Seattle Washington Building Expert Directory

Product Liability Economic Loss Rule and “Other Property” Damage

November 28, 2022 — David Adelstein - Florida Construction Legal Updates
One of the best defenses a manufacturer has, particularly in non-personal injury cases, is the economic loss rule. Lo and behold, a recent opinion out of the Middle District of Florida, Dero Roofing, LLC v. Triton, Inc., 2022 WL 14636884 (M.D.Fla. 2022), touches on this very subject with cogent analysis regarding “other property” damage for purposes of the economic loss rule. In Dero Roofing, a roofing contractor repaired hurricane damage to roofs of condominium buildings. The roofing contractor became a certified applicator of the manufacturer Triton’s products. After the roofer applied certain products with a sprayer, the products “streaked down the roof tiles onto ‘the exterior and interior of the [Condos], including penetration of the residents’ screens, gutters, and other related areas.” Dero Roofing, supra, at *1. The roofing contractor obtained an assignment of the condominium’s claims and sued the manufacturer and distributor of the (Triton manufactured) products. The defendants moved to dismiss under the economic loss doctrine. The economic loss doctrine “prohibits tort recovery when a product damages itself, causing economic loss, but does not cause personal injury or damage to any property other than itself.” Dero Roofing, supra, at *3 (quotation and citation omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

As Climate Changes, 'Underwater Mortgage' May Take on New Meaning

August 20, 2014 — James Tarmy – Bloomberg
Looking to buy a house? That’s great, unless you’re in your 20s and 30s and regularly read climate reports. They tend to project dramatic changes to the climate over the next 50 years, and given that current life expectancy is hovering around 80, we’ll likely be around to see it. So. If you’re looking to settle down for the long haul, where’s the best place to do it? Great Plains? You're looking at higher temperatures and more demand for water and energy. The Southeast, perhaps? The region may suffer from (at least) 60 days with 95-plus degree weather by 2070, according to the 2014 National Climate Assessment. Read the court decision
Read the full story...
Reprinted courtesy of James Tarmy, Bloomberg

Businesspeople to Nevada: Revoke the Construction Defect Laws

March 01, 2012 — CDJ STAFF

The Nevada chapter of the National Federation of Independent Businesses has said that Nevada’s construction defect and minimum wage laws are hampering job growth. The organization conducted a survey, and although only about two percent of the members responded, they passed the opinions of the group on to Governor Brian Sandoval. Sandoval has said, according to the report by Fox News Reno, that he wants the state to be more business friendly. He supports reforms to Nevada’s construction defect laws, saying that he’d “like to see some reform” on the issue of mandatory attorney’s fees.

Randi Thompson, the spokesperson for the Nevada chapter of the National Federation of Independent Businesses, said that members of her organization would like to see current Nevada construction defect law revoked. She described current law as “driven towards lawyers and not toward protecting consumers.”

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

SunEdison Gets Shinsei Bank Funding for Japan Solar Power Plant

March 12, 2015 — Ehren Goossens – Bloomberg
(Bloomberg) -- SunEdison Inc., a U.S. solar developer, got financing from Tokyo-based Shinsei Bank Ltd. for a large-scale project in the country. The 9.6-megawatt Tarumizu project on the southern Japanese island of Kyushu will power about 3,000 homes, Maryland Heights, Missouri-based SunEdison said Wednesday in a statement. The project is under construction and expected to be completed in September. Financial details weren’t disclosed. Read the court decision
Read the full story...
Reprinted courtesy of Ehren Goossens, Bloomberg
Mr. Goossens may be contacted at egoossens1@bloomberg.net

Subcontract Should Flow Down Delay Caused by Subcontractors

December 21, 2020 — David Adelstein - Florida Construction Legal Updates
A general contractor’s subcontract with its subcontractor should include a provision that entitles it to flow down liquidated damages assessed by the owner stemming from delays caused by the subcontractor. Such a provision does not mean the general contractor does not have to prove delays caused by the subcontractor or can arbitrarily allocate the amount or days it claims the subcontractor is liable. The general contractor still will need to reasonably establish the delays the subcontractor caused the critical path of the schedule, i.e., delayed the job. In addition to the right to flow down liquidated damages, the subcontract should also entitle the general contractor to recover its actual extended general conditions caused by the subcontractor’s delays (regardless of whether the owner assesses liquidated damages). The objective is that if the subcontractor delays the job, the subcontractor is liable for liquidated damages the general contractor is liable to the owner for in addition to the general contractor’s own delay damages. This is an important subcontractual provision so that the risk of delay caused by subcontractors is clearly flowed down to them in the subcontract. In a 1987 case, Hall Construction Co., Inc. v. Beynon, 507 So.2d 1225 (Fla. 5th DCA 1987), the subcontract at-issue contained language that stated, “The parties hereto agree that a supplier who delays performance beyond the time agreed upon in this Purchase Order shall have caused [general contractor] liquidated damages in the amount required of [general contractor] by their contract per day for each day such delay continues which sum the supplier hereby agrees to pay.” Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Meet D1's Neutrals Series: KENNETH FLOREY

June 12, 2023 — Marissa L. Downs - The Dispute Resolver
Company: Robbins Schwartz Office Location: Chicago, IL Email: kflorey@robbins-schwartz.com Website: https://www.rsnlt.com/attorneys/kenneth-m-florey/ Law School: DePaul University (JD 1992) Types of ADR services offered: Mediation, Arbitration, Project Neutral Affiliated ADR organizations: AAA Panel of Arbitrators and Mediators Geographic area served: Nationwide Q: Describe the path you took to becoming an ADR neutral. A: I’ve been involved in construction litigation my entire career as an attorney, going on 30 years. After being an advocate for all sides to these disputes (owners, contractors, and design professionals), I recognize the immense value of ADR to clients and decided to start shifting my litigation experience and skills to the neutral realm as an arbitrator and mediator. Read the court decision
Read the full story...
Reprinted courtesy of Marissa L. Downs, Laurie & Brennan, LLP
Ms. Downs may be contacted at mdowns@lauriebrennan.com

City of Aspen v. Burlingame Ranch II Condominium Owners Association: Clarifying the Application of the Colorado Governmental Immunity Act

June 17, 2024 — David McLain - Higgins, Hopkins, McLain & Roswell, LLC
On June 17, 2024, the Colorado Supreme Court delivered a significant opinion in the case of City of Aspen v. Burlingame Ranch II Condominium Owners Association (Case No. 22SC293). This decision provides crucial guidance on the interplay between the Colorado Governmental Immunity Act (“CGIA”) and the economic loss rule in the context of construction defect claims. Background of the Case The case arose from a construction defect dispute between the City of Aspen, which served as the developer and declarant for the affordable housing condominiums at issue, and the Burlingame Ranch II Condominium Owners Association, the HOA created by Aspen to manage the association after the period of declarant control. The Association alleged that Aspen breached various warranties related to the construction of affordable housing units, leading to structural deficiencies. Aspen argued that the CGIA barred these claims because they could lie in tort. The Lower Court’s Decision The district court initially agreed with Aspen, holding that the Association’s claims sounded in tort and were therefore barred by the CGIA. The court relied on the principle that governmental immunity protects public entities from liability for claims that ‘lie in tort or could lie in tort,’ as established by the CGIA. Read the court decision
Read the full story...
Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell
Mr. McLain may be contacted at mclain@hhmrlaw.com

Certificates Of Merit For NC Lawsuits Against Engineers And Architects? (Still No)(Law Note)

April 22, 2019 — Melissa Dewey Brumback - Construction Law in North Carolina
Certificates of Merit are documents intended to show that a true issue exists with a professional’s work, prior to that person being sued. While North Carolina does require that a person suing a medical provider first have the matter reviewed by a professional (and attest to that in the Complaint), there is no requirement for any review prior to a lawsuit against an architect, engineer, or surveyor. Thus, anyone can file a lawsuit against an engineer/architect/surveyor without first having their case eyeballed reviewed by another professional. Over the years, there have been attempts at adding a Certificate of Merit requirement to design professional lawsuits. See, for example, examples here: from 2005; from 2007; from 2011; and from 2013. Read the court decision
Read the full story...
Reprinted courtesy of Melissa Dewey Brumback, Ragsdale Liggett PLLC
Ms. Brumback may be contacted at mbrumback@rl-law.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES