Fairfield Connecticut Building Expert Directory

Supply Chain Delay Recommendations

August 07, 2022 — Denise Motta - Gordon & Rees Construction Law Blog
This Bulletin provides guidance to contractors, subcontractors, suppliers, and others to ensure compliance with contractual change order requirements in the event work on a construction project is impacted by supply chain delays. Contract Protection Tips: The construction industry is being impacted substantially by inability to obtain necessary construction products due to supply chain issues. Most construction contracts do not accommodate time extensions due to supply chain impacts. To address this gap in contract terms, we recommend including language such as: “lack of or failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers” as part of the defined force majeure event under the contract. This provision can be included in the Change Order section of the contract as well by including a provision such as: “If the Work is delayed by the failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers, contractor shall be entitled to a change order for its costs and time associated with the delay.” Read the court decision
Read the full story...
Reprinted courtesy of Denise Motta, Gordon Rees Scully Mansukhani, LLP
Ms. Motta may be contacted at dmotta@grsm.com

The Court of Appeals Holds That Indifference to Safety Satisfies the Standard for a Willful Violation Under WISHA

May 16, 2022 — Cameron Sheldon - Ahlers Cressman & Sleight PLLC
In March 2022, the Washington State Court of Appeals, Division One, issued Marpac Constr., LLC v. Dep’t of Lab. & Indus., No. 82200-4-I, 2022 WL 896850, at *1 (Wash. Ct. App. Mar. 28, 2022) holding Marpac Construction, LLC (“Marpac”) liable for three willful Washington Industrial Safety and Health Act of 1973 (WISHA) violations pertaining to safe crane operation near energized power lines. Marpac was the general contractor on an apartment complex construction project in West Seattle. The worksite had high voltage power lines running throughout the site. Seattle City Light had flagged some with a 10-foot offset, but none of the other power lines were flagged. Marpac’s superintendent assumed that the lines were between 26 kilovolts (kV) and 50 kV based on their connection to the lines flagged by Seattle City Light. The superintendent never called Seattle City Light to check the voltage of the lines and the lines remained above ground. In September 2016, a subcontractor began work on the project’s structural foundation. The subcontractor expressed concerns about working around the power lines, but Marpac promised it was working on mitigation of the power line hazard and directed the subcontractor continue working. At one point, the subcontractor’s employees had to move the crane and concrete forms away from the power lines to allow a cement truck to park in its place. The crane’s line contacted the power lines, causing serious injuries to two of the subcontractor’s employees. Read the court decision
Read the full story...
Reprinted courtesy of Cameron Sheldon, Ahlers Cressman & Sleight PLLC
Ms. Sheldon may be contacted at cameron.sheldon@acslawyers.com

A Retrospective As-Built Schedule Analysis Can Be Used to Support Delay

May 23, 2022 — David Adelstein - Florida Construction Legal Updates
Delay claims are part of construction. There should be no surprise why. Time is money. A delay claim should be accompanied by expert opinions that bolster evidence that gets introduced. The party against whom the delay claim is made will also have an expert – a rebuttal expert. Not surprisingly, each of the experts will rely on a different critical path as to relates to the same project. The party claiming delay will rely on a critical path that shows the actions of the other party impacted their critical path and proximately caused the delay. This will be refuted by the opposing expert that will challenge the critical path and the actions claimed had no impact on the critical path (i.e., did not proximately cause the delay). Quintessential finger pointing! This was the situation in CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022), where the government terminated the contractor for convenience and the contractor claimed equitable adjustments for, among other things, delay. The contractor’s expert relied on an as-built critical path analysis by “retrospectively creating updates to insert between the contemporaneous updates.” Id., supra, n.3. The government’s expert did not do a retrospective as-built analysis and relied on only contemporaneous schedule updates. Id. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

‘The Ground Just Gave Out’: How a Storm’s Fury Ravaged Asheville

October 07, 2024 — Michael Smith, Devon Pendleton, Claire Ballentine & Michael Sasso - Bloomberg
Eric Becker was at his vacation home in western North Carolina, in a community bordering the Pisgah National Forest and Blue Ridge Parkway, when the rain began to pour. Becker, co-founder of the private wealth management firm Cresset, lives in Florida for most of the year. He had lived through a hurricane — but nothing like what he saw during Helene. “Mud was liquefying around tree bases. You could see the root systems,” said Becker, who first began visiting the Asheville area 20 years ago and was smitten by its natural scenery, excellent food and lively arts and music scene. “The ground just gave out.” Becker is part of a wave of affluent homebuyers who have flocked to the southern Appalachian region. Transplants from wealth managers and retirees to artists and young outdoors enthusiasts have helped create a real estate goldrush in cities including Asheville, where home prices have climbed 69% in the past five years. Reprinted courtesy of Michael Smith, Bloomberg, Devon Pendleton, Bloomberg, Claire Ballentine, Bloomberg and Michael Sasso, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

Fatal Crane Collapse in Seattle Prompts Questions About Disassembly Procedures

July 09, 2019 — Jeff Rubenstone - Engineering News-Record
A tower crane being dismantled collapsed Saturday, April 27 in Seattle, killing four people, including two ironworkers on the crane and two bystanders on the street below. The jobsite, located in a Google office development in Seattle's bustling South Lake Union neighborhood, is adjacent to a busy intersection where traffic had not been blocked off during the crane’s disassembly. It is the first fatal crane accident in the Puget Sound region since a crane collapse in Bellevue, Wash., in 2006 that killed one person. Read the court decision
Read the full story...
Reprinted courtesy of Jeff Rubenstone, ENR
Mr. Rubenstone may be contacted at rubenstonej@enr.com

Insurer Must Defend Contractor Against Claims of Faulty Workmanship

May 30, 2018 — Tred R. Eyerly - Insurance Law Hawaii
The magistrate judge recommended that the insurer's motion for summary judgment seeking to determine there was no coverage for claims of faulty workmanship be denied. Greystone Multi-Family Builders v. Gemini Ins. Co., 2018 U.S. Dist. LEXIS 56770 (S.D. Tex. Feb. 26, 2018). TPG (Post Oak) purchased an OCIP policy to cover construction of an apartment complex. TPG was sued by the contractor, Greystone, after TPG cancelled the construction contract. TPG filed a counterclaim against the contractor, alleging that Greystone had failed to properly perform in building a luxury apartment complex which resulted in monetary damages to TPG. The complaint further alleged that the project was nine months behind its substantial completion date, far from complete, and over budget when TPG cancelled the contract. The cost to fix the mismanagement caused by Greystone was $18.9 million. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Florida Lawmakers Fail to Reach Agreement on Condominium Safety Bill

March 14, 2022 — Community Associations Institute
Falls Church, March 11, 2022 (GLOBE NEWSWIRE) -- Members of the Florida legislature did not reach an agreement on legislation that would require building inspections and mandatory reserve studies for certain condominium and cooperative communities prior to this session's adjournment, despite the tireless efforts from Sen. Jennifer Bradley (R-Orange Park) and Rep. Daniel Perez (R-Miami) as well as CAI advocates to pass legislation that would contribute to condominium safety after the tragic collapse of Champlain Towers South in Surfside, Fla., last June. The Virginia General Assembly recently passed legislation introduced by Sen. Scott Surovell (D-Fairfax, VA) that requires the Virginia Housing Commission to study condominium safety issues, specifically building inspections. The Maryland legislature is considering funding for condominium buildings in need of critical repairs, while Hawaii is considering building inspection requirements for condominiums. Learn more about CAI's efforts to improve condominium safety by visiting www.caionline.org/condosafety. About Community Associations Institute Since 1973, Community Associations Institute (CAI) has been the leading provider of resources and information for homeowners, volunteer board leaders, professional managers, and business professionals in the more than 355,000 homeowners associations, condominiums, and housing cooperatives in the United States and millions of communities worldwide. With more than 42,000 members, CAI works in partnership with 36 legislative action committees and 63 affiliated chapters within the U.S., Canada, South Africa, and the United Arab Emirates as well as with housing leaders in several other countries, including Australia, Spain, and the United Kingdom. A global nonprofit 501(c)(6) organization, CAI is the foremost authority in community association management, governance, education, and advocacy. Our mission is to inspire professionalism, effective leadership, and responsible citizenship—ideals reflected in community associations that are preferred places to call home. Visit us at www.caionline.org, and follow us on Twitter and Facebook @CAISocial. Read the court decision
Read the full story...
Reprinted courtesy of

Working Safely With Silica: Health Hazards and OSHA Compliance

January 17, 2022 — Rick Pedley - Construction Executive
About 2.3 million American workers are exposed to silica, including those in construction, oil and gas, agriculture and manufacturing. Silica is commonly found in a range of construction materials and when this material breaks apart, small particles are released into the air, creating what’s known as respirable crystalline silica. These particles can get into a person’s respiratory tract, which can lead to a range of serious and potentially fatal illnesses including silicosis, lung cancer, chronic obstructive pulmonary disease and kidney diseases. The Occupational Safety and Health Administration has set clear regulations for working with this substance, so construction workers and managers can know the risks of inhaling this substance and protect themselves on the job site. What is Silica? Crystalline silica is a mineral that forms naturally in the earth. Raw construction materials such as sand, stone, concrete and mortar often contain deposits of crystalline silica, which can put employees at risk. Silica becomes a danger to workers when it is released into the air and breathed in. Reprinted courtesy of Rick Pedley, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES