Seattle Washington Building Expert Directory

Lawsuit Gives Teeth to Massachusetts Pay Law

September 16, 2024 — Joseph Barra - Robinson+Cole
“The Massachusetts Legislature passed the state’s Prompt Pay Act 14 years ago to improve the downstream flow of money on most large-scale private construction projects. While the act established detailed protocols for administering applications for payment and other important construction phase processes, several questions about its interpretation and impact remained unanswered. Over the years, I watched as a significant portion of the Massachusetts design and construction community either ignored the law’s exacting requirements or were unaware of their applicability. The first indication of how the act would be interpreted came in 2022, when the state appeals court decided Tocci Building Corp. v. IRIV Partners LLC. In that case, the court strictly construed the act. It held that an owner (and its agent) who failed to promptly advise the project’s general contractor of specific factual and legal reasons why it was withholding payment, coupled with a failure to certify that funds were being withheld in good faith, violated the law—making the contractor liable for the unpaid funds. Read the court decision
Read the full story...
Reprinted courtesy of Joseph Barra, Robinson+Cole
Mr. Barra may be contacted at jbarra@rc.com

New Jersey Construction Worker Sentenced for Home Repair Fraud

October 22, 2013 — CDJ STAFF
Marcin Gradziel, who formerly worked for a construction company in Camden County, New Jersey, has been sentenced to seven years in state prison for insurance fraud. Mr. Gradziel admitted to creating fraudulent property damage claims, which he did for Precision Network Solutions, which did business as Precision Builders. Mr. Gradziel and others went through neighborhoods telling residents that their roofs or siding were damaged by hail and that they could get their homes repaired at no cost. Mr. Gradziel would then return to create damage before the inspectors arrived. Another employee, Dominik Sadowski, previously plead guilty, as did Precision Builders. The firm paid out $68,720 in restitution and is now out of business. Read the court decision
Read the full story...
Reprinted courtesy of

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Bert Hummel Appointed to Chief Justice’s Commission on Professionalism

May 10, 2021 — Bert Hummel - Lewis Brisbois
Atlanta Partner Bert Hummel was recently appointed to the Chief Justice’s Commission on Professionalism (CJCP) for the 2020-2021 term. In this role, Mr. Hummel has assisted in carrying out the charge of the CJCP, namely, to enhance professionalism among Georgia’s lawyers. Mr. Hummel’s appointment follows his participation on the Grants Committee and the Professionalism Committee of the CJCP. In addition, Mr. Hummel was selected as one of seven members of CJCP’s Benham Awards Subcommittee, which recognizes Georgia attorneys who dedicate their practice or time to serving the public and profession. “I am honored to be appointed to a body that continually strives to do so much good for both the legal profession and the community at large. For the past several months, I have appreciated the work the Commission has undertaken to promote professionalism in the practice of law through educational programming while also promoting community service programs through the CJCP’s Grants Committee that I served on as well. I look forward to continuing to serve with my colleagues at the CJCP to promote our shared goals. I also relish the opportunity to serve during a time in which professionalism is of the utmost importance as we navigate through the COVID-19 pandemic made even more unique and special by the fact this is the last year Chief Justice Melton will serve as chair after announcing his retirement from the Supreme Court effective at the end of the Bar year.” Read the court decision
Read the full story...
Reprinted courtesy of Bert Hummel, Lewis Brisbois
Mr. Hummel may be contacted at Bert.Hummel@lewisbrisbois.com

The ARC and The Covenants

May 30, 2018 — Christopher G. Hill - Construction Law Musings
For this week’s Guest Post Friday here at Musings, we welcome back Mike Collignon. Mike is a co-founder of the Green Builder Coalition. The Green Builder® Coalition amplifies the voice of green builders and professionals to drive advocacy and education for more sustainable building practices. As we start to see signs of a housing recovery, slow as it may be, I feel the industry is in a great position. All the effort put in by so many to improve our energy codes, green building programs & rating systems will finally be able to bear fruit. We can start to build homes that are much more environmentally responsible. Sure, we can have a lengthy debate about implementation and adoption rates, but you’ve got to walk before you can run. Unfortunately, I can see that progress getting shackled by an unexpected impediment: the architectural review committee (ARC; sometimes called “architectural committee” or “architectural control authority”) and the covenants of a homeowners’ association. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

A UK Bridge That Is a Lesson on How to Build Infrastructure

November 15, 2017 — Cameron J. Bell - Engineering News-Record
This country’s infrastructure—bridges, airports, dams and levees—needs wide-scale repair and renewal. The United Kingdom’s new Queensferry Crossing bridge, connecting Edinburgh to Fife in Scotland, sets a new standard for how to do it. The result speaks for itself: The Queensferry Crossing, a three-tower, 1.7-mile-long cable-stayed bridge, debuted in early September well within budget and a manageable eight-month time delay—a rare occurrence among bridges. According to research at the University of Oxford’s Saïd Business School, nine out of 10 fixed links (bridges and tunnels) suffer an average cost overrun of 34% and a time delay of roughly two years. Read the court decision
Read the full story...
Reprinted courtesy of Cameron J. Bell, ENR
ENR may be contacted at ENR.com@bnpmedia.com

Blog Completes Sixteenth Year

January 29, 2024 — Tred R. Eyerly - Insurance Law Hawaii
Insurance Law Hawaii completes its sixteenth year this month. We began posting in December 2002, 1761 posts ago. The year 2023 has added 105 new posts. The goal is to keep readers in tune with new developments in insurance-related cases from Hawaii and across the country. This year included a big case handled successfully by our office regarding insurers attempt to gain reimbursement of defense costs for uncovered claims. St. Paul Fire & Marine Ins. Co., et. al v. Bodell Construction Co., et. al, 2023 Haw. LEXIS 194 (Haw. Nov. 14, 2023). We will continue posting important coverage developments in the next year. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

United States Supreme Court Upholds Class Action Waivers in Arbitration Agreements

May 24, 2018 — Amy R. Patton, Jason I. Bluver, & Jeffrey K. Brown - Payne & Fears LLP
On May 21, 2018, the United States Supreme Court held, in a 5-4 decision, that arbitration agreements which mandate individualized resolution of claims (as opposed to class or collective resolution) are enforceable under the Federal Arbitration Act ("FAA"). In doing so, the Court rejected the argument that such "class action waivers" violate Section 7 of the National Labor Relations Act ("NLRA"), which generally protects employees' rights to act "in concert" with one another. The Court addressed a split created by decisions from three Federal Circuit Courts of Appeal: Epic Systems Corp v. Lewis (7th Circuit), Ernst & Young v. Morris (9th Circuit) and National Labor Relations Board v. Murphy Oil USA (5th Circuit). All three cases involved employees who sought to bring collective or class actions under the Fair Labor Standards Act (the "FLSA"), and their respective employers who sought to enforce pre-dispute arbitration agreements which waived such collective actions and mandated "one-on-one" arbitration of wage disputes. In support of their position, the employees argued that the class and collective action waivers were illegal because they violated the NLRA's prohibition on barring employees from engaging in "concerted activities." Reprinted courtesy of Payne & Fears LLP attorneys Amy R. Patton, Jason I. Bluver and Jeffrey K. Brown Ms. Patton may be contacted at arp@paynefears.com Mr. Bluver may be contacted at jib@paynefears.com Mr. Brown may be contacted at jkb@paynefears.com Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES