, Sopris Lodging joined the general contractor to the suit. A year later, in 2014, the general contractor joined a variety of subcontractors as third-party defendants.
Read the court decisionRead the full story...Reprinted courtesy of
Jean Meyer, Higgins, Hopkins, McLain & Roswell, LLCMr. Jean may be contacted at
meyer@hhmrlaw.com
Use of Dispute Review Boards in the Construction Process
December 27, 2021 —
Sarah B. Biser - ConsensusDocsDispute Review Boards: Overview
Problems, disagreements and claims arise in most large and complex construction projects regardless of the project delivery method. These disputes can and do delay and significantly increase the cost of the project. Dispute Review Boards, also known as Dispute Resolution Board, Dispute Board, Dispute Avoidance Board or DRB, are often found in large construction projects to assist the parties to minimize, resolve or avoid disputes and mitigate adverse impacts to projects. To date, over $270 billion worth of construction projects have used the dispute review board process to avoid numerous disputes and achieve significant savings.[1]
Unlike mediation and arbitration, a DRB is convened at the very beginning of the project and conducts regular meetings and visits at the project site throughout, allowing the DRB to discuss, observe and monitor construction, progress and potential disputes. At these meetings, DRB members become familiar with many of the facts and acquaint themselves with the job site personnel. If a dispute is submitted to them, the panelists have a great deal of knowledge about the circumstances of the problem to aid them in reaching their recommendations or conclusions. DRBs also encourage open and honest communications among or between the parties during the project, which in turn, encourages avoidance or resolution of disputes before they become formal claims. In short, the DRP process involves real-time discussion of the dispute with highly qualified people who know the particular project from day one and can provide recommendations on how to resolve disputes.
Read the court decisionRead the full story...Reprinted courtesy of
Sarah B. Biser, Fox Rothschild LLPMs. Biser may be contacted at
sbiser@foxrothschild.com
