Banks Loosening U.S. Mortgage Standards: Chart of the Day
August 13, 2014 —
Jody Shenn – BloombergPerhaps more U.S. banks than at any time in two decades are making it easier to qualify for a mortgage.
The CHART OF THE DAY shows the net share of banks telling the Federal Reserve that they’re tightening standards in the home-loan market. In the central bank’s July survey of senior loan officers released last week, the net percentage for prime mortgages was negative 18.3 percent, by far the most loosening since it started asking the question by loan-quality category in 2007. It was also greater than the highest net share of banks easing in “all” mortgages in the 1990s or 2000s.
Still, lenders have a long way to go before they unwind the restrictions they imposed in the wake of the global financial crisis that risky home loans helped to create. The current trend is mainly about “small tweaks around the edges,” according to JPMorgan Chase & Co. mortgage-bond analysts.
Read the court decisionRead the full story...Reprinted courtesy of
Jody Shenn, BloombergMs. Shenn may be contacted at
jshenn@bloomberg.net
Wearable Ways to Work in Extreme Heat
July 15, 2024 —
Clare Epstein - Construction ExecutiveEarth experienced its hottest months yet in summer 2023, and
NASA scientists are expecting 2024 to be even hotter. Rising temperatures and high humidity aren’t just uncomfortable for those outside during the summer months: They can cause serious health consequences, including death. While employers are working to find ways to combat the heat, the extreme variability in weather conditions continues to pose threats to employees.
Recently, company leaders have turned to new methods and technologies to help their teams stay safe while working both indoors and outdoors. A balance of methods and technology is necessary to keep everyone safe while they work. As summer approaches, is important to remember that the time to review and update current heat-stress safety plans is in the spring—or better yet, year-round—in order to prioritize employee safety and determine both proactive and reactive measures needed to withstand the hottest months of the year.
TRIED AND TRUE
While we are all navigating new ways of working safely in extreme temperatures, the tried-and-true measures are still extremely useful in preventing heat stress among employees. Employers can support their employees working outdoors by ensuring there are proper amenities available at all times, including shady areas, a water source and electrolyte drinks.
Reprinted courtesy of
Clare Epstein, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Policyholder Fails to Build Adequate Record to Support Bad Faith Claim
May 19, 2011 —
Tred R. EyerlyThe importance of careful preparation and documentation was the take away lesson in a Texas bad faith case, C.K. Lee v. Catlin Specialty Ins. Co., 2011 U.S. Dist. LEXIS 19145 (S.D. Tex. Feb. 28, 2011).
C.K. Lee owned a commercial shopping center in Houston. Catlin issued a commercial property policy to Lee. On September 12, 2008, Hurricane Ike hit and caused substantial property damage throughout the Texas Gulf Coast area. On September 24, 2008, Lee submitted a claim for damage to the roof of his shopping center to Catlin.
Catlin hired Engle Martin to represent its interests in adjusting the claim. Engle Martin eventually adjusted over 200 Ike-related claims for Catlin.
In November 2008, Engle Martin and Emergency Services Inc., retained by Lee, inspected Lee’s property. Engle Martin observed evidence of roof repairs that had apparently been made both before and after Hurricane Ike. Engle Martin decided it was necessary to use an infrared scan of the roof to help identify which damages, if any, were attributable to wind and which, if any, were attributable to sub par, prior repairs or natural deterioration.
Engle Martin retained Project, Time & Cost (PT&C) to conduct the infrared inspection. PT&C’s inspection determined there was no wind-related damage to the roof and no breaches or openings created by wind. Instead, the roof had exceeded its life expectancy and was in need of replacement due to normal wear and weathering. Consequently, Catlin decided that the damage to Lee’s roof was not caused by winds from Hurricane Ike.
Meanwhile, Lee’s contractor, Emergency Services, prepared a report estimating that the total cost of repairing the roof would be $871,187. Engle Martin’s estimate for repair of the roof was $22,864.
Lee filed suit for breach of contract, breach of the duty of good faith and fair dealing, and violations of the Texas Insurance Code. Catlin moved for summary judgment on all claims but breach of contract, arguing that because there was a bona fide dispute concerning the cause of the damages and whether they were covered under the policy, there was no evidence of bad faith or violations of the Texas Insurance Code.
Read the full story…
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com
Read the court decisionRead the full story...Reprinted courtesy of
What Every Project Participant Needs to Know About Delay Claims
August 05, 2024 —
Andrew G. Vicknair - The Dispute ResolverA “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays.
I. Types of Delays
Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule.
Read the court decisionRead the full story...Reprinted courtesy of
Andrew G. Vicknair, D'Arcy Vicknair, LLCMr. Vicknair may be contacted at
agv@darcyvicknair.com
How Drones are Speeding Up Construction
July 26, 2017 —
Aarni Heiskanen - AEC BusinessDrones, or unmanned aerial vehicles (UAVs), are being used in many industries, e.g. agriculture, construction, mining, oil & gas, mapping, and surveying. In construction, drones have proven to be quite disruptive, offering huge productivity increases.
Gartner’s famous Hype Cycle for Emerging Technologies, 2016, positioned drones as just entering the Peak of Inflated Expectations. Gartner claims that, “Smart machine technologies will be the most disruptive class of technologies over the next 10 years due to radical computational power, near-endless amounts of data, and unprecedented advances in deep neural networks.”
Commercial UAVs are one of the smart machine technologies in question, together with smart robots, autonomous vehicles, cognitive expert advisors, and others.
Read the court decisionRead the full story...Reprinted courtesy of
Aarni Heiskanen, AEC BusinessMr. Heiskanen may be contacted at
info@aepartners.fi
After Fatal House Explosion, Colorado Seeks New Pipeline Regulations
May 10, 2017 —
Mark Shaw - Engineering News-RecordColorado Gov. John Hickenlooper (D) has ordered comprehensive inspections, along with new monitoring and testing procedures, for all oil and gas pipelines located near houses and other buildings across the state. The action follows an April gas explosion in a northern Colorado home that killed two people.
Read the court decisionRead the full story...Reprinted courtesy of
Mark Shaw, ENRMr. Shaw may be contacted at
shawm@enr.com
Formal Request for Time Extension Not Always Required to Support Constructive Acceleration
April 25, 2022 —
David Adelstein - Florida Construction Legal UpdatesDoes a constructive acceleration claim require the contractor to always request an extension of time which is then denied by the owner? While this is certainly the preference and the contractor should be requesting an extension of time as a matter of course for an excusable delay, the answer is NO! in certain circumstances. This is conveyed in the factually detailed case discussed below where a formal request for an extension of time was not required for the contractor to support its constructive acceleration claim.
But first, what is constructive acceleration:
Constructive acceleration “occurs when the government demands compliance with an original contract deadline, despite excusable delay by the contractor.” The Federal Circuit in Fraser defined the elements of constructive acceleration as follows:
(1) that the contractor encountered a delay that is excusable under the contract; (2) that the contractor made a timely and sufficient request for an extension of the contract schedule; (3) that the government denied the contractor’s request for an extension or failed to act on it within a reasonable time; (4) that the government insisted on completion of the contract within a period shorter than the period to which the contractor would be entitled by taking into account the period of excusable delay, after which the contractor notified the government that it regarded the alleged order to accelerate as a constructive change in the contract; and (5) that the contractor was required to expend extra resources to compensate for the lost time and remain on schedule.
Nova Group/Tutor-Saliba v. U.S., 2022 WL 815826, *42 (Fed.Cl. 2022) quoting Fraser Constr. Co. v. U.S., 384 F.3d 1354, 1361 (Fed. Cir. 2004) (internal citations omitted).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Hawaii Federal District Court Remands Coverage Dispute
June 15, 2020 —
Tred R. Eyerly - Insurance Law HawaiiAccepting the insured's amended complaint, the federal district court of Hawaii remanded the coverage action to state court. Hale v. Lloyd's, London, 2020 U.S. Dist. LEXIS 9061 (D. Haw. Jan. 17, 2020).
Hale purchased a policy for his home in Hilo, Hawaii, from Defendant Pyramid Insurance Centre. The policy was memorialized by a Lloyd's Certificate issued by Defendant Lloyd's. On September 19, 2017, Hale entered Chapter 7 Bankruptcy. Included in the bankruptcy proceeding was Hale's home and a secured home mortgage loan now owned by Defendant Specialized Loan Servicing, LLC. The Bankruptcy Court issued a discharge order on January 18, 2018.
On May 9, 2018, Hale's home was destroyed, being covered with lava from the Kilauea volcano eruption. Hale filed a claim with Lloyd's based upon the loss of his home. The claim was denied. Subsequently, however, Lloyd's issued a check for the full amount of the policy. Both Hale and Specialized Loan were listed as payees on the check.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
