Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?
January 27, 2020 —
Ted R. Gropman & Christine Z. Fan - ConsensusDocsConstruction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date.
Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved.
There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973).
Reprinted courtesy of
Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP
Mr. Gropman may be contacted at gropmant@pepperlaw.com
Read the court decisionRead the full story...Reprinted courtesy of
East Coast Evaluates Damage After Fast-Moving 'Bomb Cyclone'
March 06, 2022 —
Scott Van Voorhis - Engineering News-RecordCoastal areas in the northeast US are assessing damage from a fast-moving “bomb cyclone” that caused temperatures to plummet, triggered heavy flooding and high winds, and dumped 2 ft of snow in some New England areas.
Reprinted courtesy of
Scott Van Voorhis, Engineering News-Record
ENR may be contacted at enr@enr.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
“Details Matter” is the Foundation in a Texas Construction Defect Suit
March 01, 2012 —
CDJ STAFFThe Court of Appeals of Texas has ruled in the case of Barzoukas v. Foundation Design. Mr. Barzoukas contracted with Heights Development to build a house. He subsequently sued Heights Developments and “numerous other defendants who participated in the construction of his house.” Barzoukas eventually settled with all but two defendants, one who went bankrupt and Foundation Design, the defendant in this case. In the earlier phase, Barzoukas made claims of “negligence, negligent misrepresentation, fraud, fraudulent inducement, conspiracy, and exemplary damages in connection with the foundation.”
Foundation Design had been hired to install 15-foot piers to support the foundation. The engineer of record, Larry Smith, sent a letter to Heights Development noting that they had encountered hard clay stone when drilling. Smith changed the specifications to 12-foot piers. Initially, the City of Houston called a halt to work on the home when an inspector concluded that the piers were too shallow. Heights Development later convinced the city to allow work to continue. Subsequently, experts concluded that the piers were too shallow.
Foundation Design filed a motion for summary judgment. The trial court granted this, “without specifying the basis for its ruling.” Barzoukas contends the court was in error. Foundation Design contends that “Barzoukas failed to proffer competent evidence establishing that their conduct proximately caused damages.” Further, they did not feel that Smith’s letter gave “rise to viable claims for fraud and fraudulent inducement.”
One problem the court had was a lack of evidence. The court noted that “the purported subcontract is entirely missing” in the pleadings. The court has no contract between Bazourkas and Heights Development, nor one between Heights Development and either Foundation Design or Smith. The court underscored the importance of this, writing, “details matter.” They found that “the details are largely missing here.” Without the contract, the court found it impossible to determine if “Smith or an entity related to him agreed to indemnify Heights Development for damages arising from Smith’s negligent performance.”
As the material facts are in dispute, the appeals court found that there were no grounds for a summary judgment in the case. “Pointing to the existence of a contract between Heights Development and Barzoukas, or to the existence of a subcontract, is the beginning of the analysis ? not the end.”
Foundation Design and Smith also claimed that Barzoukas’s expert did not proffer competent evidence and that the expert’s opinions were conclusory. The trial court did not rule on these claims and the appeals court has rejected them.
Finally, Barzoukas made a claim that the trial court should not have rejected his argument of fraud and fraudulent inducement. Here, however, the appeals court upheld the decision of the lower court. “Barzoukas did not present evidence supporting an inference that Smith or Foundation Design made a purposeful misrepresentation.
The court remanded the case to the trial court for reconsideration. One member of the panel, Judge Charles Seymore, upheld the entire decision of the trial court. He dissented with the majority, finding that the economic loss rule foreclosed the claim of negligence.
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of
Not a Waiver for All: Maryland Declines to Apply Subrogation Waiver to Subcontractors
September 23, 2024 —
Gus Sara - The Subrogation StrategistIn Lithko Contr., LLC v. XL Ins. Am. Inc., No. 31, Sept. Term, 2023, 2024 Md. LEXIS 256, the Supreme Court of Maryland considered whether a tenant who contracted for the construction of a large warehouse facility waived its insurer’s rights to subrogation against subcontractors when it agreed to waive subrogation against the general contractor. The court ultimately decided that the unambiguous language of the subrogation waiver in the development agreement between the parties did not extend to subcontractors. The court also held that the tenant’s requirement that subcontracts include a subrogation waiver did not, in this case, impose a project-wide waiver on all parties. The court, however, found that the requirement that the subcontracts include a similar, but not identical, waiver provision rendered the subcontract’s waiver clauses ambiguous and remanded the case to the lower court to determine if the parties to the development agreement – i.e., Duke Baltimore LLC (“Duke”) and Amazon.com.dedc, LLC (“Amazon”) – intended that the waiver clause in the subcontracts covered claims against subcontractors.
This case involved roof and structural damage to a warehouse in Baltimore, Maryland that Duke owned. In March 2014, Amazon entered into a development agreement with Duke for the construction of the warehouse. Amazon also agreed to subsequently lease the warehouse from Duke. Although Amazon essentially owned and/or developed the project, the development agreement identified Duke as “Landlord” and Amazon as “Tenant.”
Read the court decisionRead the full story...Reprinted courtesy of
Gus Sara, White and WilliamsMr. Sara may be contacted at
sarag@whiteandwilliams.com
GRSM Team Wins Summary Judgment in Million-Dollar HOA Dispute
December 17, 2024 —
Robert A. Bragalone & B. Ryan Fellman - Gordon Rees Scully MansukhaniGordon Rees Scully Mansukhani Partner Bob Bragalone and Senior Counsel Ryan Fellman won a complete summary judgment on behalf of five board members who had been added to an HOA dispute by the defendant homeowners. The GRSM team resolved the matter within just 60 days of taking over the case, bringing an end to a legal battle that had lasted more than four years.
The dispute began when the HOA, as plaintiff, filed suit against the homeowners in Denton County District Court. The HOA alleged that the homeowners had violated the HOA’s Covenants, Conditions, and Restrictions by constructing a non-conforming carport and sought a declaratory judgment to resolve the issue. In response, the homeowners filed a counterclaim and third-party petition, adding the individual HOA board members to the lawsuit. They accused the board members—who were serving in a voluntary capacity—of mishandling the dispute and filed claims against them for intentional infliction of emotional distress, negligence, and gross negligence.
Reprinted courtesy of
Robert A. Bragalone, Gordon Rees Scully Mansukhani and
B. Ryan Fellman, Gordon Rees Scully Mansukhani
Mr. Bragalone may be contacted at bbragalone@grsm.com
Mr. Fellman may be contacted at rfellman@grsm.com
Read the court decisionRead the full story...Reprinted courtesy of
Attempt to Overrule Trial Court's Order to Produce Underwriting Manual Fails
April 25, 2022 —
Tred R. Eyerly - Insurance Law HawaiiAfter being ordered by the trial court to produce its underwriting manual, the insurer's writ of certiorari to quash the order was denied by the Florida Court of Appeals. People's Trust Ins. Co. v. Foster, 2022 Fla. App. LEXIS 542 (Fla. Ct. App. Jan. 26, 2022).
The insured sued after his claim for damage caused by a water pipe in his home that leaked. In discovery, the insurer refused to produce its underwriting manual. Ruling on a motion to compel, the trial court ordered that the manual be produced. The insurer appealed.
On appeal, the insurer argued its underwriting manual was categorically prohibited in breach of contract cases until and unless bad faith litigation commenced. Although courts had quashed the premature discovery of insurers' business practices, claims files, underwriting files, underwriting manuals, and the like in breach of contract actions, there was no categorical legal rule prohibiting discovery of underwriting manuals in breach of contract cases, especially if they were relevant.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Increases in U.S. Office Rents Led by San Jose and Dallas
October 01, 2014 —
Hui-yong Yu – BloombergSan Jose, California, and Dallas led the U.S. in office-rent increases in the third quarter as cities benefiting from growth in the technology and energy industries outperformed the gradual national recovery.
Rents after any landlord discounts, known as effective rents, climbed 6.7 percent from a year earlier in San Jose, compared with the U.S. average increase of 2.6 percent, property researcher Reis Inc. (REIS) said. Dallas rents rose 5.2 percent, followed by San Francisco’s 5.1 percent gain, Houston’s 4.4 percent increase and New York’s 3.9 percent advance.
The national sluggishness in the office market’s growth is being bucked by parts of Northern California and Texas, where large bases of technology or energy workers drive demand for space, Reis said. Throughout the U.S., increases in office occupancies show that the market “is in the midst of a recovery,” according to the New York-based company.
Read the court decisionRead the full story...Reprinted courtesy of
Hui-yong Yu, BloombergHui-yong Yu may be contacted at
hyu@bloomberg.net
Firm Announces Remediation of Defective Drywall
October 16, 2013 —
CDJ STAFFThe residents of Villa Lago at Renaissance Commons will be relieved of their problems with defective Chinese drywall, according to an announcement from their legal counsel, Whitfield Bryson & Mason. Gary E. Mason, a founding member of the firm, announced to homeowners that remediation would begin on November 1. “The project will start with about 30 units on the top floor and will continue floor by floor for the next 12 months.” Residents will be moved out of their units for about three months while all drywall is removed and replaced.
Read the court decisionRead the full story...Reprinted courtesy of