Seattle Washington Building Expert Directory

Not So Fast, My Friend: Pacing and Concurrent Delay

April 25, 2022 — William E. Underwood - ConsensusDocs
When critical path activities are delayed by the owner (or another party), contractors will sometimes “pace,” or slow down, other activities to match the owner-caused delay. After all, why should the contractor hurry up and wait? But paced activities can often appear as concurrent delays on a project’s overall schedule. And all too often, contractors fail to contemporaneously document their efforts to pace work. Not only can this create avoidable disputes with owners and other contractors, but it can also create future roadblocks to the recovery of delay damages. This article examines the interplay between pacing and concurrent delay[1] and what contractors should do to minimize risk and preserve their rights to obtain more than a simple time extension for project delays. Pacing versus Concurrent Delay As a basic matter, most contracts allocate responsibility/liability for a schedule delay to the party that caused the delay. For example, if an owner is contractually required to provide equipment for a contractor to install, then the owner likely bears responsibility for any delays caused if the equipment is delivered late. If, however, the contractor was also behind schedule on other activities during this time and the project would have been delayed regardless of the owner’s late deliveries, then the delay is probably concurrent. And the contractor will generally be entitled to only an extension of time, and no other monetary relief. Read the court decision
Read the full story...
Reprinted courtesy of William E. Underwood, Jones Walker LLP (ConsensusDocs)
Mr. Underwood may be contacted at wunderwood@joneswalker.com

Tension Over Municipal Gas Bans Creates Uncertainty for Real Estate Developers

February 07, 2022 — Sidney L. Fowler, Robert G. Howard & Emily Huang - Gravel2Gavel Construction & Real Estate Law Blog
On November 15, 2021, the New York City Council approved a bill banning gas hookups in new buildings, making the biggest city in the U.S. the latest in a string of municipalities to prohibit natural gas infrastructure in new homes and buildings. In the two-and-a-half years since Berkeley, California, passed its then-novel municipal ban on new natural gas infrastructure, numerous cities have found themselves at odds with state governments and industry groups on the issue of full electrification in residential and commercial real estate. The resulting disputes, litigation and regulatory uncertainty have created headaches for the real estate industry. Although not all view the restrictions as negative, and many developers have embraced the push for more climate-neutral buildings, these bans introduce complexity to the real estate market, raising additional legal and commercial challenges. Background According to the U.S. Environmental Protection Agency, the use of natural gas in homes and businesses accounts for 13 percent of annual U.S. greenhouse gas emissions. For that reason, advocacy groups have pushed cities to prohibit natural gas infrastructure in new construction and encourage full electrification of newly constructed buildings. In addition to New York and Berkeley, cities that have either passed or considered such ordinances include San Francisco, Sacramento, Seattle and Denver, as well as numerous smaller cities. New York City’s newly passed gas ban, in particular, prohibits natural gas hookups in new buildings under seven stories by 2024, and in taller buildings by 2027, but exempts hookups in commercial kitchens. Reprinted courtesy of Sidney L. Fowler, Pillsbury, Robert G. Howard, Pillsbury and Emily Huang, Pillsbury Mr. Fowler may be contacted at sidney.fowler@pillsburylaw.com Mr. Howard may be contacted at robert.howard@pillsburylaw.com Ms. Huang may be contacted at emily.huang@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Seller Faces Federal Charges for Lying on Real Estate Disclosure Forms

October 02, 2015 — Beverley BevenFlorez-CDJ STAFF
Homeowners Glenn and Kathryn Jasen allegedly mislead buyers Kelly Magbee and family when they checked “no” on questions regarding sinkhole activity on real estate disclosure forms, according to On Your Side News. Furthermore, “Citizens Property Insurance Co. failed to file a sinkhole certification on a Spring Hill home in 2009. The company slipped the form into county records five years later- in Sept. 2014 – after questions from 8 On Your Side.” If the insurance company had filed the sinkhole documentation, then the Magbees would have been told about the sinkhole prior to the purchase of the home. According to On Your Side News, Magbee and family moved out of the home “after a crack opened in the living room.” Read the court decision
Read the full story...
Reprinted courtesy of

The New Industrial Revolution: Rebuilding America and the World

March 04, 2019 — Drew Buechley - Construction Executive
Conventional thinking says the Industrial Revolution ended more than a century ago. Yet one crucial industry has lagged behind revolutionary changes stemming from the transition from hand production methods to the use of machines and rise of factory systems. In the 1800s, these transitions caused an influx of people to urban centers, where the majority of those changes were centered. The outcome? Not enough capital or time to build adequate housing, pushing low-income newcomers into overcrowded, unsanitary slums, resulting in increased death rates and endemic levels of contagious diseases. While other industries mechanized and surged, construction remained stagnant in comparison to demand. Fast forward to the 21st century where the U.S .benefits from a developed and industrialized world. Monumental gains in technology, combined with regulations designed to protect communities from polluted waters and disease, have drastically improved quality of life. Yet one similarity remains – the industry still struggles to build enough housing for a growing population. Urban centers have been neglected for decades while the rate of urbanization increases annually. Communities still have no access to clean drinking water and many suffer from crumbling infrastructure. Home ownership is out of reach for an entire generation, with metropolitan areas unable to keep up with demand for housing. At the very center of this lies the staid construction industry. Lagging behind the rest of the industrialized world in terms of technology advances, it has severely impacted the ability to maintain a livable nation and world. Reprinted courtesy of Drew Buechley, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

In Review: SCOTUS Environmental and Administrative Decisions in the 2020 Term

August 10, 2021 — Anthony B. Cavender - Gravel2Gavel
Several decisions of interest were issued in the 2020 term, which stretched from October 2020 until early July 2021. This review will concentrate on environmental and administrative law cases. Texas v. New Mexico On December 14, 2020, the Court issued its ruling in an Original Action. Water is precious in the Pecos River Valley, and the distribution of water is governed by the Pecos River Compact. Here, Texas complained that New Mexico illegally was seeking delivery credits for evaporated water credits but the Court agreed that New Mexico was entitled to these credits under the provisions of the River Master’s Manual. Florida v. Georgia On April 1, 2021, in another waters right ruling on an Original Action filed in the Supreme Court, the Court rejected Florida’s claims that Georgia’s use of interstate waters harmed Florida’s businesses. Florida had to satisfy a heavy burden of proof, which it failed to do. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

Microsoft Urges the Construction Industry to Deliver Lifecycle Value

June 25, 2019 — Aarni Heiskanen - AEC Business
Digitalization is changing the way that we operate and use buildings. Salla Palos is directing Microsoft towards a future that inspires innovative changes in both the mindset and the business models of AECO industry stakeholders. Salla Palos moved from Finland to the United States in July 2015 and settled down in Seattle, one of the fastest growing areas in the USA. She was versed in digitalization of construction industry in Finland as well as Europe and sought the opportunity to bring that knowledge into the US market. As the Director of Emerging Technology and Innovation for Sellen Construction, one of the largest general contractor companies in the Pacific Northwest United States, Salla started developing digital building lifecycle as a strategy to solve number of industry problems. “I zeroed in on developing digital construction strategy, re-engineering processes, and innovating how emerging technology supports digital construction. My approach was open innovation, pulling the industry along with our own digital transformation. I set up collaboration with both local and international partners to be successful in driving change and transforming AEC,” Salla recalls. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Because I Haven’t Mentioned Mediation Lately. . .

November 23, 2020 — Christopher G. Hill - Construction Law Musings
Any regular reader of Construction Law Musings knows that I am both a great believer in mediation and a certified Virginia mediator. After the last few weeks in which I participated in mediation by Zoom, a Judicial Settlement Conference (read, court-ordered mediation with a retired judge), and will be participating in another mediation in person next week, it seems as if others believe in the process as well. After all of this mediation activity, all of which related to construction project-related disputes, I am more convinced than ever that almost every construction case should at least be submitted for mediation. The list below gives my reasons for saying this:

The parties are in control. In litigation or arbitration, the parties present their evidence to a third party or parties with no familiarity with the “boots on the ground” reality of the construction project at issue. This third party gives a cold review of what evidence court rules allow them to consider and gives a final ruling that one side “wins” and the other side “loses.” This decision has monetary consequences for the losing party, not the least of which is a large attorney fee bill after potentially several years of legal wrangling. With mediation, those closest to the project, the parties, can say what they want, present what they feel to be the best case, and work for a solution. The solution can be flexible and allow the two sides to reach a business decision that is at least better than a large monetary judgment against one of the parties that is only further enforceable in court.

Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Large Canada Employers and Jobsites Mandate COVID-19 Vaccines

November 08, 2021 — Scott Van Voorhis - Engineering News-Record
The push for COVID-19 vaccine mandates is gaining traction in Canada’s construction industry, with governments, large project sites and major employers setting new inoculation deadlines. Reprinted courtesy of Scott Van Voorhis, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES