Fairfield Connecticut Building Expert Directory

Mutual Or Concurrent Delay Caused By Subcontractors

March 23, 2020 — David Adelstein - Florida Construction Legal Updates
How are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project? Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs. There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project. The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

French President Vows to Rebuild Fire-Collapsed Notre Dame Roof and Iconic Spire

June 03, 2019 — Scott Blair & Peter Reina - Engineering News-Record
Two British masonry experts familiar with centuries-old stone structures voiced concern that the catastrophic fire that collapsed the roof and spire of Notre Dame on April 15 could also have damaged stonework of the iconic Paris cathedral that may affect its stability. Reprinted courtesy of Scott Blair, ENR and Peter Reina, ENR Mr. Blair may be contacted at blairs@enr.com Mr. Reina may be contacted at reina@btinternet.com Read the court decision
Read the full story...
Reprinted courtesy of

Motion to Strike Insurer's Expert Opinion Granted

August 13, 2019 — Tred R. Eyerly - Insurance Law Hawaii
The court granted the insured's motion to strike the testimony of the insurer's expert because the opinion lacked sufficient explanation or analysis. Affinity Mut. Ins. v. Thacker Air Conditioning Refrigeration Heating, 2019 U.S. Dist. LEXIS 84713 (N.D. Ind. May 20, 2019). The insured owned a market that needed renovations. The roof over an addition to the market extended from the wall of the extension to the top of the existing roof. The area between the old and new roofs was filled with blown-in insulation, so that the structural support from the new overbuilt roof was not visible. The weight of the overbuilt roof rested on top of the existing roof at the point where they met. This added additional weight on the trusses supporting the main roof. In 2014, the market upgraded the building with heating and insulation. Thacker was a subcontractor for work on the hearing system. Six gas furnaces, spaced about 35 feet apart along the length of the building, were placed by Thacker. The total weight of each unit was estimated at 280 pounds. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Understanding Liability Insurer’s Two Duties: To Defend and to Indemnify

December 26, 2022 — David Adelstein - Florida Construction Legal Updates
A liability insurer has two duties that are the crux of a liability policy: the duty to defend the insured in legal actions and the duty to indemnify the insured from losses covered under the policy. Many times, policyholders (insureds) do not fully understand or appreciate these two important duties. They need to and this is why having private counsel assist with coverage-related considerations is an absolute must. An insurers’ duty to defend is separate from its duty to indemnify. A recent opinion out of the Middle District of Florida in Progressive Express Ins. Co. v. Tate Transport Corp., 2022 WL 16963815 (M.D.Fla. 2022) clarifies the distinction between these duties with a focus on an insurer’s initial duty — the duty to defend. Please read below so you can have more of an appreciation of these duties. The court does a good job discussing Florida law with the emphasis on when an insurer’s initial duty to defend kicks-in: Duty to Defend Under Florida law, “an insurer’s duty to defend its insured against a legal action arises when the complaint alleges facts that fairly and potentially bring the suit within policy coverage.” The duty to defend is a broad one, broader than the duty to indemnify, and “[t]he merits of the underlying suit are irrelevant.” We determine whether an insurer has a duty to defend its insured based only on “the eight corners of the complaint and the policy,” and only as the complaint’s alleged facts are “fairly read[.]” The “facts” we consider in evaluating the duty to defend come solely from the complaint, regardless of the actual facts of the case and regardless of any later developed and contradictory factual record. “Any doubts regarding Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Does the Recording of a Mechanic’s Lien Memorandum by Itself Constitute Process? Read to Find Out

August 04, 2021 — Christopher G. Hill - Construction Law Musings
As a Virginia construction attorney representing those in the construction industry, mechanic’s liens are near and dear to my heart. The enforcement of mechanic’s lien rights in Virginia is a two-step process. The first step is the recording of a properly-timed memorandum of lien that includes all of the statutorily required information. The second step is a suit to enforce that memorandum of lien filed in Circuit Court. A recent case out of Norfolk, VA examined the first of these steps. In Central Radio Co. v. Warwick Builders, et al., and as Count III of a three-count Complaint, the Plaintiff, Central Radio Co., alleged that the Defendant, Warwick Builders, recorded a memorandum of lien that Warwick knew to be without merit and therefore committed an abuse of process. However, Warwick did not file any Circuit Court suit to enforce that lien. Central Radio Co. essentially alleged that the filing of the memorandum by itself constituted an attempt to extort payment and therefore was an abuse of process. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Did the Court of Appeals Just Raise the Bar for California Contractors to Self-Report Construction-Related Judgments?

June 10, 2015 — Garret Murai – California Construction Law Blog
An interesting construction case just came out from the California Court of Appeals for the Second District this past month – Pacific Caisson & Shoring, Inc. v. Bernards Bros., Inc., California Court of Appeals for the Second District, Case No. B248320 (May 19, 2015) – which discusses a number of intertwining issues that can be faced by contractors in California and concludes with a result that I’m not sure I quite agree with. Among the issues discussed by the Court of Appeal were:

The application of the dreaded Business and Professions Code section 7031 which: (1) precludes a contractor from making a claim for payment for work performed; and (2) requires a contractor to disgorge all monies received for work performed, if the contractor was not properly licensed at all times that work was performed;
The impact of an unsatisfied judgment against one contractor on the license of another “related” contractor; and
Whether a stipulated judgment providing for payments over time is an unsatisfied final judgment under the Licensing Law.

Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

How to Survive the Insurance Claim Process Before It Starts –Five Tips to Keep Your Insurance Healthy

December 15, 2016 — Robert K. Scott – Newmeyer & Dillion LLP
Every day we read about fires, floods and other tragedies that occur. They seem to be so prevalent, now than ever before. The old notion that “it can’t happen to my family” is not the best approach to being ready if you are faced with a claim. Preparation is the key to readiness in the world of insurance. These five tips can easily be implemented just in case:

Check your coverage now – not after a catastrophic event for your family. Know and ask in writing if all your insurance needs are covered and your financial limits are sufficient. A phone call to your agent or broker can start the process, but at the conclusion of the process confirm any advice or adjustments in writing, and save it in your insurance file. Policies and important correspondence can be imaged and saved in the cloud so it’s retrievable if a big loss occurs. Ask your child or grandchild how to do this if you do not understand the cloud storage and retrieval system.
Video your belongings and save in the cloud. – Use your smart phone to video your home, contents, boats, etc. Talk about the items in the viewfinder as you go. If there are expensive personal items, note their worth and ask your agent or broker if such items need to be “scheduled”---detailed with agreed upon amounts. You pay a little extra on these items but you can then recover their actual value if lost. Most “personal property” items fall under a general category under most homeowner policies and may not be sufficient.

Read the court decision
Read the full story...
Reprinted courtesy of Robert K. Scott, Newmeyer & Dillion LLP
Mr. Scott may be contacted at Robert.scott@ndlf.com

Federal Energy Regulator Approves Rule to Speed Clean Energy Grid Links

August 28, 2023 — Mary B. Powers & Debra K. Rubin - Engineering News-Record
The Federal Energy Regulatory Commission unanimously passed a sweeping rule at its July 27 open meeting meant to eliminate U.S. transmission system bottlenecks for new power generation and storage. But stakeholders worry that more needs to be done to add needed and viable clean energy projects to the grid. Reprinted courtesy of Mary B. Powers, Engineering News-Record and Debra K. Rubin, Engineering News-Record ENR may be contacted at enr@enr.com Ms. Rubin may be contacted at rubind@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES