Fairfield Connecticut Building Expert Directory

Affordable Global Housing Will Cost $11 Trillion

October 01, 2014 — Flavia Krause-Jackson – Bloomberg
Replacing the world’s substandard housing and building affordable alternatives to meet future global demand would cost as much as $11 trillion, according to initial findings in a McKinsey & Co. report. The shortage of decent accommodation means as many as 1.6 billion people from London to Shanghai may be forced to choose between shelter or necessities such as health care, food and education, data disclosed at the 2014 CityLab Conference in Los Angeles show. McKinsey will release the full report in October. The global consulting company says governments should release parcels of land at below-market prices, put housing developments near transportation and unlock idle property hoarded by speculators and investors. The report noted that China fines owners 20 percent of the land price if property is undeveloped after a year and has the right to subsequently confiscate it. Read the court decision
Read the full story...
Reprinted courtesy of Flavia Krause-Jackson, Bloomberg
Ms. Krause-Jackson may be contacted at fjackson@bloomberg.net

“Good Faith” May Not Be Good Enough: California Supreme Court to Decide When General Contractors Can Withhold Retention

March 22, 2018 — Erinn Contreras and Joy O. Siu – Construction & Infrastructure Law Blog
It is industry standard in California for owners of a construction project to make monthly payments to a contractor for work it has completed, less a certain percentage that is withheld as a guarantee of future satisfactory performance. This withholding is called a retention. Contractors generally pass these withholdings on to their subcontractors via a retention clause in the subcontract. Under such clause, if a subcontractor fails to complete its work or correct deficiencies in its work, the owner and the general contractor may use the retention to bring the subcontractor’s work into conformance with the requirements of the contract. When and how retention payments must be released are governed by, among other statutes, Civil Code section 8800 et seq. Specifically, Civil Code section 8814, subdivision (a), states that a direct contractor must pay each subcontractor its share of a retention payment within ten days after the general contractor receives all or part of a retention payment. Failure to make payments in accordance with Section 8814 can subject an owner or a contractor to a (1) two percent penalty per a month on the amount wrongfully withheld, and (2) claim for attorney’s fees for any litigation required to collect the wrongfully withheld retention payments. (Civ. Code, § 8818.) Reprinted courtesy of Erinn Contreras, Sheppard, Mullin, Richter & Hampton LLP and Joy Siu, Sheppard, Mullin, Richter & Hampton LLP Ms. Contreras may be contacted at econtreras@sheppardmullin.com Ms. Siu may be contacted at jsiu@sheppardmullin.com Read the court decision
Read the full story...
Reprinted courtesy of

How Does Your Construction Contract Treat Float

November 08, 2017 — David Adelstein - Florida Construction Legal Updates
Although there are different types of construction schedule float and more technical definitions, the definition that makes sense to me is that float is the amount of time a particular activity can be delayed without that activity delaying the project’s completion date (substantial completion date). In looking at a construction schedule, this determination is made from looking at the difference between the early start date for an activity and the late start date for that activity or the difference between the early finish date for that activity and the late finish date for that activity in your CPM schedule (which should be the same amount of time). This is often referred to as “total float” and is the float that I usually focus on since it may pertain to a delay to the substantial completion date of the project and can trigger either the assessment of liquidated damages and/or the contractor’s extended general conditions, whatever the case may be. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at Dadelstein@gmail.com

Mutual Or Concurrent Delay Caused By Subcontractors

March 23, 2020 — David Adelstein - Florida Construction Legal Updates
How are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project? Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs. There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project. The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Scientists found a way to make Cement Greener

October 01, 2014 — Beverley BevenFlorez-CDJ STAFF
According to Futurity, scientists say by “paying attention to concrete’s atomic structure…they could make it better and more environmentally friendly.” Cement currently is “the third-largest source of carbon dioxide released to the atmosphere.” Materials scientist Rouzbeh Shahsavari stated that “[t]he heart of concrete is C-S-H—that’s calcium, silicate, and hydrate (water). There are impurities, but C-S-H is the key binder that holds everything together, so that’s what we focused on.” The team spent a year in research and “looked at defects in about 150 mixtures of C-S-H to see how the molecules lined up and how their regimentation or randomness affected the product’s strength and ductility.” Read the court decision
Read the full story...
Reprinted courtesy of

Communications between Counsel and PR Firm Hired by Counsel Held Discoverable

March 22, 2017 — Kevin R. Crisp, David W. Evans, & Sarah A. Marsey – Haight Brown & Bonesteel LLP
Counsel handling cases involving newsworthy facts and litigation often hire public relations (“PR”) consultants. In Nicholas Behunin v. The Superior Court of Los Angeles County, 2017 DJDAR 2405 (No. B272225 March 14, 2017) the California Court of Appeal, Second District, denied a petition for writ of mandate concerning a trial court discovery order holding that communications between a plaintiff’s attorney and a public relations firm counsel hired for the purpose of creating a website for the Plaintiff were discoverable, despite claims that such communications were protected from disclosure by attorney-client privilege. Plaintiff sued Defendants -- (the) Charles Schwab and his son Michael Schwab -- over an unsuccessful real estate investment. Plaintiff’s attorneys hired a public relations consultant to create a website (www.chuck-you.com) that sought to link the Schwabs with the late Indonesian dictator Suharto’s family. The court succinctly described the web site as “a social media campaign to induce the Schwabs to settle the case.” Reprinted courtesy of Haight Brown & Bonesteel LLP attorneys Kevin R. Crisp, David W. Evans and Sarah A. Marsey Mr. Crisp may be contacted at kcrisp@hbblaw.com Mr. Evans may be contacted at devans@hbblaw.com Ms. Marsey may be contacted at smarsey@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Defects in Texas High School Stadium Angers Residents

March 07, 2014 — Beverley BevenFlorez-CDJ STAFF
According to WFAA News, many residents of Allen, Texas were upset when their tax dollars were spent on a new high school football stadium, and they are angry now that alleged construction defects may cause the stadium to close, and perhaps not even reopen again this fall. There “is a disproportionately large amount of our tax dollars that goes just to Allen ISD," Rachel Palmer, an Allen resident, told WFAA News. However, Ben Pogue, president of Pogue Construction, the stadium’s general contractor called the situation “a road bump.” WPAA News also interviewed Dr. Simon Chao of the Department of Civil Engineering at the University of Texas at Arlington: "Cracking is fairly common in concrete," Chao stated. "The problem is the damage water may cause by getting in the cracks.” Read the court decision
Read the full story...
Reprinted courtesy of

Ohio Court of Appeals: Absolute Pollution Exclusion Bars Coverage For Workplace Coal-Tar Pitch Exposure Claims

January 24, 2018 — White and Williams LLP
On December 28, 2017, the Ohio Court of Appeals (Eighth District) held in GrafTech International, Ltd., et al. v. Pacific Employers Ins. Co., et al., No. 105258 that coverage for alleged injurious exposures to coal tar pitch was barred by a liability insurance policy’s absolute pollution exclusion. Applying Ohio law, the court concluded that Pacific Employers had no duty to defend GrafTech or pay defense costs in connection with claims by dozens of workers at Alcoa smelting plants that they were exposed to hazardous substances in GrafTech products supplied to Alcoa as early as 1942. Read the court decision
Read the full story...
Reprinted courtesy of White and Williams

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES