SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Granting Stay, Federal Court Reviews Construction Defect Coverage in Hawaii

January 06, 2012 — Tred R. Eyerly - Insurance Law Hawaii

The federal district court ultimately stayed a construction defect case, but offered comments on the current status of coverage disputes for such defects in Hawaii. See National Union Fire Ins. Co. of Pittsburgh, Pa. v. Simpson Mfg. Co., 2011 U.S. Dist. LEXIS 128481(D. Haw. Nov. 7, 2011).

National Union filed a complaint for declaratory relief to establish it had no duty to defend or to indemnify Simpson Manufacturing Company in four actions pending in the Hawaii state courts. The state court actions concerned allegedly defective hurricane strap tie hold downs that were manufactured and sold by Simpson. The hurricane ties allegedly began to prematurely corrode and rust, causing cracking, spalling and other damage to homes.

National Union contended the underlying allegations did not constitute "property damage" caused by an "occurrence," as defined in the policies.

Read the full story…

Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

---

“But I didn’t know what I was signing….”

May 30, 2018 — Bobby Kethcart - Snell & Wilmer Real Estate Litigation Blog
In real estate cases—which frequently involve long purchase agreements, loan documents, personal guarantees, deeds of trust, etc.—we’ve likely all had a client or opposing party who trots out the line that they didn’t know what they were signing, or they didn’t read or understand what they were signing, so the document shouldn’t be enforced according to its terms. Most of us instinctively believe the claim is a loser: You signed the document, you’re bound by it. But is this actually right? Well, we did some digging. Here is the Arizona law on the subject: Nationwide Resources Corp. v. Massabni, 134 Ariz. 557, 658 P.2d 210 (App. 1982):

“A mistake of only one of the parties to a contract in the expression of his agreement or as to the subject matter does not affect its binding force and ordinarily affords no ground for its avoidance, or for relief, even in equity.” “A manifestation of acceptance to the offeror or his agent forms a contract regardless of the intent of the acceptor.”

Read the court decision
Read the full story...
Reprinted courtesy of Bobby Kethcart, Snell & Wilmer
Mr. Kethcart may be contacted at rkethcart@swlaw.com

---

S&P 500 Little Changed on Home Sales Amid Quarterly Rally

July 01, 2014 — Lu Wang and Jacob Barach – Bloomberg
June 30 (Bloomberg) --The Standard & Poor’s 500 Index was little changed, capping the longest string of quarterly gains since 1998, as a jump in pending home sales offset weaker-than-forecast manufacturing data. D.R. Horton Inc. rallied 3.2 percent, leading gains among homebuilders. Yahoo! Inc. (YHOO) rose 2.6 percent after Piper Jaffray Cos. recommended buying the stock. MannKind Corp. jumped 9.6 percent as the maker of diabetes drugs rebounded from its worst week in two months. Allergan Inc. declined 2.7 percent following regulatory decisions on its drugs. The S&P 500 fell less than 0.1 percent to 1,960.23 at 4 p.m. in New York. The equity benchmark gauge rose 4.7 percent for the quarter, a sixth consecutive advance. The Dow Jones Industrial Average lost 25.24 points, or 0.2 percent, to 16,826.60 today, trimming its quarterly advance to 2.2 percent. The Nasdaq Composite Index rose 0.2 percent, giving it a 5 percent increase for the three months. Ms. Wang may be contacted at lwang8@bloomberg.net; Mr. Barach may be contacted at jbarach1@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Lu Wang and Jacob Barach, Bloomberg

---

Coverage, Bad Faith Upheld In Construction Defect Case

October 26, 2017 — Tred R. Eyerly - Insurance Law Hawaii
The California Court of Appeal affirmed the trial court's finding of coverage for faulty workmanship allegations and bad faith by the insurer. Pulte Home Corp. v. Am Safety Indem. Co., 2017 Cal. App. LEXIS 748 (Cal. Ct. App. Aug. 30, 2017). Pulte Home Corporation was the general contractor and developer of two residential projects. American Safety issued several sequential comprehensive general liability policies to three of Pulte's subcontractors which named Pulte as an additional insured. The projects were completed by 2006. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly - Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

County Sovereign Immunity Invokes Change-Order Ordinance

December 20, 2017 — Lizbeth Dison - AHC Contruction Law Blog
The recent case of Fulton County v. Soco Contracting Company, Inc. addresses two very interesting questions for local government attorneys. First, can a county ordinance bolster a defense of sovereign immunity against a contractor’s claims? Second, can a county waive sovereign immunity by failing to respond to Requests for Admission? Facts: County hired Contractor to construct a facility near the airport. The contract provided that change orders must satisfy a county ordinance, which required approval by the Board of Commissioners. But in emergency situations, the County Manager could approve change orders, as long as the contractor executes a proposed modification and the purchasing agent approves it. The project suffered substantial delays, which Contractor attributed to weather, design delays, delays by the County in providing decisions on changes, and delays in obtaining permits during the federal government’s shutdown. As a result of these issues, Contractor comes County changed the scope of the contract. Contractor asserted claims against County for the delays and the changes to the work. The appellate opinion addresses the change order claims. Read the court decision
Read the full story...
Reprinted courtesy of Lizbeth Dison, Autry Hall & Cook, LLP

---

Tacoma Construction Site Uncovers Gravestones

August 11, 2011 — CDJ STAFF

The Seattle Times reports that a transit construction project has uncovered about twenty-five gravestones. The area was historically sensitive, as it is in territory once occupied by the Puyallup Tribe. At current report, no human remains have been found and the article cites the project?s archeological consultant as describing the gravestones as “not historically significant.”

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

---

S&P Suspended and Fined $80 Million in SEC, State Mortgage Bond Cases

January 21, 2015 — Keri Geiger and Matt Robinson – Bloomberg
Standard & Poor’s (MHFI) agreed to be suspended from rating the biggest part of the commercial-mortgage bond market and pay almost $80 million to state and federal authorities over claims it bent criteria to win business. S&P misled investors about the methodology it used in 2011 to rate eight commercial-mortgage backed securities, the U.S. Securities and Exchange Commission said in a statement today. The company will pay about $58 million to the SEC and an additional $19 million to attorneys general for New York and Massachusetts to settle the matter. Ms. Geiger may be contacted at kgeiger4@bloomberg.net; Mr. Robinson may be contacted at mrobinson55@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Keri Geiger and Matt Robinson, Bloomberg

---

Time is of the Essence, Even When the Contract Doesn’t Say So

January 11, 2021 — Christopher G. Hill - Construction Law Musings
Welcome to 2021! As often happens here at Construction Law Musings, the year starts with a few posts on notable construction law cases that dropped in the past year or so. Not only does this review hopefully help you keep up, but helps me keep up with the latest developments (one of the reasons why I keep blogging). The first of these cases is Appalachian Power Co. v. Wagman Heavy Civil, Inc. out of the Western District of Virginia federal court. In this case, Wagman Heavy Civil, Inc. (“Wagman”) and the Virginia Department of Transportation (“VDOT”) contracted for the design and construction of a highway interchange project (the “Project”). Wagman and the Appalachian Power Company (“APCO”) entered into a written contract (the “Written Contract”) for APCO to remove and relocate its utility structures (the “Work”) in order to facilitate construction for the Project. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---