FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Three Recent Cases Strike Down Liquidated Damages Clauses In Settlement Agreements…A Trend Or An Aberration?

November 01, 2021 — Adam M. Tuckman - ConsensusDocs
Beginning more than one century ago, owners and contractors generally have adopted the convention of including liquidated damages in their contracts to fix potential liability for delay (and other losses) at the inception of the project. The proliferation of liquidated damages clauses in modern contracts can be attributed to economic and legal factors. From the owner’s standpoint, it may be exceedingly difficult to prove the actual cost impact of a delayed completion of the project. A properly calculated liquidated damages rate would save the owner the significant expense of quantifying its delay damages. On the contractor’s side, a reasonable amount of liquidated damages may be preferable to uncapped or unknown liability, allowing the contractor to more accurately price its bid and efficiently allocate risk. Coinciding with, or perhaps a leading cause of, the industry’s embrace of liquidated damages provisions, was the shift in courts throughout the country from disfavoring such clauses to accepting them (within limits) as an appropriate exercise of contract rights. While some variation exists among the states, courts have generally recognized that liquidated damages clauses are a viable alternative to proof of actual loss so long as (i) actual losses were difficult to quantify, and (ii) the stipulated sum bears a reasonable relationship to the anticipated loss at the time of contracting. See, e.g., Restatement (Second) of Contracts § 356. Conversely, a clause that penalizes the breaching party rather than serving as an estimate of probable loss is likely to be found unenforceable. Read the court decision
Read the full story...
Reprinted courtesy of Adam M. Tuckman, Watt, Tieder, Hoffar, & Fitzgerald, LLP
Mr. Tuckman may be contacted at atuckman@watttieder.com

---

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

State Farm Too Quick To Deny Coverage, Court Rules

July 22, 2011 — CDJ STAFF

On July 13, 2011, Judge Sarah S. Vance of the US District Court issued a rule in the case of Travelers Cas. & Surety Co. of Am. v. Univ. Facilities, Inc. (E.D. La., 2011). In this case, Stanley Smith Drywall was contracted by Capstone Building Corporation to “perform undisclosed work at the facility believed to involve the installation of drywall.” The project involved the design and construction of student residences for the Southeastern Louisiana University in Hammond, Louisiana. In May, 2009, University Facilities, Inc. (UFI) sued Capstone Development Corporation and Capstone On-Campus Management.



State Farm insured Stanley Smith Drywall and they sought a declaration that they have no duty: “(1) to insure Stanley Smith or CBC, or (2) to defend or indemnify any party against UFI's claims in the pending arbitration.” State Farm contends “(1) there is no "occurrence" to trigger coverage under the policy; (2) only breach of contract claims are asserted; (3) there is no property damage alleged; and (4) various coverage limitations and exclusions apply to prevent coverage.’



The court concluded that “whether State Farm has a duty to defend in the arbitration must be determined by considering the claims asserted in the arbitration.” However, the arbitration claims were not made part of the record. There, “, the Court cannot determine as a matter of law State Farm's duty to defend on the present record.” The same was true of State Farm’s duty to indemnify. “Stanley Smith and CBC assert that State Farm's motion for summary judgment was filed before any discovery was conducted in the arbitration proceeding or in this case. The Court finds that State Farm has failed to develop the record sufficiently to establish that there is no genuine issue of material fact as to its duty to indemnify Stanley Smith or CBC in the arbitration.’



The court denied State Farm’s motion for a summary judgment on its duty to defend and indemnify.



Read the court’s decision…

Read the court decision
Read the full story...
Reprinted courtesy of

---

Housing Prices Up through Most of Country

December 20, 2012 — CDJ STAFF
Home prices in October were up more than six percent compared with prices in October 2011. The LA Times noted that some of the strongest gains were in California and Arizona. The Phoenix metropolitan area saw a 24.5% rise in home prices. In California, Riverside and Los Angeles were just above the national average, at 7.3% and 6.4%, contributing to the state’s overall nine percent increase. The news wasn’t good throughout the entire country, as five states did not see any price increases. Mark Fleming, the chief economist at CoreLogic, a research firm in Irvine, California said that “the housing recovery that started earlier in 2012 continues to gain momentum. Read the court decision
Read the full story...
Reprinted courtesy of

---

California Supreme Court Rules Developers can be Required to Include Affordable Housing

June 17, 2015 — Beverley BevenFlorez-CDJ STAFF
The Los Angeles Times reported that in a unanimous decision, the California Supreme court justices declared that “cities and counties” can “require developers to sell some housing at below-market rates.” Chief Justice Tani Cantil-Sakauye wrote, “It will come as no surprise to anyone familiar with California’s current housing market that the significant problems arising from a scarcity of affordable housing have not been solved over the past three decades,” as quoted in the Los Angeles Times. Los Angeles Mayor Eric Garcetti applauded the decision: “This gives Los Angeles and other local governments another possible tool to use as we tackle our affordable housing crisis.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Mind The Appeal Or: A Lesson From Auto-Owners Insurance Co. V. Bolt Factory Lofts Owners Association, Inc. On Timing Insurance Bad Faith And Declaratory Judgment Insurance Claims Following A Nunn-Agreement

August 06, 2019 — Jean Meyer - Colorado Construction Litigation
On May 30, 2019, Judge Richard Brooke Jackson of the United States District Court for the District of Colorado offered an insightful lesson to the parties in Auto-Owners Insurance Co. v. Bolt Factory Lofts Owners Association, Inc.[1] on the importance of ripeness in declaratory judgment insurance actions and bad faith counterclaims. The case arrived in front of Judge Jackson based on the following fact pattern. A homeowner association (Bolt Factory Lofts Owners Association, Inc.) (“Association”) brought construction defect claims against a variety of prime contractors and those contractors subsequently brought third-party construction defect claims against subcontractors. One of the prime contractors assigned their claims against a subcontractor by the name Sierra Glass Co., Inc. (“Sierra”) to the Association and all the other claims between all the parties settled. On the eve of trial involving only the Association’s assigned claims against Sierra, the Association made a settlement demand on Sierra for $1.9 million. Sierra asked its insurance carrier, Auto-Owners Insurance, Co. (“AOIC”), which had been defending Sierra under a reservation of rights letter, to settle the case for that amount, but AOIC refused. This prompted Sierra to enter into a “Nunn-Agreement” with the Association whereby the case would proceed to trial, Sierra would refrain from offering a defense at trial, the Association would not pursue any recovery against Sierra for the judgment, and Sierra would assign any insurance bad faith claims it may have had against AOIC to the Association. (“Nunn-Agreement”) Read the court decision
Read the full story...
Reprinted courtesy of Jean Meyer, Higgins, Hopkins, McLain & Roswell, LLC
Mr. Meyer may be contacted at meyer@hhmrlaw.com

---

The Firm Hits the 9 Year Mark!

July 22, 2019 — Christopher G. Hill - Construction Law Musings
It was 9 years ago today that I announced the formation and start of my solo practice, The Law Office of Christopher G. Hill, PC. Back then, my children were in elementary and middle school. Now I have two college students, one at Appalachian State University (with a budding photography talent that has provided some photos for this blog (including that on this post)) and the other at West Virginia University, and a rising high school junior. In just the past year I began a tenure on the Section Council Virginia Bar Association Construction and Public Contracts Law section and chair of its Legislative Committee where I assisted in the drafting of the change in the mechanic’s lien form that takes effect today.. I was named to both the Virginia Business Magazine Legal Elite in Construction Law and for a 3rd consecutive year to Virginia Super Lawyers in Construction Litigation. I spoke on how to deal with a DPOR complaint this past November at the 39th Annual Construction Law and Public Contracts seminar (one I highly recommend for any lawyer interested in construction). Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

Construction Defect Claim Survives Insurer's Summary Judgment Motion Due to Lack of Evidence

December 23, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The court denied the insurer's motion for summary judgment on a construction defect claim due to lack of evidence. Statesboro Erectors, Inc. v. Owners Ins. Co., 2024 U.S. Dist. LEXIS 176555 (N.D. Ga. Sept. 30, 2024). Griffco was the general contractor for a construction project. King Steel was hired as the "steel fabricator." King Steel subcontracted with Statesboro Erectors to complete certain construction work at the site. Statesboro agreed to the complete, proper and safe erection of the structural steel. A steel collapse occurred at the construction site. According to King Steel, the collapse "appeared to have occurred due to lack of temporary cables or bracing for steel columns." Because of the collapse, King Steel was required to supply additional materials to replace the structural damage caused by the collapse. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---