SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

January 27, 2020 — Ted R. Gropman & Christine Z. Fan - ConsensusDocs
Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date. Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved. There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973). Reprinted courtesy of Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP Mr. Gropman may be contacted at gropmant@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

South Carolina “Your Work” Exclusion, “Get To” Costs

July 30, 2014 — Scott Patterson - CD Coverage
In Precision Walls, Inc. v. Liberty Mutual Fire Insurance Co., No. 2013-000787 (S.C. Ct. App. July 23, 2014), SYS was the general contractor for a project. SYS contracted with Precision for the supply and installation of exterior insulation board, to include the taping of all joints. After Precision completed its work, another subcontractor began construction of the brick veneer wall over the insulation board. During construction of the brick wall, some of the joint sealing tape installed by Precision began to come loose. To correct the problem, the existing portion of the brick veneer wall had to be torn down, all of the joint sealing tape removed and replaced, and the brick veneer wall rebuilt. SYS deducted the cost of tearing down and rebuilding the brick veneer wall from Precision’s contract. Precision sought reimbursement for this amount from its CGL policy issued by Liberty Mutual. Read the court decision
Read the full story...
Reprinted courtesy of Scott Patterson, CD Coverage

---

South African Building Industry in Line for More State Support

November 08, 2021 — Prinesha Naidoo - Bloomberg
South Africa’s government is planning more measures to bolster its ailing building industry after banning the use of imported cement on state construction projects. “Government is undertaking research across a range of construction-related products where there appears to be significant potential for localization,” Stephen Hanival, chief economist at the Department of Trade, Industry and Competition, said in an emailed response to questions. “Further announcements will be made in due course.” The country’s preferential procurement policy framework enables the department to designate sectors for localization in line with national development and industrial policy goals. While the government has pursued localization since 2014, it has become more strategic since the advent of the pandemic with business, government and labor groups agreeing on an initial list of 42 products and sub-sectors that should be prioritized, Hanival said. Read the court decision
Read the full story...
Reprinted courtesy of Prinesha Naidoo, Bloomberg

---

General Contractor’s Professional Malpractice/Negligence Claim Against Design Professional

November 30, 2017 — David Adelstein - Florida Construction Legal Updates
A recent case supports a professional malpractice (negligence) claim by a general contractor against a design professional by reversing a trial court’s entry of summary judgment in favor of the design professional and finding a question of fact remained as to an architect’s role in the renovation of a public construction project. By the appellate court finding that a question of fact remained, the appellate court was finding that it was a triable issue, which is exactly what the general contractor wanted in this case. Getting this issue and the facts to the jury is the leverage the general contractor presumably wanted. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

---

United States Supreme Court Limits Class Arbitration

May 13, 2019 — Jeffrey K. Brown & Raymond J. Nhan - Payne & Fears
On April 24, 2019, the United States Supreme Court held that the Federal Arbitration Act ("FAA") bars orders requiring class arbitration when an agreement is ambiguous about the availability of such a procedure. Lamps Plus v. Varela, 587 U.S. __ , 2019 WL 1780275, (2019). In Lamps Plus, the Court clarified a 2010 case in which it held that a court may not compel arbitration on a class-wide basis when an agreement is silent on the availability of class arbitration. Stolt-Nielsen S.A. v. Animal Feeds Int'l Corp., 559 U.S. 662, 687 (2012). In Lamps Plus, a 5-4 decision authored by Chief Justice Roberts, the Court explained that because the FAA envisions the use of traditional individualized arbitration, a party cannot be forced under the FAA to submit to class arbitration unless the parties explicitly agreed to do so. Because class arbitration does not share the benefits of traditional arbitration -- lower costs, greater efficiency and speed, and the parties' choice of a neutral -- the FAA requires more than an "ambiguous" agreement to show that the parties bound themselves to arbitrate on a class-wide basis. Unlike individualized arbitration, or even traditional class actions, class arbitration raises serious due process concerns because absent class members will have limited judicial review. Based on these critical differences between individual and class arbitration, the Court reiterated in Lamps Plus that "courts may not infer consent to participate in class arbitration absent an affirmative contractual basis for concluding that the party agreed to do so." Reprinted courtesy of Jeffrey K. Brown, Payne & Fears and Raymond J. Nhan, Payne & Fears Mr. Brown may be contacted at jkb@paynefears.com Mr. Nhan may be contacted at rjn@paynefears.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Amazon Hits Pause on $2.5B HQ2 Project in Arlington, Va.

March 27, 2023 — Jim Parsons - Engineering News-Record
Amazon is tapping the brakes on its $2.5-billion HQ2 second headquarters project in Arlington County, Va., announcing an indefinite delay to the start of the program’s 2.8-million-sq-ft second phase, known as PenPlace. Reprinted courtesy of Jim Parsons, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

Boston Team Secures Summary Judgment Dismissal on Client’s Behalf in Serious Personal Injury Case

October 21, 2024 — Lewis Brisbois Newsroom
Boston, Mass. (October 14, 2024) - Boston Managing Partner Kenneth B. Walton and Partner Matthew M. O' Leary recently secured summary judgment on behalf of a civil engineering firm in a serious personal injury matter arising from a trip-and-fall incident in a mall parking lot. The client was retained to provide site civil engineering design for the parking lot of a local mall. The design included multiple bioretention areas known as rain gardens. In November of 2019, a woman tripped and fell while attempting to cross a rain garden to reach her car. She suffered significant bodily injuries, including a fracture of the cervical spine that resulted in partial paralysis. The woman and her husband sued the mall's owner for negligence and loss of consortium in June 2021. The owner, in turn, impleaded Lewis Brisbois' client and the lot's builder, asserting third-party claims for contribution, contractual and common law indemnity, and breach of contract. In addition, the builder cross-claimed against Lewis Brisbois' client for contribution and common law indemnity. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

---

Real Estate & Construction News Roundup (6/4/24) – New CRE Litmus Tests, Tech Integration in Real Estate and a Jump in Investor Home Purchases

July 02, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, big bank exposure to CRE lending grows, concerns for the construction industry abound, U.S. hotel securitized loans come due, and more!

• At some of the world’s biggest banks, loans to commercial real estate face new litmus tests that promise to shape the sector’s access to financing. (Frances Schwartzkopff and Gautam Naik, Bloomberg)
• Big banks’ exposure to CRE lending grows by about 40% when indirect lending to REITs is added. (Todd Gillespiev, Bloomberg)
• Cybersecurity threats, cost overruns, high interest rates, labor shortages and an economic downturn dominate the concerns of the construction industry. (Sebastian Obando, Construction Dive)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

---