FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Presenting a “Total Time” Delay Claim Is Not Sufficient

September 12, 2022 — David Adelstein - Florida Construction Legal Updates
When presenting a delay-type of claim on a construction project, a claimant MUST be in a position to properly PROVE the claim. Trying to present a delay claim loosey-goosey is not a recipe for success. In fact, it can be a recipe for an easy loss. This is not what you want. To combat this, make sure you engage a delay expert that understands delay methodologies and how to calculate delay and do NOT present a total time claim. Presenting a delay claim using a total time approach, discussed below, makes it too easy to attack the flaws and credibility of the approach. Per the discussion of the case below, a total time claim with a contractor that used its project manager, versus a delay expert, to support its claim turned the contractor’s claim into a loss. In French Construction, LLC v. Department of Veteran Affairs, 2022 WL 3134507, CBCA 6490 (CBCA 2022), a contractor submitted a delay claim to the government for almost $400,000. The contractor was hired to construct a two-story corridor to connect hospital buildings. The contractor was required to be complete within 365 days. It was not. The contractor was seeking 419 days of delay from the government. The contractor’s “delay expert” was its project manager who compared the contractor’s as-planned schedule to an as-built schedule he prepared for the claim. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

COVID-19 Response: Executive Order 13999: Enhancement of COVID-19-Related Workplace Safety Requirements

March 08, 2021 — Alan Rupe & Luis Mendoza - Lewis Brisbois
President Biden has signed 28 Executive Orders as of February 2, 2021. While this is a large number of Executive Orders compared to the historical record, most call for creating task forces and directing agencies to explore policy changes. However, there is one that stands out to employment lawyers – Executive Order 13999 (Order). Titled “Protecting Worker Health and Safety,” the Order addresses workplace safety. It sets out instructions, primarily to the Secretary of Labor and Assistant Secretary of Labor for Occupational Safety and Health, for establishing and issuing a set of guidelines under the Occupational Safety and Health Act (OSHA). Pursuant to the Order, the Secretary of Labor will issue revised guidance to employers on workplace safety concerning COVID-19, determine if emergency workplace standards are required, and improve overall OSHA shortcomings related to COVID-19 workplace protections and enforcement. Enforcement will include the use of anti-retaliation principles concerning employees reporting unsafe conditions in the workplace. OSHA has issued initial guidance based on the Order. Reprinted courtesy of Alan Rupe, Lewis Brisbois and Luis Mendoza, Lewis Brisbois Mr. Rupe may be contacted at Alan.Rupe@lewisbrisbois.com Mr. Mendoza may be contacted at Luis.Mendoza@lewisbrisbois.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Loss of Use From Allegedly Improper Drainage System Triggers Defense Under CGL Policy

February 28, 2018 — Katherine E. Miller and Michael S. Levine – Hunton Insurance Recovery Blog
The Eleventh Circuit, in Mid-Continent Casualty Co. v. Adams Homes of Northwest Florida, Inc., No. 17-12660, 2018 WL 834896, at * 3-4 (11th Cir. Feb. 13, 2018) (per curiam), recently held under Florida law that a homebuilder’s alleged failure to implement a proper drainage system that allowed for neighborhood flooding triggered a general liability insurer’s duty to defend because the allegations involved a potentially covered loss of use of covered property. Reprinted courtesy of Katherine E. Miller, Hunton & Williams and Michael S. Levine, Hunton & Williams Ms. Miller may be contacted at kmiller@hunton.com Mr. Levine may be contacted at mlevine@hunton.com Read the court decision
Read the full story...
Reprinted courtesy of

---

N.J. Governor Signs Bill Expanding P3s

September 04, 2018 — Nick Steingart - Construction Executive
Government entities in New Jersey that enter into public-private partnerships to help finance public construction projects are now required to utilize a project labor agreement (PLA) and pay state prevailing wages, among other requirements. Previously, P3s were only available to state and county colleges, but did not contain prevailing wage or PLA mandates. The new law, Senate Bill 865, allows the state and its subdivisions, including counties, municipalities and school districts, to enter into agreements with private funding sources provided they follow the additional mandates such as abiding by the state’s prevailing wage law and utilizing a union-only PLA for construction of the project. Reprinted courtesy of Nick Steingart, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Steingart may be contacted at steingart@abc.org

---

Planes, Trains and Prevailing Wages. Ok, No Planes, But Trains and Prevailing Wages Yes

October 25, 2021 — Garret Murai - California Construction Law Blog
The California Supreme Court doesn’t often delve into construction-related issues, but this year we’ve got two cases, both related to the payment of prevailing wages on California public works projects. The first, Mendoza v. Fonseca McElroy Grinding Co., Inc. (2021) 11 Cal.5th 1118 which we discussed in our last blog post, concerned whether mobilization work qualifies as a “public work” and in turn requires the payment of prevailing wages. On the same day that the Supreme Court issued its decision in Mendoza, it issued a decision in Busker v. Wabtec Corporation, et al. , Case No. S251135 (August 16, 2021). This is the equivalent of being struck by lightning twice. In Busker, the California Supreme Court considered whether on a public transportation project “field work” (e.g., building and outfitting radio towers on land adjacent to train tracks) and “onboard work” (e.g., installing electronic components on train cars and locomotives”) requires the payment of prevailing wage. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

---

New York Regulator Issues Cyber Insurance Guidelines

March 29, 2021 — Anne Kelley - Newmeyer Dillion
From the rise of ransomware attacks to the recent SolarWinds-based cyber espionage campaign that struck at the very heart of the U.S. Government, it is apparent that cybersecurity is more critical than ever. COVID-19 and the remote workplace has only served to embolden cyber criminals, and cyber risk now permeates nearly every aspect of modern life from health care data to national security. Cyber insurance plays a critical role in managing cyber risk, and businesses increasingly rely on such coverage to minimize cyber losses. Because of surging cybercrime, it is estimated that the cyber insurance market will increase from $3.15 billion in 2019 to $20 billion by 2025. Having a robust cyber insurance market and ample available coverage is vital to U.S. businesses. In recognition of this reality, the New York Department of Financial Services recently issued the first guidance by a U.S. regulator on cyber insurance—a Cyber Insurance Risk Framework. A key premise of the Framework is to drive improved cybersecurity and cyber risk management, thereby reducing cyberattacks and ensuring that cyber insurance premiums do not spiral out of control. The Framework recognizes the importance of ensuring a healthy cyber insurance market, and applies to all property/casualty insurers that write cyber insurance. Read the court decision
Read the full story...
Reprinted courtesy of Anne Kelley, Newmeyer Dillion
Ms. Kelley may be contacted at anne.kelley@ndlf.com

---

Texas Couple Claim Many Construction Defects in Home

October 08, 2013 — CDJ STAFF
A Galveston, Texas couple has claimed that their new home has “many” defects and are suing the seller. John Klein and Cheri Harmon-Klein state that they were told that the house was built in conformance with the International Residential Code and that the all hurricane damage had been repaired. Instead, they characterized the house as “unfit for human habitation.” The couple claims that the defects were not evident at inspection prior to their purchase. Read the court decision
Read the full story...
Reprinted courtesy of

---

Consolidated Case With Covered and Uncovered Allegations Triggers Duty to Defend

May 20, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The Illinois Court of Appeals held that the insurer had a duty to defend a consolidated case that included one complaint alleging intentional acts and another complaint alleging negligence. Farmers Auto. Ins. Ass'n v. Neumann, 2015 Il. App. 140026 (Ill. Ct. App. March 24, 2015, reh'g denied March 24, 2015). Neumann allegedly hit Bitner with his automobile as Bitner, a police offier, was directing traffic. Bitner sued Neumann, alleging intentional assault and intentional battery. Farmers rejected Neumann's tender because the policy did not cover intentional acts. Farmers filed for a declaratory judgment. In his answer, Neumann included an affidavit stating that he did not intend to strike or cause bodily harm to Bitner. The trial court granted the motion to strike the affidavit. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---