CAMBRIDGE MASSACHUSETTS BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Red Tape Is Holding Up a Greener Future

March 13, 2023 — The Editors - Bloomberg
Seven months on, Democrats are still celebrating the Inflation Reduction Act, even though a crucial determinant of its success — permitting reform for energy projects — remains undone. Recent data shows just how imperative it is for them to stop dragging their feet. What’s now called the IRA had little to do with inflation. It was a climate bill, and a big one: It provided $370 billion to improve energy efficiency, reduce emissions and smooth the path to a clean-power economy. It came on top of a 70% surge in private investment since 2017. But the biggest impediment to the US energy transition isn’t financing: It’s building. A decade ago, between 25% and 30% of proposed wind and solar projects moved from the drawing boards to completion. But as new projects and new funding have soared, utilities have been unable to keep up, leading to an immense backlog. A recent report by BloombergNEF found that over just six years, global clean-energy investment has gone from half the level of fossil-fuel investment to near parity, an extraordinary leap that reflects the market’s appetite for clean power. Yet America’s dysfunctional regulation is preventing many needed projects from even breaking ground. Read the court decision
Read the full story...
Reprinted courtesy of The Editors, Bloomberg

---

DC Wins Largest-Ever Civil Penalty in US Housing Discrimination Suit

November 15, 2022 — Kriston Capps - Bloomberg
Three real estate companies operating in Washington, DC, will pay record-breaking penalties in a suit brought by the city for illegally discriminating against tenants who use Section 8 vouchers and other forms of housing assistance. The attorney general for the District of Columbia, Karl Racine, announced on Thursday a settlement for $10 million. While fair housing cases involving lenders have resulted in larger compensation payouts, $10 million is the largest civil penalty ever levied in a housing discrimination case. In 2020, the city sued several entities — DARO Management Services, DARO Realty and New York-based parent company Infinity Real Estate, as well as several executives — over housing practices in the District. DARO Management operates and rents some 1,200 residential units in more than a dozen apartment buildings spread across Wards 1, 2 and 3, which include DC’s more affluent areas. (DARO Realty owns the properties, DARO Management operates them, and Infinity owns both affiliates.) Read the court decision
Read the full story...
Reprinted courtesy of Kriston Capps, Bloomberg

---

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Architect Not Responsible for Injuries to Guests

September 01, 2011 — CDJ STAFF

The Texas Court of Appeals has ruled, with one dissent, that the architectural firm that designed a home was not responsible to the injuries caused to guests when a balcony collapsed. Judge David Puryear wrote the majority opinion in Black + Vernooy Architects v. Smith.

Black + Vernooy designed a vacation home for Robert and Kathy Maxfield in 2000. The Maxfields hired a general contractor to build the home. The general contractor hired a subcontractor to build a balcony; however, the subcontractor did not follow the architect’s design in building the balcony.

A year after the house was completed; the Maxfields were visited by Lou Ann Smith and Karen Gravely. The balcony collapsed under the two women. Ms. Gravely suffered a broken finger, a crushed toe, and bruises. Ms. Smith was rendered a paraplegic as a result of the fall. They sued the Maxfields, the general contractor, and the architects for negligence. The Maxfields and the general contractor settled. A jury found that the architects held 10% of the responsibility. The architects appealed the judgment of the district court.

The Appeals Court reversed this judgment, noting that “there has been no allegation that the Architects negligently designed the balcony or that the Architects actually created the defects at issue.” Further, “the Smiths allege that the defect was caused by the construction practices of the contractor and subcontractor when the balcony was not built in accordance with the design plans of the Architects.”

The court found that even though the architects had a duty “to endeavor to guard against defects and deficiencies in the construction of the home and to generally ascertain whether the home was being built in compliance with the construction plans,” this duty did not extend to third parties.

Read the court’s decision…

Read the court decision
Read the full story...
Reprinted courtesy of

---

The ABCs of PFAS: What You Need to Know About Liabilities for the “Forever Chemical”

February 22, 2021 — Robert F. Walsh, Gregory S. Capps & R. Victoria Fuller - Complex Insurance Coverage Reporter
This article is based on a presentation the authors made at White and Williams LLP’s Virtual Coverage College® on October 22, 2020. Every year, hundreds of insurance professionals come to Philadelphia—this year via our online platform—to participate in a full day of lectures and interactive presentations by White and Williams lawyers and guest panelists about the latest issues and challenges involved in claim handling and insurance litigation. Visit coveragecollege.com for more information and stay tuned for Coverage College® 2021. Perfluoroalkyl and polyfluoroalkyl substances, commonly referred to as PFAS or PFOS, have been a key ingredient in numerous industrial and consumer products for decades. These man-made chemicals are prevalent and are also known for their longevity in the environment. More recently, PFAS have been the focus of thousands of lawsuits alleging personal injury and property damage. Some insurers have already questioned whether PFAS could rival asbestos in scope and bottom-line impacts. It is a legacy that confronts manufacturers and other defendants and insurers today. This article provides a primer on PFAS, including the current regulatory framework and litigation landscape. We also identify some key emerging coverage issues insurers should be aware of when dealing with PFAS claims under liability and first-party property policies. Reprinted courtesy of Robert F. Walsh, White and Williams LLP and Gregory S. Capps, White and Williams LLP Mr. Walsh may be contacted at walshr@whiteandwilliams.com Mr. Capps may be contacted at cappsg@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Balcony Collapses Killing Six People

June 17, 2015 — Beverley BevenFlorez-CDJ STAFF
Six college students died from injuries that occurred when a balcony collapsed at a downtown apartment complex in Berkeley, California, according to Berkeleyside. The city of Berkeley ordered a structural inspection of the remaining balconies at Library Gardens, and to immediately remove the failed balcony. The following day Berkeleyside reported that the city ordered the Library Gardens’ owners to remove another balcony after “[i]nspectors determined that the third-floor balcony ‘was structurally unsafe and presented a collapse hazard endangering public safety.’” Berkeley’s mayor, Tom Bates, stated that “investigators believe the wood wasn’t sealed properly at the time of construction and was damaged by moisture as a result,” the Wall Street Journal reported. Read the full story, 6/16/15 Berkeleyside article... Read the full story, 6/17/15 Berkeleyside article... Read the full story, Wall Street Journal... Read the court decision
Read the full story...
Reprinted courtesy of

---

Super Lawyers Selects Haight’s Melvin Marcia for Its 2023 Northern California Rising Stars List

July 16, 2023 — Melvin F. Marcia - Haight Brown & Bonesteel LLP
Congratulations to Melvin Marcia who was selected to the 2023 Northern California Rising Stars list. Each year, no more than 2.5 percent of the lawyers in the state are selected by the research team at Super Lawyers to receive this honor. Super Lawyers, part of Thomson Reuters, is a rating service of outstanding lawyers from more than 70 practice areas who have attained a high degree of peer recognition and professional achievement. The annual selections are made using a patented multiphase process that includes a statewide survey of lawyers, an independent research evaluation of candidates and peer reviews by practice area. The result is a credible, comprehensive and diverse listing of exceptional attorneys. The Super Lawyers lists are published nationwide in Super Lawyers magazines and in leading city and regional magazines and newspapers across the country. Super Lawyers magazines also feature editorial profiles of attorneys who embody excellence in the practice of law. Read the court decision
Read the full story...
Reprinted courtesy of Melvin F. Marcia, Haight Brown & Bonesteel LLP
Mr. Marcia may be contacted at mmarcia@hbblaw.com

---

Brenner Base Tunnelers Conquer Peaks and Valleys in the Alps

October 21, 2019 — Scott Blair - Engineering News-Record
A logistics tangle decades in the unraveling, the Brenner Base Tunnel project is having a banner year. Twin tunnel boring machines in May were released on their relentless journey to mine the main tunnels underneath the Alps between Austria and Italy, while a multinational crew of 2,400 workers armed with a toolkit of just about every mining technique is swarming four major worksites, including a particularly challenging area where workers must undercut a river and pass through the fast-flowing aquifer below it. Read the court decision
Read the full story...
Reprinted courtesy of Scott Blair, ENR
Mr. Blair may be contacted at blairs@enr.com

---