Cambridge Massachusetts Building Expert Directory

Blue-Sky Floods Take a Rising Toll for Businesses

March 04, 2019 — Eric Roston - Bloomberg
When American colonists planned downtown Annapolis, Maryland in 1695, they wanted easy access to the sea. Almost 325 years later, the sea is now closer than ever. It’s so close, in fact, that 16 small businesses lost roughly 2 percent of their revenue in 2017. In a first-of-its-kind study, Stanford University and Naval Academy researchers looked at the effect of sea-level rise on a single city-block. Specifically, they examined sunny-day floods—inundation that occurs when infrastructure built for lower waters is no longer sufficient to keep back the highest tides—at a central parking lot at City Dock. As sea levels rise, these “nuisance floods” are becoming more common. From the 1950s to the early 2000s, the days of flooding in the 27 most vulnerable cities across the U.S. grew from two per year to nearly 12. Read the court decision
Read the full story...
Reprinted courtesy of Eric Roston, Bloomberg

Chambers USA 2021 Ranks White and Williams as a Leading Law Firm

June 07, 2021 — White and Williams LLP
White and Williams is once again recognized by Chambers USA as a leading law firm in Pennsylvania for achievements and client service in the areas of insurance law, real estate finance and banking and finance law. The firm has also been recognized for achievements and client service in banking and finance law in Philadelphia and the surrounding area. In addition, five lawyers received individual honors – two for their work in insurance, one for his work in real estate finance, another for her work in bankruptcy and restructuring and one for his work in commercial litigation. White and Williams is acknowledged for our renowned practice offering exceptional representation to insurers and reinsurers across an impressive range of areas including coverage, bad faith litigation and excess liability. The firm is recognized for notable strength in transactional and regulatory matters, complemented by the team's adroit handling of complex alternative dispute resolution proceedings. Chambers USA also acknowledged the firm's broad trial capabilities, including handling data privacy, professional liability, toxic tort coverage claims, and experience in substantial claims arising from bodily injury and wrongful death suits. White and Williams' cross-disciplinary team is also highlighted, as one source commented that "all advice was reasoned and respectful. They worked well together and provided exceptional representation." Read the court decision
Read the full story...
Reprinted courtesy of White and Williams LLP

Application Of Two Construction Contract Provisions: No-Damages-For-Delay And Liquidated Damages

February 14, 2022 — David Adelstein - Florida Construction Legal Updates
A recent Florida opinion between a prime contractor and a Florida public body touches upon two important issues: (1) the application of a no-damage-for-delay provision; and (2) the application of a liquidated damages provision. Both provisions find there way into many construction contracts. Unfortunately, the opinion is sparse on facts. Nevertheless, the application of these provisions is worthy of consideration. In this opinion, Sarasota County v. Southern Underground Industries, Inc., 2022 WL 162977 (Fla. 2d DCA 2022), a county hired a contractor to install sanitary and water piping underneath a waterway. During construction, a nearby homeowner complained that vibration from the drilling caused damage to his home. As a result, the county stopped the contractor’s work to address a potential safety issue, as it was contractually entitled to do. The contractor hired a structural engineer to inspect the house and the engineer issued a report determining that any alleged damage was cosmetic and that there was sufficient monitoring of the vibrations to prevent future damage. The contractor also had an insurance policy to cover any homeowner claim for damage. However, upon receipt of the engineer’s report, the county did not lift its stop work order. Rather, the stop work order remained in place for an additional 71 days. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Is The Enforceability Of A No-Damage-For-Delay Provision Inappropriate For Summary Judgment

February 24, 2020 — David Adelstein - Florida Construction Legal Updates
Is the enforceability of a no-damage-for-delay provision inappropriate for resolution on a summary judgment? The recent decision in U.S. f/u/b/o Kingston Environmental Services, Inc. v. David Boland, Inc., 2019 WL 6178676 (D. Hawaii 2019), dealing with Florida law, suggests that it is inappropriate for a summary judgment resolution, particularly when there is a right to a jury trial. In this case, a prime contractor was hired on a federal construction project in Hawaii. The prime contractor hired a subcontractor and the subcontractor sued the prime contractor and its surety under the Miller Act. Of interest, the subcontractor was seeking to recover for the costs it incurred due to construction delays. The prime contractor moved for summary judgment as to the no-damage-for-delay provision in the subcontract. The no-damages-for-delay provision read as follows (and it is a well-written no-damage-for-delay provision): The Subcontractor expressly agrees that the Contractor shall not be liable to the Subcontractor for any damages or additional costs, whether foreseeable or unforeseeable, resulting in whole or in part from a delay, hindrance, suspension, or acceleration of the commencement or execution of the Work, caused in whole or in part by the acts or omissions, whether negligent or not, of the Contractor including other subcontractors or material suppliers to the Project, its agents, employees, or third parties acting on behalf of the Contractor. The Subcontractor’s sole remedy for any such delay, hindrance, suspension, or acceleration shall be a noncompensable time extension. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Virginia Chinese Drywall and pollution exclusion

May 27, 2011 — CDCoverage.com

In Nationwide Mut. Ins. Co. v. The Overlook, LLC, No. 4:10cv69 (E.D. Va. May 13, 2011), homeowner Edmonds sued insured developer/general contractor Overlook seeking damages resulting from defective Chinese drywall installed in Edmonds’ home. Overlook’s CGL insurer Nationwide defended Overlook under a reservation of rights and filed a declaratory judgment action. The federal district trial court granted Nationwide’s motion for summary judgment.

Read the full story…

Reprinted courtesy of CDCoverage.com

Read the court decision
Read the full story...
Reprinted courtesy of

You're Doing Construction in Russia, Now What?

May 16, 2022 — Anazette Ray & Michael Vardaro - Zetlin & De Chiara LLP
In recent weeks, there has been a long list of companies, from all industries spanning from construction/engineering to fashion and hospitality, that have announced that they are completely severing ties with Russia, while a host of others have announced a temporary halt. See Jeffrey A. Sonnenfeld, Over 400 Companies Have Withdrawn from Russia – But Some Remain, Yale School of Management (Updated Mar. 21, 2022), https://som.yale.edu/story/2022/over-400-companies-have-withdrawn-russia-some-remain?utm_campaign=mb. For those developers, EPC contractors, and design professionals (engineers and architects) who have construction projects in Russia, the question is, “How should we proceed?” The U.S. initially stated that it was not issuing a total embargo on business dealings and trade relations with Russia in response to the nation’s invasion of Ukraine. Instead, the U.S., along with many other Western nations, issued targeted sanctions. See Francesco Giumelli, Understanding Targeted U.N. Sanctions: An Empirical Analysis, International Affairs, 91(6), 1351-1368 (explaining the difference between embargoes and targeted sanctions). However, after evidence of war crimes by Russia emerged, President Biden issued an Executive Order prohibiting U.S. individuals, whether in the states or abroad, from new investments in Russia and prohibiting U.S. individuals from transactions with Russian state-owned entities. See April 6, 2022, Presidential Actions, https://www.whitehouse.gov/briefing-room/presidential-actions/2022/04/06/prohibiting-new-investment-in-and-certain-services-to-the-russian-federation-in-response-to-continued-russian-federation-aggression/. This new Executive Order is said to not affect existing contracts in Russia, but instead prohibits new ones. Reprinted courtesy of Anazette Ray, Zetlin & De Chiara LLP and Michael Vardaro, Zetlin & De Chiara LLP Ms. Ray may be contacted at aray@zdlaw.com Mr. Vardaro may be contacted at mvardaro@zdlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Irvine Partner Cinnamon J. Carr and Associate Brittney H. Aquino Prevail on Summary Judgment

June 17, 2024 — Linda Carter - Kahana Feld
Congratulations to Irvine Partner Cinnamon J. Carr and Associate Brittney H. Aquino for Prevailing on a Motion for Summary Judgment! Irvine Partner Cinnamon J. Carr and Associate Brittney H. Aquino prevail on summary judgment in a slip and fall case venued in Riverside County! Plaintiff filed a lawsuit alleging negligence against Kahana Feld’s client, a grocery store with over 50 stores throughout Southern California. Prior to Plaintiff’s fall, security cameras captured footage of a third-party customer picking up a case of water bottles near the entrance of the store. The customer tilted the case and water streamed to the floor. The customer then returned the leaky case to the pallet, picked up another case of water, and walked away. Approximately a minute and 10 seconds later, Plaintiff walked through the area, slipping on the spilled water. Read the court decision
Read the full story...
Reprinted courtesy of Linda Carter, Kahana Feld
Ms. Carter may be contacted at lcarter@kahanafeld.com

When it Comes to COVID Emergency Regulations, Have a Plan

December 07, 2020 — Christopher G. Hill - Construction Law Musings
As I hope readers of this construction corner of the “blogosphere” know, Virginia adopted emergency COVID workplace regulations effective July 27, 2020, and with enforcement beginning at the end of September. Among the various items found in these regulations are general requirements for all employers, including among others, the requirement to self determine the employer’s risk level and disinfecting requirements. The regulations also have some requirements that seem specially directed toward construction industry employers. These include among them engineering controls and various requirements relating to communications with subcontractors. For a good overview of these requirements, see this great post at the Virginia Bar Association’s construction law blog. One item that is not included in the emergency regulations is a statement that following the regulations immunizes an employer from COVID infection-related lawsuits. For this reason, among others, all construction (and other industry) employers should have a COVID plan that meets the requirements of these regulations at whatever “hazard level” that employer meets. These plans should be written and distributed to all employees and include protocols for workplace/job site screening and what to do if there is a need for contact tracing. I also highly recommend that any plan be created with the help of a good Virginia workplace safety consultant well versed in the COVID regulations. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES