Seattle Washington Building Expert Directory

Recovering Unabsorbed Home Office Overhead Due to Delay

May 30, 2022 — David Adelstein - Florida Construction Legal Updates
In the preceding article, I discussed the use of a retrospective as-built delay analysis in a case before the Civilian Board of Contract Appeals (CBCA). This case also discussed a damages component in certain delay claims known as unabsorbed home office overhead—a challenging damages component to recover because this deals with indirect costs as opposed to direct costs. Unabsorbed home office overhead is a damages component when the contractor is on standby, but this is NOT as easy as just claiming standby thereby you are automatically entitled to unabsorbed home office overhead. There are requirements that MUST be met.

To obtain an equitable adjustment for unabsorbed home office overhead as compensation for being on standby, [the contractor] must initially show “[1] a government-caused delay of uncertain duration,” that “[2] the delay extended the original time for performance” or precluded the contractor from finishing earlier than scheduled, and that “[3] the contractor [was] on standby and unable to take on other work during the delay period. CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022) quoting Nicon, Inc. v. U.S., 331 F.3d 878, 883 (Fed. Cir. 2003).

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Do You Have an Innovation Strategy?

November 08, 2017 — Aarni Heiskanen - AEC Business
Construction and engineering are among the top five industries ripe for disruption according to research by PwC. Will innovation come from tech companies and startups, or could established firms be proactive? For Granlund, founded in 1960, innovation is a strategic essential and a core competency. Granlund is a Finnish design, consultancy, and software services firm specializing in energy efficiency. It employs more than 800 people in 20 locations in Finland and in its offices in Shanghai and Dubai. The company is known internationally for being in the vanguard of building information modeling and for real estate management software development. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at info@aepartners.fi

BWB&O Expands to North San Diego

December 09, 2019 — Bremer Whyte Brown & O’Meara
Bremer Whyte Brown & O’Meara is excited to announce our expansion to North San Diego County. Our new office location in Encinitas is strategically located between our Newport Beach and Downtown San Diego offices. The new North San Diego office will provide further resources to better serve our clients. Read the court decision
Read the full story...
Reprinted courtesy of Bremer Whyte Brown & O’Meara

ICE Said to Seek Mortgage Role Through Talks With Data Service

August 06, 2014 — Matthew Leising, Jesse Hamilton and Jody Shenn – Bloomberg
Intercontinental Exchange Inc. (ICE), best known for energy trading and its control of the New York Stock Exchange, is engaged in negotiations that would give it a foothold in the $9.4 trillion U.S. mortgage market. ICE is in early stage talks to form a partnership with Mortgage Electronic Registration Systems Inc., which documents the ownership and resale of about half of U.S. home loans, according to a person familiar with the matter, who asked to not be identified because the discussions are private. The Atlanta-based exchange owner has been gauging demand for derivatives that enable investors to bet on defaults by U.S. homeowners, Bloomberg News reported in May. ICE, which earns most of its revenue by owning one of the world’s largest derivatives markets, has recently expanded into new businesses such as equity trading with its 2013 purchase of NYSE Euronext and the administration of interest-rate benchmarks. Mr. Leising may be contacted at mleising@bloomberg.net; Mr. Hamilton may be contacted at jhamilton33@bloomberg.net; Ms. Shenn may be contacted at jshenn@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Matthew Leising, Jesse Hamilton and Jody Shenn, Bloomberg

BP Is Not an Additional Insured Under Transocean's Policy

April 01, 2015 — Tred R. Eyerly – Insurance Law Hawaii
Responding to a certified question from the Fifth Circuit, the Texas Supreme Court determined that BP was not an additional insured under Transocean's liability policy and had no coverage under the policy for the deaths caused by the explosion of the Deepwater Horizon. In re Horizon, 2015 Tex. LEXIS 141 (Tex. Feb. 13, 2015). We have previously posted on this case in the federal courts here and here. Transocean owned the Deepwater Horizon, a mobile offshore drilling unit operating in the Gulf of Mexico pursuant to a contract with BP. After an explosion in April 2010, the rig caught fire, killing eleven crew members. Both Transocean and BP sought coverage under Transocean's primary and excess policies. Although they did not dispute that BP was an additional insured, Transocean and its insurers argued that BP was not entitled to coverage for pollution-related liabilities arising from subsurface oil releases in connection with the Deepwater Horizon accident. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Traub Lieberman Partner Michael K. Kiernan and Associate Brandon Christian Obtain Dismissal with Prejudice in Favor of Defendant

November 27, 2023 — Michael K. Kiernan & Brandon Christian - Traub Lieberman
In a 14-count breach of contract action brought in the Fifteenth Judicial Circuit in Palm Beach County, Florida, Partner Michael K. Kiernan and Associate Brandon Christian obtained dismissal with prejudice in favor of Defendant St. Joseph’s Episcopal Church of Boynton Beach, Florida (“Church”). Plaintiffs, St. Joseph’s Episcopal School (“School”) and its benefactor, William Swaney, filed suit to enforce an alleged 99-year oral lease agreement which Swaney asserted had been made to him by a prior rector of the Church in exchange for his contributions to the School. Plaintiffs also sought emergency injunctive relief to allow the School to continue to operate on Church property. The Church maintained in part that the only lease in effect was a written lease, approved by the Church Vestry and the Diocese of Southeast Florida, and which the Church Vestry unanimously voted not to renew in 2022. Reprinted courtesy of Michael K. Kiernan, Traub Lieberman and Brandon Christian, Traub Lieberman Mr. Kiernan may be contacted at mkiernan@tlsslaw.com Mr. Christian may be contacted at bchristian@tlsslaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Former Hoboken, New Jersey Mayor Disbarred for Taking Bribes

September 17, 2014 — Beverley BevenFlorez-CDJ STAFF
The New Jersey Law Journal reported that Peter Cammarano III, a former Hoboken, New Jersey, mayor, was disbarred after admitting “four years ago that he took $25,000 in bribes from a federal informant in exchange for promising his help in getting approval for a high-rise.” Cammarano “was one of 44 public officials and rabbis arrested in July 2009 as part of a massive federal investigation, known as Operation Bid Rig, into public corruption and money laundering operations.” The Disciplinary review board had recommended a three year suspension, however, the New Jersey Supreme Court rejected that recommendation. “An elected official who sells his office—who offers favored treatment in exchange for money—betrays a solemn public trust,” Justice Barry Albin wrote for the court, as quoted by the New Jersey Law Journal. “This form of corruption is corrosive to our democracy and undermines public confidence in honest government, and its rippling pernicious effects are incalculable.” “I believe the Disciplinary Review Board’s decision was right,” Joseph Jr. Hayden, Cammarano’s attorney, told the New Jersey Law Journal. “There were sufficient mitigating factors to justify only a suspension.” Read the court decision
Read the full story...
Reprinted courtesy of

There’s the 5 Second Rule, But Have You Heard of the 5 Year Rule?

April 23, 2024 — Garret Murai - California Construction Law Blog
They’re called deadlines for a reason. Usually, because something really bad could happen if you fail to meet the deadline. For those in the construction industry, you probably aware of the “deadline” to bring a claim for latent defects (10 years from substantial completion); the deadline to file suit to foreclose on a mechanics lien (90 days from the date of recording the mechanics lien), and the deadline for serving a preliminary notice (generally, 20 days from the date labor and/or materials are first furnished). Well, here’s another deadline: Under Code of Civil Procedure section 585.310, you have 5 years after a complaint is filed to bring a case to trial, absent the court granting relief. I could leave it at that, but in the next case, Oswald v. Landmark Builders, Inc., 97 Cal.App.5th 240 (2023), was too interesting to pass up. The Oswald Case On June 28, 2016, homeowners Jack Oswald and Anne Seley sued their general contractor and its subcontractors alleging construction defects at their home. Answers and cross-complaints were filed and on February 2017 the trial court determined the case to be complex and appointed a discovery master. A discovery master, for those who may be unfamiliar, is usually a retired judge or third-party lawyer appointed by a court to oversee discovery in a case such as written discovery, depositions, site inspections, etc. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES