Fairfield Connecticut Building Expert Directory

New Jersey Court Adopts Continuous Trigger for Construction Defect Claims

November 15, 2017 — Tred R. Eyerly - Insurance Law Hawaii
The New Jersey Superior Court, Appellate Division, adopted the continuous trigger for establishing which insurers were on the risk for construction defect claims. Air Master & Cooling, Inc. v. Selective Ins. Co. of Am., 2017 N.J. Super. LEXIS 144 (N.J. Super. Ct., App. Div. Oct. 10, 2017). The insured, Air Master, worked as a subcontractor on the construction of a condominium building. Air Master performed HVAC work in the building between November 2005 and April 2008. Air Master's work consisted of installing condenser units on rails on the building's roof, and also HVAC devices within each individual unit. Starting in early 2008, some of the unit owners began to notice water infiltration and damage in their windows, ceilings, and other portions of their units. On April 29, 2010, an expert consultant, Jersey Infrared Consultants, performed a moisture survey of the roof for water damage. A report identified 111 spots on the roof damaged by moisture from water infiltration. The report noted it was impossible to determine when moisture infiltration occurred. The expert recommended that these damaged areas of the roof be removed and replaced. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Washington Supreme Court Sides with Lien Claimants in Williams v. Athletic Field

September 30, 2011 — Douglas Reiser, Builders Council Blog

The Washington Supreme Court issued their opinion today on Williams v. Athletic Field, perhaps the most talked about construction law case in the past few years. I have discussed this case exhaustively here on Builders Counsel. Today we have a resolution.

In an unanimous opinion issued today, the high court sided with lien filers who followed a sample form provided in RCW 60.04.091. Additionally, the court found that a lien company - and presumably other persons - could sign the lien for the lien claimant, as an agent, without invalidating the lien.

Read the full story…

Reprinted courtesy of Douglas Reiser of Reiser Legal LLC. Mr. Reiser can be contacted at info@reiserlegal.com

Read the court decision
Read the full story...
Reprinted courtesy of

Another Worker Dies in Boston's Latest Construction Accident

June 20, 2022 — Scott Van Voorhis - Engineering News-Record
Boston Police and the US Occupational Safety and Health Administration are investigating a June 9 early morning construction accident that killed a worker in Boston’s Seaport district— the latest in a spate of fatalities at worksites across the city's metro area during the past 18 months. Reprinted courtesy of Scott Van Voorhis, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Homeowner's Mold Claim Denied Due to Spoilation

April 20, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The trial court's issuance of summary judgment to the insurer for mold and water damage was upheld on appeal. Schwartz v. Encompass Indem. Co., 2016 Mich. App. LEXIS 551 (Mich. Ct. App. March 15, 2016). The contractor was demolishing a portion of the insured's home when he discovered water damage and what appeared to be mold. The contractor believed this damage was due to improper roof installation and leaks around the windows. Further demolition was done to water-damaged portions of the home. The insured filed a claim with Encompass for mold and "over-demolition." When Encompass's adjuster inspected the home, none of the alleged mold-affected material was present because it had been removed from the site by the contractor. The claims were denied. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Colorado Abandons the “Completed and Accepted Rule” in Favor of the “Foreseeability Rule” in Determining a Contractor’s Duty to a Third Party After Work Has Been Completed

January 17, 2013 — Brady Iandiorio, Higgins, Hopkins, McLain & Roswell, LLC

In a recent case, the Colorado Court of Appeals found that a contractor had a duty to a third party to warn it of a dangerous condition, even after the contractor had completed its work and the owner had accepted the contractor’s work. Collard v. Vista Paving Corp., -- P.3d --, 2012 WL 5871446 (Colo. App. 2012). While not an earth shattering or entirely new concept, the decision rendered in Collard directly accepted the foreseeability rule at the expense of the completed and accepted rule. Id.

In Collard, the City of Grand Junction (“the City”) hired Vista Paving Corp. (“Vista”) to construct two road medians according to the City’s plans and designs. On July 9, 2007, Vista began work on the medians. According to its contract with the City, Vista was responsible for traffic control during construction of the medians. On July 19, 2007, Vista completed its construction of both medians. On that date, the City’s project inspector conducted his final inspection of Vista’s work. The City’s inspector then told Vista that its work had been completed and that Vista was authorized to leave the site. Vista requested permission to remove the traffic control devices to which the City’s inspector agreed. Vista removed all of its traffic control devices.

Read the court decision
Read the full story...
Reprinted courtesy of Brady Iandiorio
Mr. Iandiorio can be contacted at iandiorio@hhmrlaw.com

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Cross-Motions for Partial Judgment on the Pleadings for COVID-19 Claim Denied

May 24, 2021 — Tred R. Eyerly - Insurance Law Hawaii
The court denied both parties' motions for partial judgment on the pleadings seeking clarification of the policy's contamination exclusion. Thor Equities, LLC v. Factory Mut. Ins. Co., 2021 U.S. Dist. LEXIS 62967 (S.D. N.Y. March 31, 2021). Thor was a commercial landlord, renting properties across the country to hundreds of tenants, for use in a variety of businesses, including office space, retail stores, restaurants, and bars. When state governments began shutting down businesses and issuing stay-at-home orders in March 2020, many of Thor's tenants had to close shop and sought abatements or other accommodations. Thor alleged it suffered significant business interruption as a result of the pandemic. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Uniformity in Florida’s Construction Bond Laws Brings About Fairness for the Industry

August 17, 2020 — Gary L. Brown - Construction Executive
Before Florida updated its laws for construction bonds, there were some significant differences between how liens and bond claims were litigated. Forms and procedures lacked uniformity that created unnecessary challenges for the construction industry and legal practitioners serving the industry. Now, more consistency among the laws should benefit contractors, as well as lower-tiered subcontractors and suppliers. Since the updates were instated in October 2019, some of the procedures and rules used for lien enforcement have been extended to bond claims, which may make it easier to resolve differences over payment and performance. That should come as a relief to local contractors and law firms, as well as to the numerous developers and construction companies based outside of Florida that operate in the state or are considering doing so. Florida is now the number one destination for new residents, especially from high-tax states, according to IRS data. With them come new homes, retail centers, offices, industrial space, roads and other infrastructure in what is now the third-most-populous state in the nation. Reprinted courtesy of Gary L. Brown, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Brown may be contacted at gbrown@kklaw.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES