Cambridge Massachusetts Building Expert Directory

E-Commerce Logistics Test Limits of Tilt-Up Construction

January 28, 2019 — Jeff Rubenstone - Engineering News-Record
While “fulfillment centers” and other e-commerce logistic facilities drive a hot market for the manufacturing sector, traditional construction methods such as tilt-up concrete panels are being pushed to ever-greater heights. At a recent project in Tulsa, Okla., contractor Clayco oversaw installation of tilt-up composite panels that reached 81 ft in height, using an unusual brace and a lot of careful pre-planning. Read the court decision
Read the full story...
Reprinted courtesy of Jeff Rubenstone, ENR
Mr. Rubenstone may be contacted at rubenstonej@enr.com

Understanding the Real Estate and Tax Implications of Florida's Buyer Ban Law

July 16, 2023 — Kelly Erb - White and Williams LLP
Last month, Gov. Ron DeSantis (R) of Florida signed a new law that would prohibit people who are not U.S. citizens or permanent residents and whose "domicile" is in China from purchasing certain real property in the state. Generally, the prohibition applies to agricultural land and other land within ten miles of restricted areas, including military bases and infrastructure like airports and wastewater treatment plants. The law, which takes effect on July 1, 2023, would also impose criminal penalties on any person or real estate company that knowingly sells real estate in the Sunshine State to anyone impacted by the ban. Read the court decision
Read the full story...
Reprinted courtesy of Kelly Erb, White and Williams LLP
Ms. Erb may be contacted at erbk@whiteandwilliams.com

“Bound by the Bond”

September 02, 2024 — Daniel Lund III - Lexology
A New York trial court granted judgment in favor of a performance bond surety on a construction project, based upon the failure of the claiming party to abide by the terms of the bond. The “AIA Document A312” bond form – described by the court (quoting surety law authority) to be “one of the clearest, most definitive, and widely used type of traditional common law ‘performance bonds’ in private construction” – contains various procedures which must be honored as a “condition precedent to an action to recover” on the bond/against the surety. One of those prerequisites is a “declaration of default” concerning the contractor principal (here, a subcontractor). The case involved the construction of an 85-story skyscraper in midtown Manhattan, and the performance of the subcontract for the building’s superstructure. The bonded contract was at a value of approximately $25,000,000 and obligated the sub to provide a performance bond “in a form similar to the [A312 bond],” and which was otherwise satisfactory to the obligee/construction manager. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

No Coverage Based Upon Your Prior Work Exclusion

October 01, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The California Court of Appeal affirmed the trial court's determination of no coverage for construction defects based upon the policy's prior work exclusion. Yu v. Landmark Am. Ins. Co., 2014 Cal. App. Unpub. LEXIS 5966 (Cal. Ct. App. Aug. 22, 2014). Plaintiff was the owner and developer of a hotel. She contracted with ATMI Design Build to act as general contractor to construct the hotel. C&A Framing Company was a subcontractor to provide rough framing for the project. In May 2003, ATMI fired C&A before it had completed all the work required by the subcontract. After May 2003, C&A never returned to the construction site. Notice of Completion for the project was recorded April 15, 2004. In September 2004, Landmark issued to C&A a CGL policy for the period September 18, 2004 to September 18, 2005. The policy was later cancelled, effective January 14, 2005. The policy contained an endorsement entitled, "Exclusion - Your Prior Work." The exclusion barred coverage for "'property damage' arising out of 'your work' prior to 9/18/04." Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

World's Longest Suspension Bridge Takes Shape in Turkey

November 29, 2021 — Aileen Cho - Engineering News-Record
It was a long-standing dream—not only of Ersin Arıoğlu, but of a nation. Could a suspension bridge someday cross the Dardanelles Strait in Turkey and provide another link between Europe and Asia? “To build a highway suspension bridge over the Çanakkale Strait has been on the agenda of the Turkish Ministry of Public Works for the last 20 years,” Arıoğlu, co-founder of contractor Yapi Merkezi, wrote in a technical paper. That was in 1994. Reprinted courtesy of Aileen Cho, Engineering News-Record Ms. Cho may be contacted at choa@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Delays and Suspension of the Work Under Fixed Price Government Contract

July 22, 2024 — David Adelstein - Florida Construction Legal Updates
Here is an interesting fact pattern and case decided by the Civilian Board of Contract Appeals dealing with (1) force majeure type events and epidemics (Covid-19); (2) suspension of the work; and (3) delays. These are three topics important to all contractors including federal contractors. In Lusk Mechanical Contractors, Inc. v General Services Administration, 2024 WL 1953697, CBCA 7759 (CBCA 2024), a contractor entered into a fixed price contract with the government to repair, replace, and modernize site and building systems at a federal building. The contractor commenced work right before Covid-19. When Covid-19 hit, the government issued the contractor a two-week suspension of work notice on March 27, 2020. The suspension of work allowed off-site administrative work to continue but suspended on-site physical work. The government extended the suspension of work three more times. The contractor could resume work on the exterior on June 1, 2020, but was not permitted to resume work on the interior until July 20, 2020. On the same date that the contractor was able to commence interior work, it submitted a modification for delay caused by the suspension – 64 days for the time period the entire site shutdown, and 51 days for the interior work shutdown. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Insurer's Motion for Summary Judgment to Reject Collapse Coverage Denied

November 24, 2019 — Tred R. Eyerly - Insurance Law Hawaii
The insurer unsuccessfully moved for summary judgment seeking to reject the insured's collapse claim. Gnannn v. United Servs. Auto, Ass'n, 2019 Conn. Super. LEXIS 1955 (Conn. Super Ct. July 11, 2019). The insureds' home was built in 1985 and they purchased their home in 1993. A home inspection reported that some settlement and curing related cracks existed in the slab floor, but no signs of abnormal settlement were noticed. The concrete walls were in overall good condition. In 2015, the insureds became aware of abnormal cracking in the basement. USAA was informed of the claim but denied coverage in October 2015. The insureds sued USAA. After suit was filed, the insureds hired an engineer, David Grandpre, to inspect their home. He observed severe cracking in the basement walls caused by an expansive chemical reaction within the concrete. The structure was not in imminent peril of falling down, and it continued as insureds' residence. But Mr. Grandpre noticed bulging and bowing, evidence that the concrete basement walls had failed and had begun to move inward due to the lateral pressure of the soil outside the home. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Making the World’s Longest Undersea Railway Tunnel Possible with BIM

December 11, 2018 — Aarni Heiskanen - AEC Business
Finland and Estonia are Baltic sea neighbors separated by the Gulf of Finland. Over eight million travelers and 1.2 million cars travel between Helsinki and Tallinn every year by boat. However, a consortium of companies is now planning to build the Finest railway tunnel between the two countries. The vision of such a tunnel has been around since the 1990s. In June 2016, Peter Vesterbacka, previously known as the marketer behind Rovio’s Angry Birds, made the latest endeavor public in his AEC Hackathon presentation. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES