Seattle Washington Building Expert Directory

Couple Sues Attorney over Construction Defect Case, Loses

June 10, 2011 — CDJ STAFF

The California Court of Appeals has ruled against a couple who sued their lawyer, after they were unhappy with the results of a construction defect case. Craig and Jeanne Petrik sued Mahaffey and Associates for legal malpractice and breach of contract. Their lawyer, Douglas L. Mahaffey, had settled their case for $400,000. The Petricks claimed Mahaffey did not have the authority make an offer to compromise.

In the original case, Mahaffey held back the $400,000 awarded in the settlement until he and the Petricks came to terms on how much of that was owed to Mahaffey. The lower court concluded that the Petricks were due $146,323,18. The jury did not agree with the Petrik’s claim that conditions had been met in which Mahaffey would not be charging them costs.

Judges O’Leary and Ikola wrote the opinion, with the third judge on the panel, Judge Bedworth offering a dissent only on their view of the cost waiver clause.

Read the court’s opinion

Read the court decision
Read the full story...
Reprinted courtesy of

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Boston-area Asbestos-Abatement Firms Face Wage and Safety Complaints

January 26, 2017 — Justin Rice - Engineering News-Record
Several federal and state complaints against asbestos-abatement and demolition firms operating in Massachusetts have sprouted in the wake of the region’s construction boom. Involving mostly small companies and immigrant workers, the cases allege wage and benefit violations as well as improper exposure to asbestos fibers, which contain cancer-causing carcinogens. Read the court decision
Read the full story...
Reprinted courtesy of Justin Rice, ENR
Mr. Rice may be contacted at ricej@enr.com

Unpunished Racist Taunts: A Pennsylvania Harassment Case With No True 'Winner'

December 04, 2023 — Richard Korman - Engineering News-Record
The taunts started in the first days of Andre Pryce’s new job, camouflaged as joking. During the nine months of 2019 spent working as a drill rig hand, mostly in the woods in western Pennsylvania, for a contractor that also performs much construction-related drilling, he said coworkers filled his ears with racist insults. Reprinted courtesy of Richard Korman, Engineering News-Record Mr. Korman may be contacted at kormanr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Meet the Hipster Real Estate Developers Building for Millennials

October 02, 2015 — Ben Steverman – Bloomberg
John Chaffetz is showing off an apartment building that his development firm, Timberlane Partners, just bought for $7.2 million. He admits it doesn’t look so hot. “This has been treated like a prison camp,” he says of the 32-unit building in Los Angeles’s Echo Park neighborhood. Steel bars stick out of a cinder-block fence, threatening to impale someone. The front door is an ugly metal gate. But an organic supermarket opened around the corner in November, and a Blue Bottle Coffee just arrived down the block. There’s a farmers market nearby each Friday, and five minutes up Sunset Boulevard is the Silver Lake neighborhood, a nest of hipster cafes and places to buy rare cheese and handmade clothes. Timberlane plans to tear down the building’s security fencing, put terracotta back on the roof, and repair windows that date to its pre-1930 construction. “The goal,” Chaffetz says, “is for this to look like a Moroccan boutique hotel.” Read the court decision
Read the full story...
Reprinted courtesy of Ben Steverman, Bloomberg

The Job is Substantially Complete, the Subcontract was Never Signed, the Subcontractor Wants to be Paid—Now What?

July 28, 2016 — John P. Ahlers – Ahlers & Cressman PLLC
A recent case in North Carolina illustrates the types of problems created when a general contractor accepts a subcontractor’s bid and then allows the subcontractor to perform the work without obtaining a signed subcontract.[i] In this case, the general contractor (Choate Construction Company – “Choate”) accepted a bid from a foundation subcontractor (Southeast Caissons, LLC – “SEC”). Choate sent the subcontract to SEC. SEC provided its changes in a “Proposed Addendum” to the subcontract stating, “[SEC] hereby accepts the terms of the attached Subcontract, subject to and conditioned upon Choate[’s] acceptance of the terms set forth in this Addendum[.]” After that, Choate called SEC and exchanged emails concerning the subcontract terms, but did not reach an agreement. SEC then performed its subcontract and sought payment, and acknowledged it had not signed the subcontract. Choate agreed it owed SEC something, but refused to pay because SEC did not have a signed subcontract, asserting the subcontract was not binding on Choate. Read the court decision
Read the full story...
Reprinted courtesy of John P. Ahlers, Ahlers & Cressman PLLC
Mr. Ahlers may be contacted at jahlers@ac-lawyers.com

Insurance Policy’s “No Voluntary Payment” Clauses Lose Some Bite in Colorado

October 22, 2013 — Brady Iandiorio — Higgins, Hopkins, McLain & Roswell, LLC.
The Colorado Court of Appeals recently handed down an opinion dulling the teeth of the “no voluntary payment” clauses found in many contractors’ insurance policies. In the case of Stresscon Corporation v. Travelers Property Casualty Company of America, 2013 WL 4874352 (Colo. App. 2013), the Court of Appeals found that an insured’s breach of the “no voluntary payment” clause does not always bar the insured from receiving benefits from its insurance company. In July 2007, at a construction project run by Mortenson (the “GC”), a partially erected building collapsed, killing one worker and gravely injuring another. The collapse was caused by a crane hook pulling a concrete component off of its supports. The GC contracted with Stresscon Corporation (“Stresscon”) to build pre-cast concrete components for the project, and in turn Stresscon hired two sub-subcontractors, RMS and Hardrock (the “Crane Team”) to work together to erect those concrete components. Stresscon and the Crane Team had liability insurance, and Stresscon was insured by Travelers Property Casualty Company of America (“Travelers”). The accident led to three separate lawsuits: 1) one brought by the deceased worker; 2) one brought by the injured worker; and 3) one brought by the GC against Stresscon claiming it was entitled to contract damages incurred because the project was delayed. Read the court decision
Read the full story...
Reprinted courtesy of Brady Iandiorio
Brady Iandiorio can be contacted at Iandiorio@hhmrlaw.com

Lis Pendens – Recordation and Dissolution

July 28, 2016 — David Adelstein – Florida Construction Legal Updates
When you file a construction lien foreclosure lawsuit, you must also record a lis pendens in the official (public) records against the property. This lis pendens serves as written notice that there is a lawsuit concerning the real property, and more specifically, title relating to that real property. If the property is then sold or rented, the buyer or tenant will ultimately be bound by a final determination relating to the lawsuit concerning title to the property. This is the value in recording a lis pendens and why it is a MUST in any foreclosure lawsuit. (This is the same value in any mortgage foreclosure lawsuit and why lis pendens are recorded in these lawsuits too.) A lis pendens will show up in a title report. In most instances, title companies will not issue a title policy if there is a lis pendens or may require a certain amount of money escrowed as a result of the lis pendens and pending action in order to issue a title policy. Also, a buyer, in particular, and a tenant are not going to want to invest in property where the title to that property is at-issue in a lawsuit. Hence, the lis pendens impacts the sale and potential re-financing of the property. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES