CAMBRIDGE MASSACHUSETTS BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Hawaii Appellate Court Finds Agent May Be Liable for Failing to Submit Claim

November 01, 2022 — Tred R. Eyerly - Insurance Law Hawaii
After the agent informed the insured there was no coverage and submitting a claim would be a useless effort, the Hawaii Intermediate Court of Appeal reversed the trial court's dismissal of the insured's suit against the agent. Pflueger, Inc. v. AIG Holdings, Inc., 2022 Haw. App. LEXIS 279 (Haw. Ct. App. Sept. 2, 2022). In May 2008, Pflueger notified its agent, Noguchi & Associates, Inc., that it had received federal grand jury subpoenas. Noguchi informed Pflueger that the subpoenas did not qualify as a "claim" under two policies issued by National Union. Consequently, Noguchi did not forward a claim or the subpoenas to National Union and did not seek clarification as to whether the grand jury subpoenas were covered under the policies. Pflueger relied upon Noguchi's representations and took no further action until its attorney submitted a demand letter tendering Pflueger's defense to Nation Union nine months later, in February 2009. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

City Covered From Lawsuits Filed After Hurricane-Damaged Dwellings Demolished

January 15, 2014 — Tred R. Eyerly - Insurance Law Hawaii
The Fifth Circuit affirmed the District Court's finding that a duty to defend was owed St. Bernard Parish after it was sued for condemning and demolishing housing destroyed by Hurricane Katrina. Lexington Ins. Co. v. St. Bernard Parish Gov't, 2013 U.S. App. LEXIS 24292 (5th Cir. Dec. 6, 2013). St. Bernard's policies with Lexington provided coverage for "property damage" and "personal and advertising injury." The policies included a $10,000,000 per occurrence and aggregate limit, subject to a $250,000 retained limit. Lexington denied coverage and filed for a declaratory judgment that the policies' $250,000 retained limit applied separately to each alleged demolition or property damage asserted in the underlying actions. Under this theory, no defense would be owed because no property had a value exceeding $250,000. The District Court found that only one retained limit applied. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Fifth Circuit Holds Insurer Owes Duty to Defend Latent Condition Claim That Caused Fire Damage to Property Years After Construction Work

September 21, 2020 — Jeremy S. Macklin - Traub Lieberman
Most general liability policies only provide coverage for “property damage” that occurs during the policy period. Thus, when analyzing coverage for a construction defect claim, it is important to ascertain the date on which damage occurred. Of course, the plaintiffs’ bar crafts pleadings to be purposefully vague as to the date (or period) of damage to property. A recent Fifth Circuit decision applying Texas law addresses this coverage issue in the context of allegations of a condition created by an insured during the policy period that caused damage after the policy expired. In Gonzalez v. Mid-Continent Cas. Co., 969 F.3d 554 (5th Cir. 2020), Gilbert Gonzales (the insured) was a siding contractor. In 2013, the underlying plaintiff hired Gonzales to install new siding on his house. In 2016, the underlying plaintiff’s house was damaged in a fire. The underlying plaintiff sued Gilbert in Texas state court alleging that when Gonzalez installed the siding in 2013, he hammered nails through electrical wiring and created a dangerous condition that caused a fire three years later in 2016. At the time Gilbert performed construction work, he was insured by Mid-Continent Casualty Company. Mid-Continent disclaimed coverage to Gonzales on the basis that the complaint unequivocally alleged that property was damaged in 2016 and there were no allegations that property damage occurred prior to 2016 or was continuing in nature. Read the court decision
Read the full story...
Reprinted courtesy of Jeremy S. Macklin, Traub Lieberman
Mr. Macklin may be contacted at jmacklin@tlsslaw.com

---

Recovering Unabsorbed Home Office Overhead Due to Delay

May 30, 2022 — David Adelstein - Florida Construction Legal Updates
In the preceding article, I discussed the use of a retrospective as-built delay analysis in a case before the Civilian Board of Contract Appeals (CBCA). This case also discussed a damages component in certain delay claims known as unabsorbed home office overhead—a challenging damages component to recover because this deals with indirect costs as opposed to direct costs. Unabsorbed home office overhead is a damages component when the contractor is on standby, but this is NOT as easy as just claiming standby thereby you are automatically entitled to unabsorbed home office overhead. There are requirements that MUST be met.

To obtain an equitable adjustment for unabsorbed home office overhead as compensation for being on standby, [the contractor] must initially show “[1] a government-caused delay of uncertain duration,” that “[2] the delay extended the original time for performance” or precluded the contractor from finishing earlier than scheduled, and that “[3] the contractor [was] on standby and unable to take on other work during the delay period. CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022) quoting Nicon, Inc. v. U.S., 331 F.3d 878, 883 (Fed. Cir. 2003).

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Residential Building Sector: Peaking or Soaring?

October 01, 2013 — CDJ STAFF
Forbes notes that residential builders and remodelers are one of the fastest-growing groups of privately held companies, but is that growth going to continue? Tim McPeak, an analyst at Sageworks, said, “aside from the strong sales growth, these companies have a relatively healthy 4.6% net profit margin.” Another analyst, Scott Cresswell of The Bonadio Group, said that his “clients who do multifamily are exponentially off the charts with new work. Cresswell also noted that firms in the Northeast are also experiences labor shortages, particularly with wood-frame construction, since, “there are not a lot of carpenters out there.” As a result of the new construction, some workers are more money from overtime. A further hike in interest rates may stop this growth. Mr. McPeak noted that “the expectation of everyone is we’re going to see rates rise.” Read the court decision
Read the full story...
Reprinted courtesy of

---

US-Mexico Border Wall Bids Include Tourist Attraction, Solar Panels

April 05, 2017 — Engineering News-Record
SAN DIEGO (AP) — Tuesday was the deadline for companies to propose designs for President Donald Trump's border wall with Mexico . U.S. Customs and Border Protection will ask several of the bidders to build prototypes in San Diego . The government won't identify companies until contracts are awarded around June 1 — and even then, only the winners — but some bidders released plans on their own. Read the court decision
Read the full story...
Reprinted courtesy of Engineering News-Record
ENR may be contacted at ENR.com@bnpmedia.com

---

New Rule Prohibits Use of Funds For Certain DoD Construction and Infrastructure Programs and Projects

May 30, 2018 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
Recently, our colleagues Glenn Sweatt and Alex Ginsberg published their Client Alert titled DFARS Clause Blocks Funding for Unsafe Projects in Afghanistan, Recently published regulation implements the FY17 NDAA to prohibit use of funds for DoD construction and infrastructure programs and projects in Afghanistan that cannot be safely accessed by U.S. Government personnel. Takeaways include:

New rule prevents Government contracting officers from funding projects that are not able to be safely accessed by Government civilian or military personnel, as these may pose an increased risk of fraud, corruption or waste, or lack efficient oversight.

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

---

Colorado Supreme Court Decision Could Tarnish Appraisal Process for Policyholders

September 16, 2019 — Michael V. Pepe - Saxe Doernberger & Vita, P.C.
On June 24, 2019, the Colorado Supreme Court ruled that the plain language of appraisal provisions in insurance policies, requiring “impartial appraisers,” direct appraisers to be “unbiased, disinterested, and unswayed by personal interest,” regardless of who hires them, and prohibits the party-appointed appraisers from acting as advocates. A common and attractive alternative dispute resolution option, the appraisal process usually entails the policyholder and insurer each hiring their own appraiser, who estimates how much the claim is worth. These appraisers also select a third-party umpire, and if they cannot agree upon one, a court appoints one. The umpire analyzes the conflicting estimates and presents a number to resolve the dispute. If two of the three parties agree with the outcome, the number becomes binding. Owners Ins. Co. v. Dakota Station II Condo. Ass'n, Inc.1 began when Dakota Station II Condominium Association Inc. (“Dakota”) and its insurer, Owners Insurance Company (“Owners”) could not agree on how to value two claims arising out of weather damage. To settle the differences and come to a resolution, Dakota invoked the appraisal provision in the insurance policy instructing each party to select its own “competent and impartial appraiser.” Ultimately, a court-appointed umpire considered six cost categories in dispute and adopted four of Owners’ estimates and two of Dakota’s. Read the court decision
Read the full story...
Reprinted courtesy of Michael V. Pepe, Saxe Doernberger & Vita, P.C.
Mr. Pepe may be contacted at mvp@sdvlaw.com

---