Fairfield Connecticut Building Expert Directory

Understanding Entitlement to Delays and Proper Support

December 10, 2024 — Andrew G. Vicknair - The Dispute Resolver
In a previous post, we discussed delays on construction projects including (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. We also reviewed the common methods of delay analysis include (1) the Total Cost Method, (2) the Modified Total Cost Approach, and (3) the Measured Mile Method. Once you have determined the type of delay and the method to be used to analyze and quantify the delay, it is important to understand the type of documents/evidence needed to support your claim for delay. If a party determines that they are entitled to some type of recovery for the delay, the party making a claim for delay, such as a contractor, must have the proper documentation/evidence to assist in proving entitlement for damages from the delay. Without the proper back-up, contractors are generally unable to recover all of the additional costs and expenses associated with the delays or, at best, recover only an “equitable” amount. Generally, damages must be proved with reasonable certainty and may not be based on speculation or conjecture. Thus, it is crucial for a party asserting a delay to have the proper documentation to support a delay claim, if the goal is to recover the damages associated with the delay. Read the court decision
Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

COVID-19 Is Not Direct Physical Loss Or Damage

April 13, 2020 — Joseph Blyskal, Dennis Brown & Michelle Bernard - Gordon & Rees Insurance Coverage Law Blog
Is a cash register that is not being used damaged property? When you need to wash a table, a chair, or a section of flooring with readily available cleaning products to make them safe and useable, are you repairing damaged property? Is a spilled cup of coffee waiting to be wiped up actual damage to the premises? If your customers stay home to help stop the spread of a virus, has there been a physical loss inside your shuttered store or restaurant? The insuring agreements typically found in commercial property insurance policies require “direct physical loss of or damage to” covered property as the triggering event. Without establishing direct physical loss or damage a policyholder cannot meet its burden to trigger coverage for a purely economic loss of business income resulting from shuttering its business due to concerns over exposure to—or even the actual presence of—COVID-19. Despite this well-understood policy language, it is already beyond question that insurers will confront creative—albeit strained—arguments from policyholder firms attempting to trigger coverage for pure economic loss. The scope of the human and economic tragedy we all face will be matched by the scope of the effort to force the financial harm onto insurance companies. The plaintiffs in what appears to be the first-filed case seeking a declaratory judgment in the context of first-party insurance coverage rely on the assertion that “contamination of the insured premises by the Coronavirus would be a direct physical loss needing remediation to clean the surfaces” of its establishment, a New Orleans restaurant, to trigger coverage for business interruption.[1] See Cajun Conti, LLC, et. al. v. Certain Underwriters at Lloyd’s, London, et. al. Civil District Court for the Parish of Orleans, State of Louisiana. The complaint alleges that the property is insured under an “all risk policy” defining “covered causes of loss” as “direct physical loss.” The plaintiffs rely on the alleged presence of the virus on “the surface of objects” in certain conditions and the need to clean those surfaces. They go so far as to claim that “[a]ny effort by [the insurer] to deny the reality that the virus causes physical damage and loss would constitute a false and potentially fraudulent misrepresentation. . . .” Reprinted courtesy of Gordon & Rees attorneys Joseph Blyskal, Dennis Brown and Michelle Bernard Mr. Blyskal may be contacted at tblatchley@grsm.com Mr. Brown may be contacted at dbrown@grsm.com Ms. Bernard may be contacted at mbernard@grsm.com Read the court decision
Read the full story...
Reprinted courtesy of

Appraisal Goes Forward Even Though Insurer Has Yet to Determine Coverage on Additional Claims

December 11, 2023 — Tred R. Eyerly - Insurance Law Hawaii
The trial court's order granting the insured's motion to stay litigation and compel an appraisal was affirmed even though the insurer had not determined coverage on the insured's additional claims.Heritage Prop. & Cas. Ins. Co. v. Wellington Place HOA, 2023 Fla. App. LEXIS 6405 (Fla. Ct. App. Sept. 13, 2023). The insured homeowner's association reported roof damage to its insurer, Heritage, after Hurrican Irma struck. Heritage agreed the damage was covered, but issued no payment because the amount of loss was less than the deductible. The insured hired its own adjuster. The insured requested an extension of the policy's two year time limit to complete repairs because the claim was still in dispute and the insurer had not yet paid sufficient funds to allow necessary repairs. Heritage sent a revised estimate and asked the insured to send its adjuster's estimate in order to address any disputes. The insured submitted its adjuster's estimate of more than $6 million, including, for the first time, the cost to replace all the windows and sliding glass doors. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

California Booms With FivePoint New Schools: Real Estate

May 13, 2014 — John Gittelsohn – Bloomberg
FivePoint Communities Management Inc. is already constructing a school at its Great Park Neighborhoods project in Irvine, California, for 1,000 elementary and middle school students even as it’s still building the first 700 homes. “We build the schools ahead of time,” said Emile Haddad, chief executive officer of Aliso Viejo, California-based FivePoint, which has permits for about 10,000 homes at Great Park. “That way we always have them ready.” Local schools, along with parks and recreation facilities, have long been draws for buyers in new communities. Now, as school districts face tight construction budgets and homebuilders compete to attract families able to qualify for mortgages, developers are taking the lead on school construction instead of waiting for local governments to do the job. Read the court decision
Read the full story...
Reprinted courtesy of John Gittelsohn, Bloomberg
Mr. Gittelsohn may be contacted at johngitt@bloomberg.net

East Coast Evaluates Damage After Fast-Moving 'Bomb Cyclone'

March 06, 2022 — Scott Van Voorhis - Engineering News-Record
Coastal areas in the northeast US are assessing damage from a fast-moving “bomb cyclone” that caused temperatures to plummet, triggered heavy flooding and high winds, and dumped 2 ft of snow in some New England areas. Reprinted courtesy of Scott Van Voorhis, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Mississippi Supreme Court Addresses Earth Movement Exclusion

December 09, 2019 — Anthony Hatzilabrou - Traub Lieberman
Recently, the Mississippi Supreme Court held that structural damages to the foundation of an insured’s home came within the earth movement exclusion in a homeowner’s policy, notwithstanding a provision in the policy which provided coverage for water damage resulting “from accidental discharge or overflow of water … from within … [p]lumbing, heating, air condition or household appliance.” In Mississippi Farm Bureau Cas. Ins. Co. v. Smith, 264 So. 3d 737 (Miss. 2019), the appellee, Smith, filed a lawsuit against her homeowner's insurance company, Mississippi Farm Bureau Casualty Insurance Company (“Farm Bureau”) for its refusal to pay for repairs to the foundation of Smith’s home. Smith alleged that the refusal to pay for repairs amounted to breach of contract and asserted claims for bad faith and tortious breach of contract. In response, Farm Bureau filed a motion for summary judgment on the basis of the policy’s earth-movement exclusion, which provided that Farm Bureau “did not insure for loss caused directly or indirectly by…Earth Movement…[which] means…[a]ny other earth movement including earth sinking, rising or shifting... caused by or resulting from human or animal forces.” Smith filed a cross-motion for partial summary judgment on the basis that the earth-movement exclusion did not preclude coverage because her insurance policy also contained a clause expressly covering water damage. Read the court decision
Read the full story...
Reprinted courtesy of Anthony Hatzilabrou, Traub Lieberman
Mr. Hatzilabrou may be contacted at thatzilabrou@tlsslaw.com

Construction Defect Leads to Death of Worker

January 28, 2013 — CDJ STAFF
The family of a Florida man has received $2.4 million in damages as a result of his death. Victor Lizarraga was killed when a steel column fell due to the anchor bolts being improperly secured. The general contractor on the project, R. L. Haines, told subcontractors that the epoxy had sufficient time to cure. An OSHA investigation determined that the epoxy was not used properly. Mr. Lizarraga worked for a subcontractor on the project. Mr. Lizarraga and his coworkers were hired to erect steel columns. The epoxy failed, sending a 1,750-pound column down onto Mr. Lizarraga. According to the lawsuit, "due to the sudden and unexpected nature of this incident Mr. Lizarraga had no ability, opportunity or time to get out of the way of the falling column." Other parties in the lawsuit settled with the family. R. L. Haines was the only defendant to go to a jury trial. Read the court decision
Read the full story...
Reprinted courtesy of

Lane Construction Sues JV Partner Skanska Over Orlando I-4 Project

February 08, 2021 — Scott Judy - Engineering News-Record
One of Florida’s most troubled construction projects is now in court, with one partner in a design-build joint venture pitted against another. Reprinted courtesy of Scott Judy, Engineering News-Record Mr. Judy may be contacted at judys@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES