FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

The Construction Project is Late—Allocation of Delay

November 17, 2016 — David Adelstein – Florida Construction Legal Updates
The construction project is late. Very late. The owner is upset and notifies the contractor that it is assessing liquidated damages. The contractor, in turn, claims that the project is late because of excusable, compensable delays and, perhaps, excusable, noncompensable delays. This is a common and unfortunate story between an owner and contractor on any late construction project. Now the fun begins regarding the allocation of the delay! Through previous articles, I discussed that in this scenario the burden really falls on the contractor to establish that the liquidated damages were improperly assessed against it and, thus, it is entitled to additional time and/or extended general conditions as a result of excusable delays. Naturally, this requires the contractor to develop a critical path analysis (time impact analysis) allocating the impacts / delays (and the reasons for the impacts/ delays) to the project completion date. The reason the burden really falls on the contractor is because the owner’s burden is relatively easy – the project was not complete on time pursuant to the contract and any approved changed orders. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Katz, Barron, Squitero, Faust, Friedberg, English & Allen, P.A.
Mr. Adelstein may be contacted at dma@katzbarron.com

---

Bremer Whyte Congratulates Nicole Nuzzo on OCBA Professionalism and Ethics Committee Appointment

November 17, 2016 — Beverley BevenFlorez – CDJ Staff
Nicole Nuzzo of Bremer Whyte Brown & O’Meara LLP was selected as one of the fifteen members of the Orange County Bar Association’s (OCBA) Professionalism and Ethics Committee, announced the firm. Committee members “are committed to supporting and encouraging OCBA members to engage in the professional and ethical practice of law. Members of the Committee are appointed by the OCBA president.” Ms. Nuzzo practices Family Law at the firm’s Newport Beach, California office. Read the court decision
Read the full story...
Reprinted courtesy of

---

Defense Dept. IG: White House Email Stonewall Stalls Border Wall Contract Probe

December 14, 2020 — Mary B. Powers & Debra K. Rubin - Engineering News-Record
After nearly one year of work, the U.S. Defense Dept.’s Inspector General can’t finish a congressionally-ordered probe of a $400-million U.S-Mexico border wall construction award last December to contractor Fisher Sand & Gravel because agency attorneys won't allow release of requested DOD and White House e-mails related to the contract, Acting Inspector General Sean O’Donnell said in a Nov. 30 report to Congress. Reprinted courtesy of Mary B. Powers, Engineering News-Record and Debra K. Rubin, Engineering News-Record Ms. Rubin may be contacted at rubind@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

New Jersey Legislation Would Bar Anti-Concurrent Causation Clause in Homeowners' Policies

June 08, 2020 — Tred R. Eyerly - Insurance Law Hawaii
A bill prohibiting the use of anti-concurrent causation clauses in homeowners' insurance policies has been introduced before the New Jersey legislature. The bill is here. Under an anti-concurrent causation clause, the policy bars coverage if two perils (i.e., wind and water damage) contribute to a loss and one peril is excluded from coverage. For example, wind damage alone may be covered, while water damage is excluded. If both wind and water contribute to the loss, regardless of the degree to which each peril contributes, the anti-concurrent causation clause would bar coverage. New Jersey S 217 states,

An insurer authorized to transact the business of homeowners insurance in this state shall not exclude coverage in a homeowners insurance policy for loss or damage caused by a peril insured against under the terms of the policy on the grounds that the loss or damage occurred concurrently or in any sequence with a peril not insured against under the terms of the policy. Any such provision to exclude coverage shall be void and unenforceable.

Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Duty to Defend Bodily Injury Evolving Over Many Policy Periods Prorated in Louisiana

November 17, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The Louisiana Supreme Court held that the duty to defend in long latency disease cases should be prorated between the insurer and insured when the policies cover for only a portion of the time in which the exposure occurred. Arceneaux v. Amstar Corp., 2016 La. LEXIS 1675 (La. Sept. 7, 2016). Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Arizona Is Smart About Water. It Should Stay That Way.

February 19, 2024 — Mark Gongloff - Bloomberg
You really have to hand it to Arizona: Even as its population has doubled and it has suffered through a decades long megadrought, the state uses less water today than it did 40 years ago. This success story is the result of what may be the smartest, most conservative approach to water in the country. But homebuilders want to scrap some key elements of this careful system. It’s a bad idea, especially as the climate changes, making the state’s water supply less reliable. And it’s a cautionary tale for the rest of us as we try to adapt to a warming world. In 1980, alarmed at watching its precious groundwater disappear amid rapid development, Arizona passed the Groundwater Management Act. The law established the Arizona Department of Water Resources, set up water-management zones around cities and required new housing developments to prove they had access to 100 years’ worth of clean water, among other things. Read the court decision
Read the full story...
Reprinted courtesy of Mark Gongloff, Bloomberg

---

Fourth Circuit Issues New Ruling on Point Sources Under the CWA

October 02, 2018 — Anthony B. Cavender - Gravel2Gavel
The Clean Water Act (CWA) authorizes citizen suits to enforce the provisions of the law which requires a permit to discharge a pollutant from a point source into navigable waters. Earlier this year, the U.S. Court of Appeals for the Fourth Circuit, in Upstate Forever v. Kinder Morgan Energy Partners, held that discharges into groundwater, not surface water, could also trigger the regulatory authority of the CWA if there was a hydrological connection between the groundwater and the navigable, surface, waters. In its a closely-watched case, Sierra Club v. Virginia Electric & Power Company (“VEPCO”), which also involved discharges into groundwater, the Fourth Circuit was bound by this this new and controversial precedent (a Supreme Court review is very likely), but the plaintiffs in the VEPCO case could not establish that the landfill and the settling ponds used by VEPCO were “point sources”—another important element that must be established. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

---

New York Appellate Division Reverses Denial of Landlord’s Additional Insured Tender

December 07, 2020 — Eric D. Suben - Traub Lieberman
In Wesco Insurance Co. v. Travelers Property & Cas. Co. of America, 2020 WL 6572489 (1st Dep’t Nov. 10, 2020), the New York Appellate Division found that a commercial landlord was owed additional insured coverage in connection with an incident in which a plaintiff slipped and fell on the sidewalk while exiting the leased premises. The tenant, Capital One, was the named insured in a CGL policy issued by Travelers. The policy added the landlord as an additional insured, but “only with respect to liability arising out of the ownership, maintenance or use of that part of the premises leased to [Capital One] and shown in the Schedule.” The lease defined the demised premises to include the building and “all appurtenances.” Travelers denied the landlord’s tender on the basis that the sidewalk did not constitute “that part of the premises leased to” Capital One. In the ensuing declaratory judgment action brought by Wesco (the landlord’s insurer), the court granted Travelers’ motion for summary judgment on this ground. Read the court decision
Read the full story...
Reprinted courtesy of Eric D. Suben, Traub Lieberman
Mr. Suben may be contacted at esuben@tlsslaw.com

---