Seattle Washington Building Expert Directory

The CA Supreme Court Grants Petition for Review of McMillin Albany LLC v. Super Ct. 2015 F069370 (Cal.App.5 Dist.) As to Whether the Right to Repair Act (SB800) is the Exclusive Remedy for All Defect Claims Arising Out of New Residential Construction

December 02, 2015 — Richard H. Glucksman, Esq., Glenn T. Barger, Esq., Jon A. Turigliatto, Esq., & David A. Napper, Esq. – Chapman Glucksman Dean Roeb & Barger Bulletin
As anticipated in a prior CGDRB 2015 Bulletin that discussed the Fifth Appellate District Court’s noteworthy opinion in McMillin Albany LLC v. Super Ct. 2015 F069370 (Cal.App.5 Dist), the California Supreme Court has granted the petition for review of the McMillin Albany decision. The Supreme Court will attempt to resolve the conflict of authority presented by the Fourth Appellate District Court’s opinion in Liberty Mut. Ins. Co. v. Brookfield Crystal Cove LLC (2013) 219 Cal.App.4th 98 and the Fifth Appellate District Court’s rejection of the Liberty Mutual holding in McMillin Albany. In Liberty Mutual, the Fourth District Court of Appeal held that compliance with SB800’s pre-litigation procedures prior to initiating litigation is only required for defect claims [violations of SB 800’s building standards] that have not yet resulted in actual property damage. Where damage has occurred, a homeowner may initiate litigation under common law causes of action without first complying with the pre-litigation procedures set forth in SB 800. Two years later, the Fifth District Court of Appeal, in McMillin Albany, held that the California Legislature intended that all construction defect claims arising out new residential construction are subject to the standards and requirements of the Right to Repair Act [SB800], including specifically, the requirement that the claimant provide the builder with notice and an opportunity to repair prior to filing a lawsuit. According to the Court, SB 800 is the exclusive remedy for all defect claims arising out of new residential construction sold on or after January 1, 2003. The holdings in Liberty Mutual and McMillin Albany present a conflict of authority that the California Supreme Court has appropriately deemed worthy of review. The parties will now be permitted to file briefs on the merits and amicus briefs will certainly be submitted by the defense and plaintiff bars. Our firm will be closely monitoring this case, the outcome of which will significantly impact pre-litigation construction defect claims going forward. We will provide updates as to further activities and the Supreme Court’s decision. Reprinted courtesy of Chapman Glucksman Dean Roeb & Barger attorneys Richard H. Glucksman, Glenn T. Barger, Jon A. Turigliatto and David A. Napper Mr. Glucksman may be contacted at rglucksman@cgdrblaw.com Mr. Barger may be contacted at gbarger@cgdrblaw.com Mr. Turigliatto may be contacted at jturigliatto@cgdrblaw.com Mr. Napper may be contacted at dnapper@cgdrblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Shifting the Risk of Delay by Having Float Go Your Way

July 05, 2021 — Christopher J. Brasco & Matthew D. Baker - ConsensusDocs
Critical path delay plays a central role in allocating responsibility for project delay. The interrelated concept of concurrency is also frequently determinative of entitlement on a range of claims including by owners for liquidated damages and by contractors for delay damages. What constitutes critical/concurrent delay, however, is hotly debated by scheduling experts. The lack of real consensus regarding how critical/concurrent delay should be determined and analyzed has created significant uncertainty in scheduling disputes. Indeed, courts have adopted differing and at times conflicting theories of concurrency that can produce divergent outcomes for the parties. In an effort to reduce uncertainty, stakeholders have increasingly adopted specialized contractual provisions and scheduling techniques which have significant implications for the evaluation of the companion concepts of criticality and concurrency. One such mechanism is float sequestration. Regardless of whether float sequestration is ultimately in the construction industry’s broader interest, stakeholders must be able to recognize its use and appreciate the implications for delay disputes on their projects. Simply defined, float is the number of days an activity can be delayed before affecting the project’s critical path (i.e., the longest chain of activities which determines the project’s minimal duration). Typically, only delays affecting the critical path can produce concurrent delay. Consequently, the concept of float is integral to understanding and resolving issues of both criticality and concurrency. Reprinted courtesy of Christopher J. Brasco, Watt, Tieder, Hoffar & Fitzgerald, LLP and Matthew D. Baker, Watt, Tieder, Hoffar & Fitzgerald, LLP Mr. Brasco may be contacted at cbrasco@watttieder.com Mr. Baker may be contacted at mbaker@watttieder.com Read the court decision
Read the full story...
Reprinted courtesy of

Constructing a New American Dream

August 06, 2014 — Beverley BevenFlorez-CDJ STAFF
Shelley D. Hutchins in Big Builder interviewed various architects and engineers to discuss the future of home design and building. Obtaining the American Dream “means having a place of sanctuary and security as well as shelter,” Hutchins wrote. “What that house looks like and how it functions is changing to accommodate different family make-ups, population and culture shifts toward denser more integrated communities, and increasingly extreme weather patterns.” Hutchins declared, “According to experts, educators, and experimenters in the residential design and construction industry many solutions for building houses for the future involve revisiting what worked before. Combining historic research with new innovations is what will produce the best housing.” Read the court decision
Read the full story...
Reprinted courtesy of

Chambers USA 2020 Ranks White and Williams as a Leading Law Firm

June 15, 2020 — White and Williams LLP
White and Williams is once again recognized by Chambers USA as a leading law firm in Pennsylvania for achievements and client service in the area of insurance law. In addition, four lawyers received individual honors – two for their work in insurance, one for his work in banking and finance and another for his work in commercial litigation. White and Williams is acknowledged for its renowned practice offering expert representation to insurers and reinsurers across an impressive range of areas including coverage, bad faith litigation and excess liability. The firm is recognized for its notable strength in transactional and regulatory matters, complemented by its adroit handling of complex alternative dispute resolution proceedings and is described as "reasoned and respectful." Chambers also acknowledged the firm's broad trial capabilities, including handling data privacy, professional liability and toxic tort coverage claims as well as its experience in substantial claims arising from bodily injury and wrongful death suits. White and Williams' cross-disciplinary team is also highlighted, characterized for "work[ing] well together and provid[ing] exceptional representation." Read the court decision
Read the full story...
Reprinted courtesy of White and Williams LLP

COVID-19 Response: Key Legal Considerations for Event Cancellations

March 30, 2020 — Michael G. Platner, Solomon B. Zoberman, & Jane C. Luxton - Lewis Brisbois
Every passing day brings stark new reports of novel coronavirus (COVID-19) cases and increasing numbers of cancelled conventions, concerts, and other major events. Both the hospitality and travel industry on the one hand, and organizations that are canceling events on the other, are scrambling to understand the legal consequences of these costly terminations. Cancellation fees can be breathtaking, and affected parties are quickly learning that there are no simple answers as to whether a disease outbreak of this scope and scale falls within force majeure (or Act of God) clauses that either do not explicitly list, or arguably may never have contemplated, circumstances of this type. Generally, force majeure clauses excuse parties’ performance under a contract when circumstances that are beyond their control arise and prevent them from fulfilling their obligations. The party electing to enforce its rights under the force majeure clause must show that the triggering event qualifies as a force majeure event, and that the event has rendered the party’s performance impossible or impracticable. Reprinted courtesy of Lewis Brisbois attorneys Michael G. Platner, Solomon B. Zoberman and Jane C. Luxton Mr. Platner may be contacted at Michael.Platner@lewisbrisbois.com Mr. Zoberman may be contacted at Solomon.Zoberman@lewisbrisbois.com Ms. Luxton may be contacted at Jane.Luxton@lewisbrisbois.com Read the court decision
Read the full story...
Reprinted courtesy of

AB 1701 – General Contractor Liability for Subcontractors’ Unpaid Wages

November 08, 2017 — Alex Baghdassarian, Eric M. Gruzen, and Kerri Sakaue - Peckar & Abramson, P.C.
Contractors will soon find themselves on the frontline of wage disputes on projects if laborers working on behalf of their subcontractors or vendors are unpaid. On October 14, 2017, Governor Jerry Brown signed into law AB 1701, which will allow laborers to seek direct compensation from the general contractors on private projects, if their wages remain unpaid. The legislative mandate requires direct contractors—defined as contractors who have a direct contractual relationship with an owner—to assume liability for any debt incurred by a subcontractor, at any tier, for a wage claimant’s performance of labor included in the subject of the original contract between the general contractor and the owner. The California bill will apply to all private construction contracts entered into on or after January 1, 2018. Previously, all laborers could maintain a mechanic’s lien claim against private property, without needing to serve a 20-day preliminary notice, but there was no statutory obligation on the “direct contractors” to reimburse the laborers their unpaid wages. Reprinted courtesy of Peckar & Abramson, P.C. attorneys Alex Baghdassarian, Eric M. Gruzen and Kerri Sakaue Mr. Baghdassarian may be contacted at abaghdassarian@pecklaw.com Mr. Gruzen may be contacted at egruzen@pecklaw.com Ms. Sakaue may be contacted at ksakaue@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Federal Energy Regulator Approves Rule to Speed Clean Energy Grid Links

August 28, 2023 — Mary B. Powers & Debra K. Rubin - Engineering News-Record
The Federal Energy Regulatory Commission unanimously passed a sweeping rule at its July 27 open meeting meant to eliminate U.S. transmission system bottlenecks for new power generation and storage. But stakeholders worry that more needs to be done to add needed and viable clean energy projects to the grid. Reprinted courtesy of Mary B. Powers, Engineering News-Record and Debra K. Rubin, Engineering News-Record ENR may be contacted at enr@enr.com Ms. Rubin may be contacted at rubind@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Massive Redesign Turns Newark Airport Terminal Into a Foodie Theme Park

March 05, 2015 — Belinda Lanks – Bloomberg
You wait on what looks like a Soviet bread line. You show your I.D. to a guard. You take off your shoes, empty your pockets, and surrender to a digital scanner. Fortunately, there’s always a bevy of gleaming cocktail bars and foodie outposts welcoming you to the other side. No? Get ready. That’s the plan for United Airlines’ Terminal C at Newark Liberty International Airport—a $120 million redesign that includes 55 dining venues with enough celebrity-chef cameos to rival the glitziest of Las Vegas casinos. Instead of the usual McDonald’s, TCBY, and Sbarro, there will be restaurants serving up far-ranging cuisine, from authentic ramen and tacos to gourmet, Neapolitan-style pizza and Swedish meatballs. Since the terminal must remain in operation, all the structures will be assembled off-site and dropped in next year to keep construction time to a minimum. Read the court decision
Read the full story...
Reprinted courtesy of Belinda Lanks, Bloomberg

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES