Seattle Washington Building Expert Directory

Defining Constructive Acceleration

March 22, 2021 — David Adelstein - Florida Construction Legal Updates
When it comes to the definition of “constructive acceleration,” the case of Fraser Const. Co. v. U.S., 384 F.3d 1354 (Fed.Cir. 2004) is a cited case and contains an instructive definition, quoted below, for proving a constructive acceleration claim. In a nutshell, a constructive acceleration claim is when the contractor incurs added costs for trying to complete the contract on time when it should be provided extensions of time to perform based on excusable delay (i.e., delay not caused by the contractor). These added costs could be bringing in additional supervision to manage the work, adding manpower to perform the work, working overtime, working weekends, adding more shift work, stacking trades, etc. However, just because a contractor claims they have been constructively accelerated does not make it so. The contractor has to actually ask for an extension of time based on an excusable delay and the owner either denied the extension or unreasonably sat on the request for an extension of time; thus, the contractor incurred significant costs to accelerate in order to finish the project on time because it was deprived of a requested time extension for excusable delay. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Doctrine of Merger Not a Good Blend for Seller of Sonoma Winery Property

April 15, 2015 — Kristen Lee Price and Lawrence S. Zucker II – Haight Brown & Bonesteel LLP
In Ram’s Gate Winery, LLC v. Joseph G. Roche, et al. (No. A139189 & A141090, filed 4/9/15) (Ram’s Gate), the California Court of Appeal for the First Appellate District held the doctrine of merger did not extinguish a seller’s contractual duty to disclose potentially hazardous seismic conditions on a Sonoma winery property. In Ram’s Gate, the buyer of the property filed a lawsuit alleging the seller failed to disclose information relating to earthquake issues prior to the close of escrow. In the parties’ “Purchase and Sales Agreement” (Purchase Agreement) the seller agreed to disclose any information known to it regarding “known geological hazards . . . soil reports . . . geotechnical reports” and other facts “having effect on the value of the ownership or use of the property.” The seller, however, argued this disclosure warranty did not survive the escrow period because it did not expressly provide for survival while other provisions in the Purchase Agreement did. Reprinted courtesy of Kristen Lee Price, Haight Brown & Bonesteel LLP and Lawrence S. Zucker II, Haight Brown & Bonesteel LLP Ms. Price may be contacted at kprice@hbblaw.com Mr. Zucker may be contacted at lzucker@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Sellers' Alleged Misrepresentation Does Not Amount To An Occurrence

November 30, 2020 — Tred R. Eyerly - Insurance Law Hawaii
The insurer successfully established on summary judgment that the insureds' alleged misrepresentation in the sale of a condominium was not an occurrence. Novak v. St. Maxent-Wimberly House Condo., 2020 U.S. Dist. LEXIS 167397 (E.D. La. Sept. 14, 2020). State Farm issued the sellers a condominium unit owner's policy. The buyers sued the sellers, contending the sellers had made misrepresentations in the sale process. The sellers allegedly failed to disclose defects in the condominium before and at the time of the sale. State Farm intervened, seeking a declaration that it was not required to defend or indemnify the sellers because there was no occurrence. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Peckar & Abramson Once Again Recognized Among Construction Executive’s “Top 50 Construction Law Firms™”

July 02, 2024 — Peckar & Abramson, P.C.
Peckar & Abramson, P.C. (P&A) is pleased to announce that it has once again been ranked among the top of Construction Executive’s (CE) “The Top 50 Construction Law Firms™.” P&A has been recognized in this manner since 2019, the inaugural year of the publication’s rankings. According to CE, its 2024 ranking was the result of a rigorous and comprehensive survey that invited numerous U.S. law firms with a construction practice to participate. The data collected focused on unique metrics such as the firm’s construction practice, number of attorneys and clients, and year of establishment. CE’s algorithm meticulously weighed these factors, among others, to determine the ranking, ensuring the credibility and accuracy of the recognition. Firm Chair Steven M. Charney commented, “We are honored to be recognized as one of Construction Executive’s “Top 50 Construction Law Firms.” This recognition serves as a resounding testament to our commitment to the construction industry and our team’s hard work and dedication. We remain committed to providing exceptional legal services to our clients and striving for excellence in all we do.” The complete rankings and profile are available here. Read the court decision
Read the full story...
Reprinted courtesy of Peckar & Abramson, P.C.

Maui Wildfire Cleanup Could Cost $1B and Take One Year

September 18, 2023 — James Leggate - Engineering News-Record
Hawaii Gov. Josh Green and Sen. Brian Schatz (D-Hawaii) have estimated at $1 billion the cost of cleanup after the Maui wildfires—which started Aug. 8 and killed at least 115 people and destroyed more than 2,200 structures. Officials planning the rebuilding of the parts of West Maui devastated by the wildfires are emphasizing safety and residents’ wishes over speed. Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at leggatej@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

When Construction Defects Appear, Don’t Choose Between Rebuilding and Building Your Case

October 11, 2021 — Curtis Martin - ConsensusDocs
When construction defects occur during construction, they intensify pressure from a schedule that may already be tight. Defects must be analyzed, confirmed, removed, and replaced and this can be time consuming. Or course, a construction schedule rarely anticipates defects, demolition, and rework and the owner will still expect the project to be completed on time; however, pressing forward with immediate remediation may have unintended consequences. Before starting demolition, consider the evidentiary doctrine of spoliation. Spoilation occurs when a party destroys or unreasonably deprives another party of evidence and courts have imposed sanctions on a party that deprives an opponent of evidence. The doctrine has historically concerned documents, but its application has extended to electronic data, and courts also apply it to building conditions in construction defects cases. So, before tearing out or fixing defective work, consider the need to allow the opposing party to inspect, test and document it. Imagine this scenario. The concrete in a slab placed by your subcontractor shows low compressive strength results in the 28-day cylinder tests. Tearing out the slab and replacing it will put you at least a month behind schedule and you don’t want to waste any time before removing and replacing it. Nevertheless, while you’re rebuilding the defective slab, be mindful that you are also building a case. If you plan to recover the costs you incur because of the defective concrete from the responsible parties, you should allow the subcontractor (and possibly the concrete supplier and other implicated parties) to examine, preserve, and/or test the work in question. Failure to do so may subject you to spoliation sanctions and jeopardize your right to recover damages. Read the court decision
Read the full story...
Reprinted courtesy of Curtis Martin, Peckar & Abramson
Mr. Martin may be contacted at cmartin@pecklaw.com

Saved By The Statute: The Economic Loss Doctrine Does Not Bar Claims Under Pennsylvania’s Unfair Trade Practices and Consumer Protection Law

May 10, 2021 — Gus Sara - The Subrogation Strategist
In Earl v. NVR, Inc., No. 20-2109, 2021 U.S. App. LEXIS 6451, the U.S. Court of Appeals for the Third Circuit (Third Circuit) considered whether, under Pennsylvania law, the plaintiff’s Unfair Trade Practices and Consumer Protection Law (UTPCPL) claims against the builder of her home were barred by the economic loss doctrine. The UTPCPL is a Pennsylvania statute that prohibits “unfair methods of competition and unfair or deceptive acts or practices in the conduct of any trade or commerce.” 73 Pa. Stat. Ann. § 201-3. The Third Circuit previously addressed the impact of the economic loss doctrine on UTPCPL claims in Werwinski v. Ford Motor Co., 286 F.3d 661 (3d Cir. 2002). In Werwinski, the court held that the plaintiff’s UTPCPL claim was barred by the economic loss doctrine. The Court of Appeals overturned its decision in Werwinski and held that the economic loss doctrine does not bar UTPCPL claims since such claims are statutory, and not based in tort. In Earl, the plaintiff, Lisa Earl, entered into an agreement with defendant NVR, Inc. (NVR) for the construction and sale of a home in Allegheny County, Pennsylvania. Ms. Earl learned of the home through NVR’s marketing, which described the home as containing “quality architecture, timeless design, and beautiful finishes.” Ms. Earl alleged that during the construction of the home, she had further discussions with agents of NVR, who made representations that the home would be constructed in a good and workmanlike manner and that any deficiencies noted by Ms. Earl would be remedied. The defendant also assured Ms. Earl that the home would be constructed in accordance with relevant building codes and industry standards. After moving into the home, Ms. Earl discovered several material defects in the construction. She provided notice of these defects to NVR, but NVR’s attempts to repair some of the defects were inadequate. Read the court decision
Read the full story...
Reprinted courtesy of Gus Sara, White and Williams
Mr. Sara may be contacted at sarag@whiteandwilliams.com

Nevada Governor Signs Construction Defect Reform Bill

February 26, 2015 — Beverley BevenFlorez-CDJ STAFF
According to the Las Vegas Review-Journal, Nevada Governor Brian Sandoval “signed the first major Republican-backed reform bill of the 2015 session, a measure making changes to Nevada’s construction defect law.” Sandoval stated, “During my State of the State address, I challenged the Legislature with passing meaningful construction defect reform. They have met that challenge with the Homeowner Protections Act, which discourages frivolous litigation and strengthens Nevada’s rebounding housing market,” as quoted in the Las Vegas Review-Journal. The bill, which goes into effect immediately, “restricts the definition of what constitutes a home defect, repeals a provision allowing attorney fees and costs in a home defect judgment, and requires specific descriptions of defects.” It also reduces the statute of limitations from ten years to six years, and prohibits homeowner association boards from filing suits on behalf of homeowners. Not all legislatures were in favor of the measure. For instance, Sen. Aaron Ford “called the measure the ‘homeowner rejection’ act rather than a homeowner protection act at a joint hearing on the bill,” according to the Las Vegas-Review Journal. Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES