Fairfield Connecticut Building Expert Directory

Green Construction Claims: More of the Same

May 10, 2021 — Christopher G. Hill - Construction Law Musings
For this week’s Guest Post Friday, Musings welcomes back Timothy R. Hughes, Esq., LEED AP. Tim (@timrhughes on Twitter) is a Shareholder in the Arlington, Virginia firm of Bean, Kinney & Korman, P.C. In his practice as a business, corporate, and construction law attorney, Tim was the Chair of the Construction Law and Public Contracts Section of the Virginia State Bar. He was recognized by Virginia Lawyer’s Weekly as a 2010 “Leader in the Law” and a member of the Legal Elite for Construction Law for 2010 by Virginia Business Magazine. A regular speaker and writer, Tim is the lead editor of his firm blog, Virginia Real Estate, Land Use and Construction Law. Green construction liability risk has received a lot of discussion over time. My take is that sustainable design and construction projects present the same type of risk profile as other construction projects, with the caveat that there may be “a little more”. A little more risk. A little more lack of predictability. A little more process overlay. Thus, green construction claims really are just “more of the same”. I have watched and participated in the discussion. With regards to the Chesapeake Bay Foundation building, the reality is that any project can face challenges of product specification and performance, green or not. We can see plenty of examples where products have created tremendous risk and liability to the construction industry, the avalanche of EIFS litigation and Chinese drywall standing as just two of the most recent examples. A product failed, but that is nothing truly new. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Ten Years After Colorado’s Adverse Possession Amendment: a brief look backwards and forwards

September 25, 2018 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
In response to national outrage over an infamous adverse possession case in Boulder, Colorado, in which a lawyer and a judge intentionally took their neighbors’ undeveloped land through adverse possession, the Colorado legislature amended the state’s adverse possession statute (C.R.S. § 38-41-101) to make the claim significantly harder to prove. It did this because it believed “there were insufficient ‘obstacles’ to establishing a claim for adverse possession under the existing law.”[1] Effective July 1, 2008, the amendment created a heightened burden of proof, additional element requirements, and the possibility of a losing defendant recovering money from successful plaintiffs for the value of the land they took and the taxes the defendant had paid on that land. The Boulder case eventually settled, but the resulting statutory amendments have drastically changed the landscape of Colorado’s adverse possession law. Ten years later, this blog post takes a brief look at the amended statute, the impact it has had, and questions that have yet to be resolved. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

California’s Housing Costs Endanger Growth, Analyst Says

March 19, 2015 — John Gittelsohn – Bloomberg
(Bloomberg) -- California’s high housing costs threaten the state’s economy as workers increasingly struggle to afford a roof over their heads, the state Legislative Analyst’s Office said in a report released Tuesday. “The state’s high housing costs make California a less attractive place to call home, making it more difficult for companies to hire and retain qualified employees, likely preventing the state’s economy from meeting its full potential,” Chas Alamo and Brian Uhler, senior fiscal and policy analysts with the office, said in the study. California was home to four of the five most expensive U.S. metropolitan markets for single-family home sales in the fourth quarter of last year, led by a median home price of $855,000 in the San Jose, Sunnyvale and Santa Clara area, according to the National Association of Realtors. San Francisco ranked second, with Honolulu and the California cities of Anaheim and San Diego rounding out the top five. The suburbs north of New York City and greater Los Angeles followed. Read the court decision
Read the full story...
Reprinted courtesy of John Gittelsohn, Bloomberg
Mr. Gittelsohn may be contacted at johngitt@bloomberg.net

How the Cumulative Impact Theory has been Defined

November 30, 2020 — David Adelstein - Florida Construction Legal Updates
Largely in the federal contract arena, there is a theory referred to as “cumulative impacts” used by a contractor to recover unforeseeable costs associated with a multitude of changes that have an overwhelming ripple effect on its efficiency, particularly efficiency dealing with its original, base contract work. In other words, by dealing with extensive changes, there is an unforeseeable impact imposed on the contractor relative to its unchanged or base contract work. Under this theory, the contractor oftentimes prices its cumulative impact under a total cost approach with an examination on its cost overrun. However, this is not an easy theory to prevail on because there needs to be a focus on the sheer number of changes, causation supporting the impact, and whether there were concurrent impacts or delays that played a role in the ripple effect. See, e.g., Appeals of J.A. Jones Const. Co., ENGBCA No. 6348, 00-2 BCA P 31000 (July 7, 2000) (“However, in the vast majority of cases such claims are routinely denied because there were an insufficient number of changes, contractor-caused concurrent delays, disruptions and inefficiencies and/or a general absence of evidence of causation and impact.”). To best articulate how the cumulative impact theory has been defined, I want to include language directly from courts and board of contract appeals that have dealt with this theory. This way the contractor knows how to best work with their experts with this definition in mind–and, yes, experts will be needed–to persuasively package and establish causation and damages stemming from the multitude of changes. While many of these definitions are worded differently, you will see they have the same focus dealing with the unforeseeable ripple effect of the extensive changes. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

CGL Insurer’s Duty to Defend Insured During Pre-Suit 558 Process: Maybe?

December 20, 2017 — David Adelstein - Florida Construction Legal Updates
In earlier postings, I discussed the issue of whether Florida Statutes Chapter 558′s pre-suit construction defects process triggers a CGL insurer’s duty to defend. The issue was whether Florida’s 558 pre-suit notice of a construction defect and repair process met the definition of “suit” within a standard CGL policy. A standard CGL policy defines the term “suit” as: “Suit” means a civil proceeding in which damages because of “bodily injury,” “property damage” or “personal and advertising injury” to which this insurance applies are alleged. “Suit” includes: a. An arbitration proceeding in which such damages are claimed and to which the insured must submit or does submit with our consent; or b. Any other alternative dispute resolution proceeding in which such damages are claimed and to which the insured submits with our consent. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

Suffolk Construction Drywall Suits Involve Claim for $3 Million in Court Costs

November 11, 2024 — Richard Korman - Engineering News-Record
Suffolk Construction lost a breach-of-contract contract lawsuit in July with a former drywall subcontractor's surety—but the contractor's payout may dramatically increase if the presiding U.S. district court judge in Miami allows the surety to collect $3 million more in requested attorneys' fees and trial costs. Reprinted courtesy of Richard Korman, Engineering News-Record Mr. Korman may be contacted at kormanr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Waiver of Consequential Damages: The Most Important Provision in a Construction Contract

March 08, 2021 — Jeremy P. Brummond - Construction Executive
Construction agreements can be lengthy. They often include terms covering everything from logistics for working on the project site to complicated provisions regarding intellectual property. Many provisions in a construction agreement deal with risk and who is going to pay for damage claims if or when they occur. However, not all risk-shifting provisions are equally important. While provisions that impose obligations on the contractor to maintain confidentiality, indemnify for personal injury or property damage, or correct defective work can expose a contractor to substantial damage claims and are thus important, contractors can significantly control the amount of damages the owner can claim by including a well-drafted waiver of “consequential damages” provision in the agreement. Because the waiver of consequential damages can significantly control the amount of damages for which a contractor is assuming risk and greatly limit the owner’s ability to recoup many damages, it is arguably the most important provision in a construction contract. Therefore, it is essential for contractors and owners to carefully consider the waiver of consequential damages before entering into any construction agreement. Reprinted courtesy of Jeremy P. Brummond, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Brummond may be contacted at jbrummond@lewisrice.com

Banks Loosening U.S. Mortgage Standards: Chart of the Day

August 13, 2014 — Jody Shenn – Bloomberg
Perhaps more U.S. banks than at any time in two decades are making it easier to qualify for a mortgage. The CHART OF THE DAY shows the net share of banks telling the Federal Reserve that they’re tightening standards in the home-loan market. In the central bank’s July survey of senior loan officers released last week, the net percentage for prime mortgages was negative 18.3 percent, by far the most loosening since it started asking the question by loan-quality category in 2007. It was also greater than the highest net share of banks easing in “all” mortgages in the 1990s or 2000s. Still, lenders have a long way to go before they unwind the restrictions they imposed in the wake of the global financial crisis that risky home loans helped to create. The current trend is mainly about “small tweaks around the edges,” according to JPMorgan Chase & Co. mortgage-bond analysts. Read the court decision
Read the full story...
Reprinted courtesy of Jody Shenn, Bloomberg
Ms. Shenn may be contacted at jshenn@bloomberg.net

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES