Intellectual Property And Employment Law Best Practices: Are You Covering Your Bases In Protecting Construction-Related Trade Secrets?
November 15, 2021 —
Colin Holley - ConsensusDocsThere are four main types of intellectual property (IP) – patents, copyrights, trademarks and trade secrets. Many companies have IP rights of all four types. Very different steps are required to protect different types of IP. Your company should work with an experienced IP attorney to develop and continuously update a comprehensive IP protection plan. And for the reasons discussed below, it is important for your company’s IP protection plan to be closely coordinated with employment and contracting practices.
Patents are rights that may be granted to protect uniquely-original and usable inventions for a prescribed period of years, the length of which depends on the patent type. To register a patent, an application must be filed with the United States Patent and Trademark Office (USPTO), which will decide whether the invention is patentable. A registration gives the owner the ability to prevent others from using or selling the invention without permission. Registered patents may be challenged in court on several grounds, but mounting a successful challenge is a very expensive proposition. A patent registration is thus a highly valued asset and is key to preventing others from using or copying your invention, unless you have a foolproof way to keep your invention secret and out of the hands of competitors. On the other hand, if it is possible to keep the invention secret for enough time to gain a commercial advantage over competitors and the enforceability of the patent is questionable, registering a patent may be a mistake because the invention must be publicly disclosed in excruciating detail, for all competitors to see.
Read the court decisionRead the full story...Reprinted courtesy of
Colin Holley, Watt, Tieder, Hoffar, & Fitzgerald, LLPMr. Holley may be contacted at
cholley@watttieder.com
Berkeley Researchers Look to Ancient Rome for Greener Concrete
June 28, 2013 —
CDJ STAFFWhile modern concrete often crumbles after fifty years, some concrete laid down during the Roman Empire is still strong, even after 2,000 years. Researchers at UC Berkeley have been puzzling over the secrets of Roman concrete, using samples from a breakwater near Naples. The breakwater was built about 37 BC, and the concrete is still strong. Unlike modern concrete, the Romans made theirs with a mixture of lime and volcanic ash.
Paulo Monteiro, a professor of civil and environmental engineering at Berkeley, noted that one of the drawbacks of Roman cement was that it hardens more slowly than modern concrete. An advantage is that it is more environmentally friendly, and the researchers are trying to determine if volcanic ash cement would be a good substitute. Professor Montiero hopes that fly ash and volcanic ash cements “could replace 40 percent of the world’s demand for Portland cement.”
Read the court decisionRead the full story...Reprinted courtesy of
Not So Fast, My Friend: Pacing and Concurrent Delay
April 25, 2022 —
William E. Underwood - ConsensusDocsWhen critical path activities are delayed by the owner (or another party), contractors will sometimes “pace,” or slow down, other activities to match the owner-caused delay. After all, why should the contractor hurry up and wait? But paced activities can often appear as concurrent delays on a project’s overall schedule. And all too often, contractors fail to contemporaneously document their efforts to pace work. Not only can this create avoidable disputes with owners and other contractors, but it can also create future roadblocks to the recovery of delay damages. This article examines the interplay between pacing and concurrent delay[1] and what contractors should do to minimize risk and preserve their rights to obtain more than a simple time extension for project delays.
Pacing versus Concurrent Delay
As a basic matter, most contracts allocate responsibility/liability for a schedule delay to the party that caused the delay. For example, if an owner is contractually required to provide equipment for a contractor to install, then the owner likely bears responsibility for any delays caused if the equipment is delivered late. If, however, the contractor was also behind schedule on other activities during this time and the project would have been delayed regardless of the owner’s late deliveries, then the delay is probably concurrent. And the contractor will generally be entitled to only an extension of time, and no other monetary relief.
Read the court decisionRead the full story...Reprinted courtesy of
William E. Underwood, Jones Walker LLP (ConsensusDocs)Mr. Underwood may be contacted at
wunderwood@joneswalker.com
Discussing Parametric Design with Shajay Bhooshan of Zaha Hadid Architects
May 10, 2017 —
Aarni Heiskanen - AEC Businessobotics, 3D printing, and digital fabrication—these evolving technologies are changing how we design and construct. Looking into the future can surprisingly cause us to rediscover history, as I learned when discussing parametric design with Shajay Bhooshan.
During the AEC Hackathon Munich in April 2017, I became acquainted with Shajay Bhooshan, associate at Zaha Hadid Architects. Shajay showed me designs that were intriguingly reminiscent of natural forms but completely modern in expression. He explained how these lightweight structures had been digitally designed and constructed with minimal use of material. One of the examples he shared was a large shell structure that consisted of aluminium elements that could be assembled and dismantled easily.
Read the court decisionRead the full story...Reprinted courtesy of
Aarni Heiskanen, AEC BusinessMr. Heiskanen may be contacted at
info@aepartners.fi
Florida SB 2022-736: Construction Defect Claims
February 07, 2022 —
Kelly A. Johnson - Saxe Doernberger & Vita, P.C.*Special thank you to SDV Law Clerk Iliriana Fteja for contributing to this article.
A new bill (SB 2022-736) was recently introduced to the Florida Senate. The proposed amendments to the statutes of limitations and repose could significantly impact construction defect claims by effectively creating additional exposure to contractors and insurance carriers.
The proposed bill requires all actions founded on the design, planning, or construction of an improvement to real property to be commenced within four years after the time to commence an action begins. Under the proposed amendment, the time to commence an action runs from the date of actual possession by the owner, the date of the issuance of a certificate of occupancy, the date of abandonment of construction if not completed, or the date of completion of the contract or termination of the contract between the professional engineer, registered architect, or licensed contractor and their employer. This provision would effectively alter the time to commence an action to whichever triggering event is earliest instead of the latest triggering event per the previous statute.
Read the court decisionRead the full story...Reprinted courtesy of
Kelly A. Johnson, Saxe Doernberger & Vita, P.C.Ms. Johnson may be contacted at
KJohnson@sdvlaw.com
Sarah P. Long Expands Insurance Coverage Team at Payne & Fears
March 19, 2024 —
Payne & Fears LLPSarah P. Long has joined Payne & Fears LLP as a Partner in the firm’s Insurance Coverage and Litigation Group. Sarah has represented clients in all aspects of insurance coverage and litigation and also focus on construction defect claims and litigation.
Before joining Payne & Fears, Sarah was a partner at Koeller, Nebeker, Carlson, Haluck, LLP, where she represented many of the nation’s builders in construction defect actions and bad faith insurance coverage disputes for 17 years.
Known for her dependability, efficiency, and creative problem-solving, Sarah always strives to secure the best results for her clients in the most efficient manner.
“We are excited to welcome Sarah to P&F as we continue to expand and add depth to our Insurance Litigation Group. I have known Sarah in a professional and personal capacity for more than 16 years. She is well respected by clients and peers in the legal profession. She is a bright, efficient, and innovative attorney and a wonderful person,” said Sarah Odia, the group’s co-chair.
Read the court decisionRead the full story...Reprinted courtesy of
Payne & Fears LLP
Real Estate & Construction News Roundup (08/15/23) – Manufacturing Soars with CHIPS Act, New Threats to U.S. Infrastructure and AI Innovation for One Company
September 25, 2023 —
Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law BlogIn our latest roundup, wildfires wreak havoc in Maui, JLL unveils an AI specifically for commercial real estate, the lasting effects of the CHIPS ACT, and more!
- So far, 11,000 JLL employees have used the company’s new proprietary large language model that has generative AI capabilities specifically for the commercial real estate industry. (Lindsey Wilkinson, Construction Dive)
- Since the enactment of the CHIPS Act, manufacturing activity has boomed with a nearly 80% increase from June 2022. (Sebastian Obando and Julia Himmel, Construction Dive)
- Construction-tech-focused investors among others have poured $35 million into an Israeli startup that develops leakage detection technology using artificial intelligence to prevent water damage. (Sharon Wrobel, Times of Israel)
Read the court decisionRead the full story...Reprinted courtesy of
Pillsbury's Construction & Real Estate Law Team
Affordable Harlem Housing Allegedly Riddled with Construction Defects
July 09, 2014 —
Beverley BevenFlorez-CDJ STAFFA family in Harlem, New York has demanded that Abyssinian Development Corporation pay $250,000 to fix the construction defects in their newly-purchased townhouse, according to The Daily News.
Allegedly, “[i]nterior walls, bamboo-tiled floors and windowsills began to crack shortly after they moved in, and an improperly installed gas boiler system” stopped working, while “rain has caused cellar walls to deteriorate.”
The townhouse is part of the “Harlem Village Homes II initiative that offers affordable houses in Harlem to those making below $130,000.”
Read the court decisionRead the full story...Reprinted courtesy of