FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Submitting Claims on Government Projects Can Be Tricky

March 19, 2015 — Craig Martin – Construction Contractor Advisor
The Federal Circuit Court of Appeals opinion in K-Con Building Systems, Inc. v. United States illustrates the difficulties a contractor may face when pursuing a claim before a Contracting Officer. After nearly 10 years of litigation, the court found that the contractor’s claim to the Contracting Officer did not contain enough detail to allow the claim to proceed. That’s a lot of time and resources wasted on a claim that was dead from the start. K-Con was awarded a $582,000 job to design and build a Coast Guard support building in Michigan. K-Con was unable to complete the project by the finish date and the Coast Guard assessed liquidated damages of $109,554. K-Con contested the assessment of liquidated damages by submitting a one paragraph letter asserting that it was not the sole cause of the alleged delays; that the government was at fault for the delay; and the liquidated damages were an impermissible penalty. The Contracting Officer ultimately denied K-Con’s claim and K-Con appealed to the Court of Claims. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

---

Guessing as to your Construction Damages is Not the Best Approach

November 18, 2019 — David Adelstein - Florida Construction Legal Updates
Arbitrarily guessing as to your construction damages is NOT the best approach. Sure, experts can be costly. No doubt about it. Having an expert versus guessing as to your construction damages caused by another party’s breach of contract is a no brainer. Engage an expert or, at a minimum, be in a position to competently testify as to your damages caused by another party’s breach of contract. Otherwise, the guessing is not going to get you very far as a concrete subcontractor found out in Patrick Concrete Constructors, Inc. v. Layne Christensen Co., 2018 WL 6528485 (W.D. New York 2018) where the subcontractor could not competently support its delay-related damages or change orders and, equally important, could not support that the damages were proximately caused by the general contractor’s breach of the subcontract. In this case, the concrete subcontractor entered into a subcontract to perform concrete work for a public project. The project was delayed and the general contractor was required to pay liquidated damages to the owner. Not surprisingly, the subcontractor disputed liability for delays and sued the general contractor for all of its delay-related damages “in the form of labor and materials escalation, loss of productivity, procurement and impact costs, field and home office overhead, idle equipment, inability to take on other work, lost profits, and interest.” Patrick Concrete Constructors, 2018 WL at *1. The general contractor moved for summary judgment as to the plaintiff’s delay-related damages – the subcontractor’s damages were nothing but guesses and the subcontractor could not prove the general contractor was the cause of the subcontractor’s damages. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Clearly Determining in Contract Who Determines Arbitrability of Dispute

April 26, 2021 — David Adelstein - Florida Construction Legal Updates
As you know from prior postings: “Arbitration provisions are creatures of contract and must be construed ‘as a matter of contract interpretation.’ ” Fallang Family Limited Partnership v. Privcap Companies, LLC, 46 Fla.L.Weekly D639e (Fla. 4th DCA 2021) (citation omitted). Thus, if you prefer to arbitrate potential disputes, instead of litigating potential disputes, you want to include an arbitration provision in your contract. While there are positives and negatives to arbitration, no different than litigation, these positives and negatives should be considered during the contract negotiation process when dealing with the dispute resolution process in the contract. Generally, under the law, the arbitrability of a dispute is determined by the court. However, this can be deferred to the arbitrator with clear and unmistakable language in the contract. By way of example, the American Arbitration Association includes a rule that allows an arbitrator to rule on the arbitrability of the dispute, i.e., the claims asserted are subject to the governing arbitration provision in the contract. Recent law has suggested that if the objective is to authorize an American Arbitration Association arbitrator to make this determination, the contract clearly and unmistakably needs to state this intent and generally referring to the American Arbitration Association rules is not good enough. For this reason, I have included in arbitration provisions language that specifically states, “In the event of any dispute as to the arbitrability of any claim or dispute, the parties agree that an appointed arbitrator within the American Arbitration Association shall make this determination.” I have also included in arbitration provisions the converse so that if there is a dispute as to the arbitrability of a claim or dispute, the court, and not the arbitrator, will make this determination. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Collapse of Improperly Built Deck Not An Occurrence

August 17, 2017 — Tred R. Eyerly - Insurance Law Hawaii
The court found that the insured's faulty construction of an outside deck did not arise from an occurrence. Employers Mut. Cas. Co. v. West, 2017 U.S. Dist. LEXIS 113951 (N.D. Miss. July 21, 2017). D.L. Action Construction Company (DLA) constructed multifamily dwellings. They were sued by the homeowners after a deck collapsed at one of the dwellings. Also sued was the subcontractor, Littrell Construction, who installed the deck. The homeowners alleged that Littrell knew that college students would be residing in the units and that the decks would be heavily used. The decks were attached to the building structure using only nails instead of bolts. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly - Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Quick Note: Don’t Forget To Serve The Contractor Final Payment Affidavit

July 30, 2019 — David Adelstein - Florida Construction Legal Updates
If you are a contractor in DIRECT CONTRACT with an owner, serve a contractor final payment affidavit on the owner, as a matter of course, and without any undue delay, particularly if you are owed money and have recorded a construction lien. In numerous circumstances, I like to serve the contractor final payment affidavit with the construction lien. The contractor final payment affidavit is not a meaningless form. It is a statutory form (set forth in Florida Statute s. 713.06) required to be filled out by a lienor in direct privity of contract with an owner and served on the owner at least 5 days prior to the lienor foreclosing its construction lien. The contractor final payment affidavit serves as a condition precedent to foreclosing a construction lien. Failure to timely serve a contractor final payment affidavit should result in a dismissal of the lien foreclosure lawsuit, presumably by the owner moving for a motion for summary judgment. This should not occur. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Insurer Must Cover Construction Defects Claims under Actual Injury Rule

March 01, 2012 — Tred R. Eyerly - Insurance Law Hawaii

The Texas Court of Appeals held that the insured need not prove the exact dates physical damage occurred in order to trigger defense and indemnity coverage. Vines-Herrin Custom Homes, LLC v. Great Am. Lloyds Ins. Co., 2011 Tex. App. LEXIS 10027 (Tex. Ct. App. Dec. 21, 2011).



In 1999, the insured built a home. He was insured under a CGL policy issued by Great American from November 9, 1998 to November 9, 2000. Thereafter, the insured held a CGL policy issued by Mid-Continent from November 9, 2000 to September 18, 2002.



After construction was completed, the insured sold the house to the buyer in May 2000. After moving in, the buyer found numerous construction defects in the home, including water entering cracks in the home, and sinking and sagging of parts of the house. The buyer sued the insured, who sought coverage under the two policies. When the insurers refused to defend the underlying suit, the insured sued for a declaratory judgment.



The underlying case went to arbitration and an award of $2.4 million was granted to the buyer. The insured assigned to the buyer his claims against the insurers.

Read the full story…



Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

 Read the court decision
Read the full story...
Reprinted courtesy of

---

Is It Time to Get Rid of Retainage?

June 15, 2020 — David K. Taylor - Construction Executive
Many debate the pros, cons and claims of retainage—when one party to a construction contract withholds a percentage (typically 5%-10%) from an otherwise approved contractor pay application, and which typically is not paid until a project is substantially complete. If an owner withholds retainage from a prime contractor, typically the contractor will in turn withhold retainage from its subcontractors. While retainage has been part of the construction industry for decades, its concept, use (and abuse) have been under more discussion during the past 10 years. Based on heavy lobbying from primary subcontractor groups, state legislatures have passed laws to regulate retainage in commercial projects. Lenders have become more careful about loans and are frequently involved in retainage discussions. Bonded projects are subject to criticism when a surety does not step in and, like the mythical insurance company, write a check. Reprinted courtesy of David K. Taylor, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Taylor may be contacted at dtaylor@bradley.com

---

Three White and Williams Lawyers Named Top Lawyers by Delaware Today

December 07, 2020 — White and Williams LLP
White and Williams is pleased to announce that John Balaguer, Managing Partner of the Wilmington office, Partner Stephen Milewski and Counsel Dana Spring Monzo have been chosen by their peers as Delaware Today's 2020 "Top Lawyers." The annual list recognizes John, Steve and Dana in the practice area of Medical Malpractice for the Defense. John has over 30 years of experience defending complex tort cases and is recognized as one of the leading trial lawyers in the State of Delaware. Steve has over 15 years of experience as a trial lawyer specializing in healthcare law, particularly defending hospitals, doctors and healthcare providers in medical negligence cases. Dana's practice is focused on complex civil litigation, primarily medical malpractice. For more than a decade she has represented the interests of physicians, hospitals and healthcare providers in Delaware. Read the court decision
Read the full story...
Reprinted courtesy of White and Williams LLP

---